Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.
Acceptance Procedure Lessor hereby authorizes one or more employees of the related Lessee, to be designated by such Lessee, as the authorized representative or representatives of Lessor to accept delivery on behalf of Lessor of that Leased Property identified on the applicable Funding Request. Each Lessee hereby agrees that such acceptance of delivery by such authorized representative or representatives and the execution and delivery by such Lessee on each Closing Date for property to be leased hereunder of a Lease Supplement in substantially the form of Exhibit A hereto (appropriately completed) shall, without further act, constitute the irrevocable acceptance by such Lessee of that Leased Property which is the subject thereof for all purposes of this Lease and the other Operative Documents on the terms set forth therein and herein, and that such Leased Property, together with, in the case of Land, any Building or other improvements thereon or to be constructed thereon pursuant to the Construction Agency Agreement, shall be deemed to be included in the leasehold estate of this Lease and shall be subject to the terms and conditions of this Lease as of such Closing Date. The demise and lease of each Building pursuant to this Section 2.2 shall include any additional right, title or interest in such Building which may at any time be acquired by Lessor, the intent being that all right, title and interest of Lessor in and to such Building shall at all times be demised and leased to the related Lessee hereunder.
Acceptance; Rejection A holder of Notes may accept the offer to prepay made pursuant to this Section 8.3 by causing a notice of such acceptance to be delivered to the Company not later than 15 days after receipt by such holder of the most recent offer of prepayment. A failure by a holder of Notes to respond to an offer to prepay made pursuant to this Section 8.3 shall be deemed to constitute a rejection of such offer by such holder.
Acceptance Criteria a) The operational ground check, the engine performance check and the acceptance flight contemplated in clause 2.2, 2.3 and 2.4 shall be conducted using Airbus’ ISATM.
Final Working Drawings After the Final Space Plan has been approved by Landlord, Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all EXHIBIT B applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of all of the Final Working Drawings, either (i) approve the Final Working Drawings, (ii) approve the Final Working Drawings subject to specified conditions, which conditions must be stated in a reasonably clear and complete manner, and shall only be conditions reasonably intended to address a potential Design Problem, or (iii) disapprove and return the Construction Drawings to Tenant with requested revisions; provided, however, Landlord shall only disapprove such Final Working Drawings to the extent of a Design Problem. If Landlord disapproves the Final Working Drawings, Tenant may resubmit the Final Working Drawings to Landlord at any time, and Landlord shall approve or disapprove the resubmitted Final Working Drawings, based upon the criteria set forth in this Section 3.3, within three (3) business days after Landlord receives such resubmitted Final Working Drawings. Such procedure shall be repeated until the Final Working Drawings are approved.
Acceptance and Rejection Jubilant shall be entitled to reject any shipment of Products that fails to conform to the Product Specifications or Packaging Specifications at the time of delivery to Jubilant. Jubilant shall notify Cadista of such rejection within thirty (30) days after delivery of such Products shipment to Jubilant, and shall set forth in such notification the basis under this Agreement for such rejection, including any testing or inspection results, provided, however, that in the event any such non-conformity is latent or was not obvious and could not be readily discovered from a physical inspection of the Products shipment, Jubilant may give written notice to Cadista of its rejection of such shipment within thirty (30) days after Jubilant's discovery of such non-conformance. Failure to so notify Cadista, or failure to identify the basis under this Agreement for rejection of any Product, shall constitute acceptance of such Product, except to the extent the Product fails to conform to the Product Specifications or Packaging Specifications as the case may be. After such failure to notify, Jubilant shall be obligated to make payment for such Product in accordance with pricing provisions of this Agreement. If the parties disagree as to whether any Product meets the Product Specifications or Packaging Specifications and the parties are unable to negotiate a commercially reasonable resolution, then samples and/or batch records, as appropriate, from the disputed shipment shall promptly be submitted for testing and evaluation to an independent Third Party as shall be agreed to in writing by both parties. The determination of such Third Party as to whether the disputed Product shipment meets the Product Specifications or Packaging Specifications shall be final and binding. The cost of the testing and evaluation by the independent third party shall be borne by the party whose position is found to be erroneous. If, pursuant to this Section 3.2, any Products are found not to conform to the Product Specifications or Packaging Specifications, as a result of a cause occurring prior to placement thereof with the carrier (and not arising as a result of the Materials being defective or failing to meet their respective specifications), at Cadista’s option, Jubilant shall either (i) deliver such non-conforming Products to Cadista or (ii) destroy such non-conforming Products in accordance with applicable laws, rules and regulations. Cadista shall reimburse Jubilant for all reasonable costs and expenses in connection such delivery or destruction, and, at Cadista’s option and as Jubilant’s exclusive remedy, Cadista shall either: (i) credit Jubilant for the amount paid or payable by Jubilant to Cadista for such rejected Product shipment (and reimburse Jubilant for the Material of such rejected batch at Jubilant’s cost for such Materials), or (ii) replace such rejected Product shipment (with Cadista paying Jubilant for all Materials or such replacement shipment in an amount equal to Jubilant’s cost), at no additional cost to Jubilant, as promptly as reasonably practicable, but in no event later than forty-five (45) days from receipt of notice of non-conformity of such shipment from Jubilant. Jubilant shall notify Cadista in writing of any claim relating to quantitative deficiencies in any shipment of Product that Jubilant considers to have been caused prior to shipment hereunder within thirty (30) days following receipt of any such shipment. Any claim for a quantitative deficiency which is not made within such thirty (30) days shall be deemed to have been waived by Jubilant and Jubilant shall be obligated to make payment for such Product in accordance with Section 5 of this Agreement. In the event Jubilant determines there is a quantitative deficiency from the applicable shipping documentation, the parties shall investigate such deficiency and, if the parties agree that such deficiency occurred prior to shipment, Cadista shall, at Jubilant’s option and as Jubilant’s exclusive remedy for such quantitative deficiency, (a) credit Jubilant for the amount paid by Jubilant to Cadista in excess of the aggregate price for actual quantities shipped; or (b) subject to Cadista having Product on hand at the time of request by Jubilant, rectify any such deficiency by promptly shipping the appropriate quantities of any relevant Product to Jubilant, but in no event later than fifteen (15) calendar days following the occurrence of such a deficiency, in which case Jubilant shall be obligated to pay for any such quantities pursuant to Section 5 of this Agreement.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
