Train 4 Substantial Completion Date definition

Train 4 Substantial Completion Date means the date of substantial completion as set forth in an engineering, procurement and construction agreement for Train 4.
Sample 1Sample 2Sample 3
Train 4 Substantial Completion Date means the date of substantial completion as set forth in an engineering, procurement and construction agreement for Train
Sample 1

Examples of Train 4 Substantial Completion Date in a sentence

  • If Contractor does not achieve Substantial Completion of Train 4 by the Guaranteed Train 4 Substantial Completion Date (as may be adjusted by Change Order in accordance with this Agreement), Contractor shall pay liquidated damages (“Train 4 Delay Liquidated Damages”) to Owner in the amounts listed in Attachment E per Day for each Day, or portion thereof, of delay until Substantial Completion of Train 4 occurs.

Related to Train 4 Substantial Completion Date

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Final Completion Certificate has the meaning set forth in Section 11.6.

  • Subproject means a specific activity financed, or proposed to be financed through a FOSAP Grant under Part B.1 of the Project.

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);