Substantially Common Control means, as used in the context of 40 O.S. §3- 111.1, means that sixty percent (60%) of the methods or mechanisms of control of the predecessor is found to be in place and ongoing in the successor entity.
Substantially Completed or “Substantial Completion” means that (i) Landlord has completed the Finish Work in accordance with the Working Plans, except for (x) minor details of construction that will not unreasonably interfere with Tenant’s use of the Premises (collectively, “Punch List Items”), and (y) any part of the Finish Work that is not completed due to any act or omission of Tenant or Tenant’s Visitors; and (ii) Landlord has obtained a valid temporary or permanent certificate of occupancy for the Premises (provided that any such temporary certificate of occupancy permits occupancy of the Premises and provided that Landlord delivers a copy of the permanent certificate of occupancy to Tenant promptly upon receipt of same) or, alternatively, Landlord has completed all Finish Work necessary to entitle Landlord to the issuance of a temporary or permanent certificate of occupancy but for the completion of any Finish Work that is not completed due to any act or omission of Tenant or Tenant’s Visitors (in which case, Landlord shall diligently pursue such temporary or permanent certificate of occupancy following the completion of any such Finish Work that is not completed due to any such act or omission of Tenant or Tenant’s Visitors). If the completion of the Finish Work is delayed due to any act or omission by Tenant or Tenant’s Visitors, including, but not limited to, delays due to changes in or additions to the Finish Work requested by Tenant, delays in submission of information or estimates, delays in giving authorizations or approvals, or delays due to the postponement of any work at the request of Tenant, then the date set forth in paragraph (7) of the Basic Lease Provisions on which Tenant actually begins to pay Basic Rent will be accelerated by the number of days of delay caused by Tenant and Tenant’s Visitors (any such delay being referred to herein as a “Tenant Delay”).
Substantially Complete or “Substantial Completion” shall mean that (a) the Base Building Improvements that are required to permit Tenant to enter the Premises for purposes of performing the Tenant Improvement have been completed in accordance with the Building Plans, the correction or completion of which items, collectively, will not substantially interfere with Tenant’s ability to commence the Tenant Improvement Work and (b) Tenant is legally permitted to enter the Premises for purposes of performing the Tenant Improvement Work. Landlord and Tenant shall then arrange a mutually convenient time, no later than ten (10) Business Days after the anticipated Substantial Completion Date specified in Landlord’s notice, for Tenant and/or Tenant’s Architect (as defined below) and Landlord and/or Landlord’s Architect to conduct a walk-through inspection of the Base Building Improvements. During the inspection, Landlord’s Architect shall compile a punchlist of items yet to be completed. If Tenant or Tenant’s Architect shall fail to inspect the Base Building Improvements within ten (10) Business Days after the Substantial Completion Date specified in Landlord’s notice, the Base Building Improvements shall be deemed completed and satisfactory in all respects, and the Substantial Completion Date shall be the date set forth in Landlord’s notice. Landlord shall use commercially reasonable efforts to cause the remaining Base Building Improvements to have been completed on or before the Term Commencement Date in accordance with the Building Plans, the correction or completion of which items, collectively, will not substantially interfere with Tenant’s ability to occupy the Premises to commence the Tenant Improvement Work
Substantially limits means the extent to which the impairment limits an individual’s ability to perform a major life activity as compared to most people in the general population, whether or not an individual chooses to forgo mitigating measures. 42 U.S.C. 126 §12102(4); 28 CFR §35.108(d); 28 CFR §35.105(d) The rules of construction when determining whether an impairment substantially limits performance of a major life activity include:
Substantially similar means substantially similar in function or capability or otherwise competitive to the products or services being developed, manufactured or sold by the Company during and/or at the end of Executive’s employment, or are marketed to substantially the same type of user or customer as that to which the products and services of the Company are marketed or proposed to be marketed.
Not Typically Combined Network Elements shall mean that the particular Network Elements requested by ONS are not elements that BellSouth combines for its use in its network.
Biologically-based mental illness means schizophrenia, schizoaffective disorder, major depressive disorder, bipolar disorder, paranoia and other psychotic disorders, obsessive-compulsive disorder, and panic disorder, as these terms are defined in the most recent edition of the diagnostic and statistical manual of mental disorders published by the American Psychiatric Association.
Substantial Completion Date means the date on which Substantial Completion occurs.
Substantial improvement means any combination of repairs, reconstruction, rehabilitation, addition, or other improvement of a structure, taking place during any one-year period for which the cost equals or exceeds 50 percent of the market value of the structure before the “start of construction” of the improvement. This term includes structures which have incurred “substantial damage”, regardless of the actual repair work performed. The term does not, however, include either:
Deadly weapon means any weapon, whether loaded or unloaded, from which a shot may be discharged, or a switchblade knife, gravity knife, billy, blackjack, bludgeon, or metal knuckles.
Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.
domestic premises means any premises used wholly or partly as a dwelling or intended for such use;
Ready for Occupancy means the date upon which (i) the Leased Premises are available for Tenant's occupancy in a broom clean condition and (ii) the improvements, if any, to be made to the Leased Premises by Landlord as a condition to Tenant's obligation to accept possession of the Leased Premises have been substantially completed and the appropriate governmental building department (i.e., the City building department, if the Property is located within a City, or otherwise the County building department) shall have approved the construction of such improvements as substantially complete or is willing to so approve the construction of the improvements as substantially complete subject only to compliance with specified conditions which are the responsibility of Tenant to satisfy or is willing to allow Tenant to occupy subject to its receiving assurances that specified work will be completed.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.
Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.
Disturbance Control Standard or “DCS” shall mean the reliability standard that sets the time limit following a disturbance within which a balancing authority must return its Area Control Error to within a specified range.
Substantial Taking means a Taking of at least 15% of the Land or Improvements which, in Lessee’s and Lessor’s reasonable judgment, will materially and adversely interfere with any development or use of the Premises that Lessee is then conducting or intends in good faith to conduct in the future.
Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.
Substantial evidence means evidence that:
Controlled dangerous substance means a drug, substance, or
Medically confirmed means the medical opinion of the attending physician has been confirmed by a consulting physician who has examined the patient and the patient's relevant medical records.
Sexually oriented business means an adult arcade, adult bookstore or adult video store, adult cabaret, adult motel, adult motion picture theater, adult theater, escort agency, nude model studio, or sexual encounter center.
Industrial Activity means activities subject to NPDES Industrial Permits as defined in 40 CFR, Section 122.26 (b)(14).
Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.
Substantially Equal means that the successful bid is within two percent (2%) of the next lowest responsible bid. However, the bids shall not be substantially equal where the two percent difference is equal to or greater than Ten Thousand Dollars ($10,000.00).
Sexually violent offense means an offense for which a conviction has been entered for any of the following indictable offenses: