Accounts and Management of Funds Sample Clauses

Accounts and Management of Funds. 7.1 In so far as applicable to the Commercial Managers’ Services, the Commercial Manager shall operate accounting systems satisfactory to the Shipowning Entity and provide regular services, reports and records in this regard and maintain records of all expenditure and cost together with information necessary and appropriate for the settlement of accounts between the parties hereto. 7.2 Notwithstanding any contrary provisions herein the Commercial Manager shall in no circumstances whatsoever be required to use or commit its own funds to finance the provision of the Management Services. 7.3 The Commercial Manager shall at all times maintain and keep true and correct accounts and shall make the same available for inspection and auditing by the Company at such times as may be mutually agreed. On the termination, for whatever reasons, of this Agreement, the Commercial Manager shall release to the Shipowning Entities, if so requested, the originals where possible, or otherwise certified copies, of all such accounts and all documents specifically relating to the Vessels and their commercial operation.
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
Accounts and Management of Funds. 10.1 Insofar as applicable to the Services, the Company shall operate accounting systems satisfactory to the Owner and provide regular services, reports and records in this regard and maintain records of all expenditure and cost together with information necessary and appropriate for the settlement of accounts between the parties hereto. 10.2 The Company shall at all times maintain and keep true and correct accounts and shall make the same available for inspection and auditing by the Owner. On the termination, for whatever reasons, of this Agreement, the Company shall release to the Owner, if so requested, the originals where possible, or otherwise certified copies, of all such accounts and all documents specifically relating to the Services.
Sample 1

Related to Accounts and Management of Funds

  • Accounts and Records The accounts and records maintained by ALPS shall be the property of the Fund. ALPS shall prepare, maintain and preserve such accounts and records as required by the 1940 Act and other applicable securities laws, rules and regulations. ALPS shall surrender such accounts and records to the Fund, in the form in which such accounts and records have been maintained or preserved, promptly upon receipt of instructions from the Fund. The Fund shall have access to such accounts and records at all times during ALPS’ normal business hours. Upon the reasonable request of the Fund, copies of any such books and records shall be provided by ALPS to the Fund at the Fund’s expense. ALPS shall assist the Fund, the Fund’s independent auditors, or, upon approval of the Fund, any regulatory body, in any requested review of the Fund’s accounts and records, and reports by ALPS or its independent accountants concerning its accounting system and internal auditing controls will be open to such entities for audit or inspection upon reasonable request. ALPS or its undersigned as defined by Rule 17a-4 of the Securities and Exchange Act (the “Exchange Act”), shall have access to all electronic communications, including password access to the system storing the electronic communications, of registered representatives of ALPS that are associated with the Fund and are required to be maintained under Rule 17a-4 of the Exchange Act and FINRA Rules 3110 and 3010. Electronic storage media maintained by the Fund will comply with Rule 17a-4 of the Exchange Act.

  • Maintenance of Accounts and Records Tenant shall keep true records and books of account of Tenant in which full, true and correct entries will be made of dealings and transactions in relation to the business and affairs of Tenant in accordance with GAAP. Tenant shall apply accounting principles in the preparation of the financial statements of Tenant which, in the judgment of and the opinion of its independent public accountants, are in accordance with GAAP, where applicable, except for changes approved by such independent public accountants. Tenant shall provide to Landlord either in a footnote to the financial statements delivered under Section 17.2 which relate to the period in which such change occurs, or in separate schedules to such financial statements, information sufficient to show the effect of any such changes on such financial statements.

  • Management Accounts The Management Accounts have been prepared in accordance with the same accounting principles and practices adopted for the Accounts and show a fair view of the assets and liabilities of the Company as the Management Accounts Date.

