Background Check means the process of checking an applicant’s arrest and conviction record, through any means.
Project Milestone means the project milestone set forth in Schedule-J;
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Data Subject Request means an actual or purported request or notice or complaint from or on behalf of a Data Subject exercising his rights under the Data Protection Laws in relation to Personal Data including without limitation: the right of access by the Data Subject, the right to rectification, the right to erasure, the right to restriction of processing, the right to data portability and the right to object;
Target Completion Date has the meaning given such term in Section 3.3(b).
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.