Final Condition Sample Clauses

Final Condition. The “Final Condition” of the applicable Building shall mean that (A) the Base, Shell and Core of such Building has been substantially completed in accordance with the Base Building Construction Drawings and Specifications and Applicable Laws to the extent necessary for Landlord to obtain a certificate of occupancy or temporary certificate of occupancy, or legal equivalent (each, a “CofO”), for the applicable Base, Shell and Core, and (B) the Common Areas that relate to Tenant’s use or occupancy of the applicable Phase have been substantially completed in accordance with the Base Building Construction Drawings and Specifications and Applicable Laws to the extent necessary for Landlord to obtain a CofO, excluding the completion of “punch-list” items (the “Base Building Punch List Items”). The Final Condition of the Premises shall be deemed to occur on the date such Final Condition would have occurred but for Tenant Delays. As used herein, the term “Tenant Delay” shall mean an actual delay in achieving the Delivery Condition or Final Condition to the extent caused by: (i) the failure of Tenant to timely approve or disapprove any matter requiring Tenant’s approval relating to the construction of the Base, Shell and Core; or (ii) unreasonable (when judged in accordance with industry custom and practice) interference by Tenant, its agents or other Tenant Parties with the substantial completion of the Base, Shell and Core which interference continues for more than one (1) business day following written notice from Landlord. For purposes of clarification, Base Building Punch List Items shall not include any items that would (I) materially interfere with the operation of Tenant’s business from the applicable Phase or (II) prevent Tenant from obtaining a CofO for the applicable Phase following Tenant’s substantial completion of the Improvements in the applicable Phase. Without limiting the foregoing, the Final Condition with respect to a particular Phase shall not be deemed to have occurred, other than as a result of Tenant Delays, unless (i) Tenant has access to and from the applicable Building, the applicable Phase and the Parking Facilities, (ii) Tenant has use of the Parking Facilities, (iii) all Building Systems serving the applicable Phase are complete (except for Base Building Punch List items applicable thereto) and Landlord is providing services to the applicable Phase in accordance with the requirements of the Lease, and (iv) Tenant may conduct its busines...
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Final Condition. Owner and Renter agree that the Boat was in the following condition upon the return of the Boat to Owner (the “Final Condition”): Item Final Condition Exterior and Bimini Top Seats Carpet Upholstery Ladder Jet Pump Stereo and Speakers
Sample 1
Final Condition. Landlord and Tenant acknowledge and agree that Landlord satisfied the “Final Condition” (as defined in Section 1.3 of the Work Letter attached to the Lease as Exhibit B) with respect to Building A and Building B as required by the terms of the Lease, on September 25, 2015. Notwithstanding the foregoing, following the date of this Second Amendment, Landlord shall perform certain electrical work required in connection with the installation of one (1) additional electric vehicle charging station in the Project parking facilities.
Sample 1
Final Condition. The "Final Condition" shall mean that the Base, Shell and Core of the Building has been substantially completed in accordance with the Base Building Plans (as the same may be modified in accordance with the terms and conditions of this Work Letter) to the extent necessary for Landlord to obtain a certificate of occupancy or temporary certificate of occupancy, or legal equivalent (each, a "CofO"), for the Base, Shell and Core, and (B) the Common Areas that relate to Tenant's use or occupancy of the Building, the Food and Beverage Space and the Parking Facilities have been substantially completed in accordance with the Base Building Plans to the extent necessary for Landlord to obtain a CofO, with the exception of any punch list items (the "Base Building Punch List Items"). The date that Landlord causes the Final Condition to occur shall be referred to as the "Final Condition Date". The Final Condition Date shall be deemed to occur on the date such Final Condition would have occurred but for Tenant Delays; provided that the number of days of Tenant Delays shall be offset by the number of days, if any, that the construction of the Improvements are delayed as a result of Landlord's interference with the construction of the Improvements. The Final Condition Date shall be deemed to occur on the date the Final Condition would have occurred but for Tenant Delays, subject to Landlord Delay Days.
Sample 1
Final Condition. The “Final Condition” of the Building shall mean that the Landlord Initial Compliance Obligations have been completed and the Base Building Improvements have been substantially completed in accordance with the Base Building Plans (as the same may be modified in accordance with the terms and conditions of this Tenant Work Letter), with the exception of any punch list items (the “Base Building Punch List Items”). The date that Landlord causes the Final Condition to occur shall be referred to as the “Final Condition Date;” provided, however, that if a Tenant BB Delay occurs, then the Final Condition Date shall be deemed to occur on the date the Final Condition would have occurred but for Tenant BB Delays.
Sample 1
