Cost of the Work The sum of all allowable costs necessarily incurred and paid by Contractor in the proper performance of the Work.
Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
INDEPENDENT CAPACITY OF THE CONTRACTOR The parties intend that an independent contractor relationship will be created by this contract. The CONTRACTOR and his or her employees or agents performing under this contract are not employees or agents of the AGENCY. The CONTRACTOR will not hold himself/herself out as or claim to be an officer or employee of the AGENCY or of the State of Washington by reason hereof, nor will the CONTRACTOR make any claim of right, privilege or benefit that would accrue to such employee under law. Conduct and control of the work will be solely with the CONTRACTOR.
Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11:
(a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event;
(b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5;
(c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party.
(d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Maintenance obligations of the Contractor (i) The Contractor shall maintain the Project Highway for a period of 5 (five) years, corresponding to the Defects Liability Period, commencing from the date of the Completion Certificate (the “Maintenance Period”). For the performance of its Maintenance obligations, the Contractor shall be paid (if not included in the Schedule - H):
(a) For flexible pavement with 5 years Maintenance Period including structures: no maintenance charges shall be paid for the first year; 0.50%of the Contract Price each for the second, third and fourth year; and 1% of the Contract Price for the fifth year
(b) For rigid pavement with 10 years Maintenance Period including structures: 0.25% of the Contract Price each for the first, second and third year, 0.5% of the Contract Price each for fourth, fifth, sixth and seventh year, and 0.75% of the Contract Price each for eighth, ninth and tenth year.
(c) For flexible perpetual pavement with 10 years maintenance period including structures: no maintenance charges shall be paid for the first year; 0.5% of the Contract Price each for the second, third and fourth year; 0.75% of the Contract Price each for the subsequent years till laying of the renewal layer or end of maintenance period, whichever is earlier. The requirement for the renewal layer shall be worked out based on the survey and investigation of the existing pavement and the cost of such renewal works shall be made separately to the Contractor based on the principles defined under clause 13.2(iii). After laying of the renewal layer, the Contractor shall be paid @ 0.5% of the original Contract Price each for the remaining years till the end of maintenance period.
(d) For stand-alone Bridge/ Tunnel works: the contractor shall be paid @ 0.25% of the Contract Price each for the first five years and @ 0.50% of the Contract Price each for the remaining period of five years.
(e) For any other works: The contractor shall be paid at the rate of 0.50% of the contract price for the entire duration of maintenance period.
Admission of a Substitute or Additional General Partner A Person shall be admitted as a substitute or additional General Partner of the Partnership only if the following terms and conditions are satisfied:
(a) the Person to be admitted as a substitute or additional General Partner shall have accepted and agreed to be bound by all the terms and provisions of this Agreement by executing a counterpart thereof and such other documents or instruments as may be required or appropriate in order to effect the admission of such Person as a General Partner, and a certificate evidencing the admission of such Person as a General Partner shall have been filed for recordation and all other actions required by Section 2.5 hereof in connection with such admission shall have been performed;
(b) if the Person to be admitted as a substitute or additional General Partner is a corporation or a partnership it shall have provided the Partnership with evidence satisfactory to counsel for the Partnership of such Person’s authority to become a General Partner and to be bound by the terms and provisions of this Agreement; and
(c) counsel for the Partnership shall have rendered an opinion (relying on such opinions from other counsel and the state or any other jurisdiction as may be necessary) that the admission of the person to be admitted as a substitute or additional General Partner is in conformity with the Act, that none of the actions taken in connection with the admission of such Person as a substitute or additional General Partner will cause (i) the Partnership to be classified other than as a partnership for federal income tax purposes, or (ii) the loss of any Limited Partner’s limited liability.
