Achievement of Practical Completion. The Participants must use their best endeavours to perform the Works to the stage of Practical Completion by the Date for Practical Completion.
Achievement of Practical Completion Sample Clauses
Related to Achievement of Practical Completion
Practical Completion (a) When the Developer considers that the Works, or any part of the Works, are complete, the Developer must send a Notice to the Council accompanied by complete works as executed plans, any relevant certificates or consents of any public utility authority and a request for written certification from the Council that the Works are complete.
PROGRESS AND COMPLETION 8.2.1 All time limits stated in the Contract Documents are material terms and time is the essence of the Contract. A failure by Contractor to do what is required by the time specified in the Contract Documents is a breach of the contract.
Project/Milestones Taxpayer develops and manufactures various products for use in the defense, aerospace and security industries. In consideration for the Credit, Taxpayer agrees to expand its operations at various locations throughout California, including El Segundo, Redondo Beach, Palmdale, Sunnyvale, Woodland Hills, Azusa and Rancho Xxxxxxxx. As part of its expansion, Taxpayer will invest in manufacturing equipment, computer and electrical equipment and make tenant improvements to the above facilities. Additionally, Taxpayer will hire full-time employees as part of its expansion (collectively, the “Project”). Further, Taxpayer agrees to satisfy the milestones as described in Exhibit “A” (“Milestones”) and must maintain Milestones for a minimum of three (3) taxable years thereafter. In the event Taxpayer employs more than the number of Full- time employees, determined on an annual full-time equivalent basis, than required in Exhibit A, for purposes of satisfying the “Minimum Annual Salary of California Full-time Employees Hired” and the “Cumulative Average Annual Salary of California Full-time Employees Hired,” Taxpayer may use the salaries of any of the Full-time employees hired and retained within the required time period. For purposes of calculating the “Minimum Annual Salary of California Full-time Employees Hired” and the “Cumulative Average Annual Salary of California Full-time Employees Hired,” the salary of any full-time employee that is not employed by the taxpayer for the entire taxable year shall be annualized. In addition, Xxxxxxxx agrees that any full-time employee hired after the effective date of this agreement that is a “qualified full-time employee” (as defined in RTC section 23636) shall be excluded from the calculation of the net increase of full-time employees required by this Agreement if Taxpayer claims the credit allowed by RTC section 23636.
Final Completion The full and final completion of all Work in accordance with the Contract Documents.
At Substantial Completion and Final Completion the Contractor shall provide a certification letter certifying that the Work does not contain asbestos as required by the UTUGCs.
Milestones Subject to the provisions of the SGIP, the Parties shall agree on milestones for which each Party is responsible and list them in Attachment 4 of this Agreement. A Party’s obligations under this provision may be extended by agreement. If a Party anticipates that it will be unable to meet a milestone for any reason other than a Force Majeure event, it shall immediately notify the other Parties of the reason(s) for not meeting the milestone and (1) propose the earliest reasonable alternate date by which it can attain this and future milestones, and (2) requesting appropriate amendments to Attachment 4. The Party affected by the failure to meet a milestone shall not unreasonably withhold agreement to such an amendment unless it will suffer significant uncompensated economic or operational harm from the delay, (1) attainment of the same milestone has previously been delayed, or (2) it has reason to believe that the delay in meeting the milestone is intentional or unwarranted notwithstanding the circumstances explained by the Party proposing the amendment.
STATEMENT OF PHILOSOPHY The University of Minnesota and the Union are committed to recognizing and acknowledging the healthy and positive diversity that we have on the University campuses. Further, the parties recognize that all employees have the right to work in a productive environment in which there is no verbal or physical intimidation, or discrimination or harassment based on the criteria provided in Section 1, Discrimination Prohibition, and Section 2, Sexual Harassment. It is in this spirit that the parties agree to the provisions of this Article. This statement shall not be grievable nor shall either party use this Section as evidence or argument in arbitration.
Substantial Completion “Substantial Completion” means the stage in the progress of the Work when the Work, or designated portions thereof, may still require minor modifications or adjustments but, in the Owner’s opinion, the Work has progressed to the point such that all parts of the Work under consideration are fully operational and usable for intended purposes, as evidenced by a Certificate of Substantial Completion approved by the Owner. If a Certificate of Occupancy is required by public authorities having jurisdiction over the Work, said certificate shall be issued before the Work or any portion thereof is considered substantially complete. When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Contractor shall notify Owner’s Designated Representative (sometimes referred to as the “ODR”) and request a determination as to whether the Work or designated portion thereof is substantially complete. If the ODR does not consider the Work substantially complete, the ODR will notify the Contractor giving reasons therefore. Failure on the Owner’s part to list a reason does not alter the responsibility of the Contractor to complete all Work in accordance with the terms of this Agreement. After satisfactorily completing items identified by Owner’s Designated Representative, the Contractor shall then submit another request for the ODR to determine Substantial Completion. If The ODR considers the Work substantially complete, The ODR will prepare and deliver a certificate of Substantial Completion which shall establish the date of Substantial Completion, shall include a punch list of items to be completed or corrected before final completion and final payment, shall establish the time within which the Contractor shall finish the punch list, and shall establish responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work, warranty and insurance. Failure to include an item on the punch list does not alter the responsibility of the Contractor to complete all Work in accordance with the terms and conditions of this Agreement. The certificate of Substantial Completion shall be signed by the Owner and the Contractor to evidence acceptance of the responsibilities assigned to them in such certificate. Substantial Completion (as defined in this agreement) for all stages of the Work shall be achieved on or before the following Substantial Completion date: DATE FOR SUBSTANTIAL COMPLETION: TBD Under no circumstances will the time for Substantial Completion exceed this date without a written amendment to this Agreement. THE TIMES SET FORTH IN THE CONSTRUCTION DOCUMENTS ARE AN ESSENTIAL ELEMENT OF THE AGREEMENT. TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE ESSENCE OF THIS AGREEMENT.
Development Milestones In addition to its obligations under Paragraph 7.1, LICENSEE specifically commits to achieving the following development milestones in its diligence activities under this AGREEMENT: (a) (b).
Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least thirty (30) days written notice to the SLDC and GUVNL, of the date on which it intends to synchronize the Power Project to the Grid System.