Final Condition. The "Final Condition" shall mean that the Base, Shell and Core of the applicable Building has been substantially completed in accordance with the Base Building Plans (as the same may be modified in accordance with the terms and conditions of this Tenant Work Letter) to the extent necessary for Landlord to obtain a certificate of occupancy or temporary certificate of occupancy, or legal equivalent (each, a "CofO"), for the applicable Base, Shell and Core, except to the extent Landlord's inability to obtain the CofO is caused by the Tenant Improvements not being designed per Code or because the Substantial Completion of the Tenant Improvements has not yet occurred, as those terms are defined below. The date that Landlord causes the Final Condition to occur shall be referred to as the "Final Condition Date". The Final Condition Date shall occur separately as to each Building and shall be deemed to occur on the date the Final Condition would have occurred but for any Tenant Delay (as defined below). As used herein, the term "Tenant Delay" shall mean (i) the failure of Tenant to timely approve or disapprove any matter requiring Tenant's approval relating to the construction of the Base, Shell and Core; (ii) 788287.02/WLA 375755-00007/7-26-18/mjh/ejw EXHIBIT B -1- CXXXXXX HIGHLINE 1173, 1167 & 1000 Xxxxxxx Xxxxxx Roku, Inc. unreasonable (when judged in accordance with industry custom and practice) interference by Tenant, its agents or Tenant Parties (except as otherwise allowed by this Tenant Work Letter) with the substantial completion of the Base, Shell and Core and which objectively preclude or delay the construction of the Base, Shell and Core and the Delivery Date and (iii) Tenant's physical alteration of the items of the Base, Shell and Core on any floor of the Premises or Tenant's failure to complete or construct any portion of the Tenant Improvements (including temporary or permanent life-safety work or fire sprinkler work) (such altered item or item that Tenant fails to construct shall each be a "TI Item"), which altered or unconstructed TI Item interferes with Landlord's ability to cause the substantial completion of the Base, Shell and Core; provided that to the extent Landlord reasonably determines that the altered or unconstructed TI Item will delay the substantial completion of the Base, Shell and Core, Landlord may, upon prior notice to Tenant, modify such altered TI Item or construct the unconstructed TI Item, and deduct the cost thereof (as reas...
Sample 1
Final Condition. The “Final Condition” shall be deemed to have occurred when both of the following have occurred: (1) the Base, Shell and Core for both Buildings have been substantially completed in accordance with the Base Building Plans (as the same may be modified in accordance with the terms and conditions of this Work Letter), and Landlord’s architect has certified in writing that the Base, Shell and Core have been completed in accordance with the Base Building Plans, with the exception of any punch list items, (2) all necessary governmental inspections of the Base, Shell and Core for both Buildings have been obtained and approved, and the City of Sunnyvale has signed off on the permit cards for the Base, Shell and Core for both Buildings, (3) all utilities systems serving the Buildings, the elevators serving the Buildings, the life safety support systems serving the Buildings (including fire sprinklers and safety auditory systems), all heating, ventilating and air conditioning systems and all mechanical, electrical and plumbing systems serving the Buildings, except to the extent such items may be included in the Tenant Improvements, have been installed and are operating; (4) the Buildings are in such a state of completion that, upon completion of the Tenant Improvements, the requirements necessary to obtain approval for occupancy of the Premises from applicable governmental authorities (including approval from the Building Department and Fire Department of the City of Sunnyvale for Tenant to occupy the Premises) have been satisfied; and (5) the “Site Planning” work (parking structure, roadways, sidewalks, Project lighting, plaza area, and landscaping) described in Schedule 1 of this Work Letter is completed to the extent necessary to obtain approval for occupancy of the Premises from applicable governmental authorities (including approval from the Building Department and Fire Department of the City of Sunnyvale for Tenant to occupy the Premises) upon completion of the Tenant Improvements. The “Final Condition Date” shall be the earlier of (a) the date on which Final Condition occurs, or (b) the date on which Final Condition would have occurred but for Tenant Delays. If the Final Condition Date has not occurred on or before the Required Completion Date (defined below), Tenant
Sample 1
AutoNDA by SimpleDocs
Final Condition. The "Final Condition" shall mean that (i) the Base, Shell and Core of the Building has been substantially completed in material conformance with the Base Building Plans (as the same may be modified in accordance with the TCCs of this Work Letter) to the extent necessary for Landlord to obtain a certificate of occupancy or temporary certificate of occupancy, or legal equivalent (each, a "CofO"), for the Base, Shell and Core, except to the extent Landlord's inability to obtain the CofO is caused by the Improvements not being designed per Code or because the Substantial Completion of the Improvements has not yet occurred, as those terms are defined below, (ii) the Common Areas have been substantially completed in accordance with the Base Building Plans (as the same may be modified in accordance with the TCCs of this Work Letter) to the extent necessary for Landlord to obtain a CofO for the Building, with the exception of any punch list items (the "Base Building Punch List Items").
Sample 1