Obligations of the Concessionaire 5.1.1 Subject to and on the terms and conditions of this Agreement, the Concessionaire shall, at its own cost and expense, procure finance for and undertake the design, engineering, procurement, construction, operation and maintenance of the Project and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
5.1.2 The Concessionaire shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
5.1.3 Subject to the provisions of Clauses 5.1.1 and 5.1.2, the Concessionaire shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
5.1.4 The Concessionaire shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement carry out the following but not be limited to:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits (other than those set forth in Clause 4.1.3), and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for materials, methods, processes and systems used or incorporated into the Project;
(c) perform and fulfil its obligations under the Financing Agreements;
(d) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed by it or its Contractors in connection with the performance of its obligations under this Agreement;
(e) make reasonable efforts to facilitate the acquisition of land required for the purposes of the Agreement;
(f) ensure and procure that its Contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Concessionaire's obligations under this Agreement;
(g) not do or omit to do any act, deed or thing which may in any manner be violative of any of the provisions of this Agreement;
(h) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(i) modify/demolish the existing structures on the Site at its own cost and consequences. The Concessionaire shall ensure that the demolition and construction of the existing structures is also in compliance with the prevailing building bye laws, zoning regulations as prescribed by H&UPD, GoUP, other appropriate authority or any regulatory authority (ASI, TTZ, NGT etc.). XXX policy of GoI and GoUP shall be admissible as and where applicable. The Concessionaire shall be responsible for safe and hassle-free disposal of the scrap from the Site;
(j) (deleted)
(k) transfer the Bus Terminal and the Commercial Complex to the Authority upon Termination of this Agreement, in accordance with the provisions thereof.
(l) develop a centralized covered Bus Terminal with adequate number of bus bays along with RCC yard area, passenger movement spaces, furniture fixtures, electrical fittings, utilities and other related requirements;
(m) {where Bus Terminal and workshops/ depots are adjoining, the development of workshops unit with necessary structural provisions and RCC yard, furniture fixtures, electrical fittings with minimum 6 meters of working/ maintenance shed height with no access from and/ to commercial areas as a mandatory requirement. However, Authority shall take separate electricity connection for the workshop area and shall pay for the electricity usage in it}1;
(n) construct and maintain public amenities like ablution units etc.;
(o) all the passenger amenities, Workshop facilities as well as UPSRTC staff facilities shall be maintained hygienic, neat and clean during the concession period;
(p) accesses either through staircases, overbridges or underpasses for movement of pedestrians from one platform to the other in a safe and fully secured manner;
(q) a dedicated office for UPSRTC staff with a sufficient usable area along with change rooms and toilets as per the specifications of UPSRTC shall be made available unconditionally and free of cost for the entire concession period on ground and first floors only of the Bus Terminal;
(r) all the facilities for plumbing, internal electrification and all the other allied works to render the office functional (partitions excluded);
(s) facility for parking adequate number of 4 wheelers, 3 Wheelers and 2 wheelers of passengers and commercial area users. The parking facility for Bus Terminal and for the Commercial Complex shall be segregated. (Refer prevailing Government of Housing and Urban Planning department circulars/ G.O’s); 1 This provision to be used only for Sites where workshops are adjoining the Bus Terminal
(t) all the other allied facilities for fire protection, accesses in the form of ramps, protective railings, ventilation system etc.;
(u) day to day operation and management of the Project as per this Agreement; and
(v) bear the expenses of electricity and water in the Bus Terminal during the Concession Period of Bus Terminal, except electricity and water charges for Authority’s office, workshop, drivers or staff dormitory and electric bus charging which shall be borne by the Authority.
Default – Reprocurement Costs In case of Contract breach by Contractor, resulting in termination by the County, the County may procure the goods and/or services from other sources. If the cost for those goods and/or services is higher than under the terms of the existing Contract, Contractor will be responsible for paying the County the difference between the Contract cost and the price paid, and the County may deduct this cost from any unpaid balance due the Contractor. The price paid by the County shall be the prevailing market price at the time such purchase is made. This is in addition to any other remedies available under this Contract and under law.