  • Investment Advisory and Management Services The Investment Adviser hereby appoints the Subadviser to serve as subadviser to the Fund and the Subadviser hereby accepts such appointment. Subject to the supervision of the Investment Adviser, Subadviser will regularly provide the Fund with investment advice and investment management services concerning the investments of the Fund. The Subadviser will determine what securities shall be purchased, held or sold by the Fund and what portion of the Funds assets shall be held uninvested in cash and cash equivalents, subject always to the provisions of the Trusts Declaration of Trust and By-laws and the 1940 Act, and to the investment objectives, policies and restrictions applicable to the Fund (including, without limitation, the requirements of Subchapters L and M of the Internal Revenue Code of 1986, as amended) (the Code), as each of the same shall be from time to time in effect or set forth in the Funds Prospectus and Statement of Additional Information, as well as any other investment guidelines or policies the Board of Trustees or the Investment Adviser may from time to time establish and deliver in writing to the Subadviser. To carry out such determinations the Subadviser will exercise full discretion, subject to the preceding paragraph, and act for the Fund in the same manner and with the same force and effect as the Trust might or could do with respect to purchases, sales or other transactions, as well as with respect to all other things necessary or incidental to the furtherance or conduct of such purchases, sales or other transactions. Notwithstanding the foregoing, the Subadviser shall, upon written instructions from the Investment Adviser, effect such portfolio transactions for the Fund as the Investment Adviser may from time to time direct. Such instructions will be given in reasonable circumstances, including, without limitation, any termination of this Agreement. The Subadviser will also make its officers and employees available to meet with the officers of the Investment Adviser and the Trusts officers and Trustees at least quarterly on due notice to review the investments and investment program of the Fund in the light of current and prospective economic and market conditions. From time to time as the Board of Trustees of the Trust or the Investment Adviser may reasonably request, the Subadviser will furnish to the Investment Adviser and Trusts officers and to each of its Trustees, at the Subadvisers expense, reports on portfolio transactions and reports on issues of securities held by the Fund, all in such detail as the Trust or the Investment Adviser may reasonably request. The Subadviser shall maintain all books and records required by Rule 31a-1 under the 1940 Act relating to its responsibilities provided hereunder with respect to the Fund, and shall preserve such records for the periods and in a manner prescribed by Rule 31a-2 under the 1940 Act. The Subadviser shall permit the Investment Adviser, the Funds officers and its independent public accountants to inspect and audit such records at reasonable times during normal business hours upon due notice. If any occasion should arise in which the Subadviser gives any advice to its clients concerning the shares of the Fund, the Subadviser will act solely as investment counsel for such clients and not in any way on behalf of the Fund. The Subadvisers services to the Fund pursuant to this Agreement are not to be deemed to be exclusive, and it is understood that the Subadviser may render investment advice, management and other services to others.

  • Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Cash Accounts, Deposits and Money Movements Subject to the terms and conditions set forth in this Section 7, the Fund hereby authorizes the Custodian to open and maintain, with itself or with Subcustodians, cash accounts in United States Dollars, in such other currencies as are the currencies of the countries in which the Fund maintains Investments or in such other currencies as the Fund shall from time to time request by Instruction.

  • Management Services Agreement The term "Management Services ----------------------------- Agreement" shall mean this Management Services Agreement by and between Practice and Business Manager and any amendments hereto.

  • ADMINISTRATION OF THE CONTRACT 2.2.1 The Architect will provide administration of the Contract as hereinafter described. 2.2.2 The Architect will be the State's representative during construction and until final payment is due. The Architect will advise and consult with the State. The State's instructions to the Contractor shall be forwarded through the Architect. The Architect will have authority to act on behalf of the State only to the extent provided in the Contract Documents, unless otherwise modified by written instrument in accordance with Subparagraph 2.2.10. 2.2.3 The Architect will visit the site at intervals appropriate to the stage of construction to familiarize himself or herself generally with the progress and quality of the Work and to determine in general if the Work is proceeding in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of his or her on-site observations as an architect, he or she will keep the State informed of the progress of the Work, and will endeavor to guard the State against defects and deficiencies in the Work of the Contractor. 2.2.4 The Architect will not be responsible for and will not have control or charge of construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and he or she will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. The Architect will not be responsible for or have control or charge over the acts or omissions of the Contractor, 2.2.5 The Architect shall at all times have access to the Work wherever it is in preparation and progress. The Contractor shall provide facilities for such access so the Architect may perform his or her functions under the Contract Documents.

  • Establishment of Collateral Accounts Securities Intermediary acknowledges and agrees that: (i) it has established and is maintaining on its books and records the accounts identified on the attached Schedule 1 (each such account, together with any replacements thereof or substitutions therefor, the “Collateral Account” and such accounts, collectively, the “Collateral Accounts”) in the name of the Borrower; (ii) each Collateral Account is a “securities account” (within the meaning of Section 8-501(a) of the UCC) in respect of which Securities Intermediary is a “securities intermediary” (within the meaning of Section 8-102(a)(14) of the UCC and, with respect to any Book-Entry Security, within the meaning of Federal Book-Entry Regulations) and the Security Agent is the “entitlement holder” (within the meaning of Section 8-102(a)(7) of the UCC); provided, however, that if, notwithstanding the intention of the parties hereto, all or any portion of the Collateral Account is determined to be a “deposit account” (within the meaning of Section 9-102 of the UCC) rather than a “securities account,” then the Securities Intermediary represents, warrants, covenants and agrees that it is a “bank” (as defined in Section 9-102(a)(8) of the UCC) and will treat the Borrower as its customer (within the meaning of Section 9-104(a)(3) of the UCC) with respect to the Collateral Accounts (or portion thereof); (iii) all property delivered, or to be delivered, to Securities Intermediary pursuant to this Agreement is, and will be, promptly credited to the Collateral Accounts; (iv) it does not know of any claim to or interest in any Collateral Account or any assets or funds therein, except for claims and interests of the parties to this Agreement as set forth herein; and (v) it shall not change the name or account number of any Collateral Account without the prior written consent of the Security Agent. Except as provided in Section 2(b), Securities Intermediary agrees that it shall not take “entitlement orders” (as defined in Section 8-102(a)(8) of the UCC) or “instructions” (within the meaning of Section 9-104(a)(2) of the UCC) with respect to the Collateral Accounts or any assets or funds therein from any Person other than the Security Agent.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!