Related to Final Condition

  • ORIGINAL CONDITIONS A. All reinsurance under this Contract shall be subject to the same rates, terms, conditions, waivers and interpretations and to the same modifications and alterations as the Policy, subject to the terms and conditions of this Contract, and the Reinsurer shall be credited with its exact proportion of the Insured's premiums due to the Company under the Policy.

  • Physical Condition Except as disclosed in the Physical Conditions Reports delivered to Lender in connecting with this Loan, to Borrower's knowledge, the Property, including, without limitation, all buildings, improvements, parking facilities, sidewalks, storm drainage systems, roofs, plumbing systems, HVAC systems, fire protection systems, electrical systems, equipment, elevators, exterior sidings and doors, landscaping, irrigation systems and all structural components, are in good condition, order and repair in all material respects; there exists no structural or other material defects or damages in the Property, whether latent or otherwise, and Borrower has not received notice from any insurance company or bonding company of any defects or inadequacies in the Property, or any part thereof, which would adversely affect the insurability of the same or cause the imposition of extraordinary premiums or charges thereon or of any termination or threatened termination of any policy of insurance or bond.

  • Additional Conditions For each mediation or arbitration:

  • Financial Condition There shall have been no material adverse change, as determined by Bank, in the financial condition or business of Borrower, nor any material decline, as determined by Bank, in the market value of any collateral required hereunder or a substantial or material portion of the assets of Borrower.

  • Special Conditions A submitted appeal must;

  • Environmental Condition Except as set forth on Schedule 5.12 to the Information Certificate, (a) to each Loan Party’s knowledge, no properties or assets of any Loan Party or any of its Subsidiaries have ever been used by a Loan Party, its Subsidiaries, or by previous owners or operators in the disposal of, or to produce, store, handle, treat, release, or transport, any Hazardous Materials, where such disposal, production, storage, handling, treatment, release or transport was in violation, in any material respect, of any applicable Environmental Law, (b) to each Loan Party’s knowledge, after due inquiry, no Loan Party’s nor any of its Subsidiaries’ properties or assets have ever been designated or identified in any manner pursuant to any environmental protection statute as a Hazardous Materials disposal site, (c) no Loan Party nor any of its Subsidiaries has received notice that a Lien arising under any Environmental Law has attached to any revenues or to any Real Property owned or operated by a Loan Party or its Subsidiaries, and (d) no Loan Party nor any of its Subsidiaries nor any of their respective facilities or operations is subject to any outstanding written order, consent decree, or settlement agreement with any Person relating to any Environmental Law or Environmental Liability that, individually or in the aggregate, could reasonably be expected to result in a Material Adverse Change.

  • Financial Conditions Section 4.01. (a) The Recipient shall maintain or cause to be maintained a financial management system, including records and accounts, and prepare financial statements in a format acceptable to the Bank, adequate to reflect the operations, resources and expenditures in respect of the Project and each Sub-project (including its cost and the benefits to be derived from it).

  • Investigation of Financial Condition Without in any manner reducing or otherwise mitigating the representations contained herein, Company shall have the opportunity to meet with Buyer's accountants and attorneys to discuss the financial condition of Buyer. Buyer shall make available to Company all books and records of Buyer.

  • Mutual Conditions The respective obligations of each party to consummate the purchase and issuance and sale of the Purchased Units shall be subject to the satisfaction on or prior to the Closing Date of each of the following conditions (any or all of which may be waived by a party on behalf of itself in writing, in whole or in part, to the extent permitted by applicable Law):

  • Environmental Conditions A Phase I environmental site assessment (or update of a previous Phase I and or Phase II environmental site assessment) and, with respect to certain Mortgage Loans, a Phase II environmental site assessment (collectively, an “ESA”) meeting ASTM requirements conducted by a reputable environmental consultant in connection with such Mortgage Loan within 12 months prior to its origination date (or an update of a previous ESA was prepared), and such ESA (i) did not identify the existence of Recognized Environmental Conditions (as such term is defined in ASTM E1527-05 or its successor, hereinafter “Environmental Condition”) at the related Mortgaged Property or the need for further investigation, or (ii) if the existence of an Environmental Condition or need for further investigation was indicated in any such ESA, then at least one of the following statements is true: (A) an amount reasonably estimated by a reputable environmental consultant to be sufficient to cover the estimated cost to cure any material noncompliance with applicable Environmental Laws or the Environmental Condition has been escrowed by the related Mortgagor and is held or controlled by the related lender; (B) if the only Environmental Condition relates to the presence of asbestos-containing materials, radon in indoor air, lead based paint or lead in drinking water, the only recommended action in the ESA is the institution of such a plan, an operations or maintenance plan has been required to be instituted by the related Mortgagor that can reasonably be expected to mitigate the identified risk; (C) the Environmental Condition identified in the related environmental report was remediated, abated or contained in all material respects prior to the date hereof, and, if and as appropriate, a no further action, completion or closure letter or its equivalent, was obtained from the applicable governmental regulatory authority (or the Environmental Condition affecting the related Mortgaged Property was otherwise listed by such governmental authority as “closed” or a reputable environmental consultant has concluded that no further action or investigation is required); (D) an environmental policy or a lender’s pollution legal liability insurance policy that covers liability for the Environmental Condition was obtained from an insurer rated no less than “A-” (or the equivalent) by Xxxxx’x, S&P and/or Fitch; (E) a party not related to the Mortgagor was identified as the responsible party for the Environmental Condition and such responsible party has financial resources reasonably estimated to be adequate to address the situation; or (F) a party related to the Mortgagor having financial resources reasonably estimated to be adequate to address the situation is required to take action. To Seller’s knowledge, except as set forth in the ESA, there is no Environmental Condition at the related Mortgaged Property.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!