Acknowledgement of Delays Sample Clauses

Acknowledgement of Delays. The parties acknowledge that delays may be caused by, or arise from, any number of events during the performance of the Work including, but not limited to, work performed, work deleted, Work Orders, valid Roadway and Bridge Improvements Scope Issues identified during the Scope Validation Period, Differing Tunnel Improvements Site Conditions, Delay Events, Compensation Events, supplemental agreements, force accounts, delays disruptions, differing site conditions, utility conflicts, design changes or defects, time extension, extra work, overruns, nearby or adjacent projects, right of way issues, permitting issues, actions of suppliers, subcontractors or other contractors, actions of third parties, actions of local residences and business owners, shop drawing approval, process delays, expansion of the physical limits of the Project, weather (other than floods in excess of the base flood, hurricane forces winds and tornados), weekends, holidays, suspension of contract time, extended or absorbed home office or job site overhead, lump sum maintenance of traffic adjustments, lost profits, prime xxxx-up impacts, conditions, circumstances, or potential damages on or pertaining to or as arising out of the Contract Documents, or other events, forces, or factors sometimes experienced in highway, bridge and tunnel construction work. Accordingly, Design-Builder acknowledges and agrees that it shall be solely responsible for all costs or impacts incurred by Design-Builder (not previously identified and covered by Work Order, overrun, or force account) if Design-Builder chooses to accept the No Excuses Incentive Payment.
Sample 1
AutoNDA by SimpleDocs

Related to Acknowledgement of Delays

  • ACKNOWLEDGEMENT AND CONFIRMATION Each party to this Amendment hereby confirms and agrees that, after giving effect to this Amendment and the amendments contemplated hereby, and except as expressly modified hereby, the Credit Agreement and the other Credit Documents to which it is a party remain in full force and effect and enforceable against such party in accordance with their respective terms and shall not be discharged, diminished, limited or otherwise affected in any respect.

  • Acknowledgement of Rights The Company acknowledges that, with respect to any Securities held by Firstar Capital Trust or a trustee of such trust, if the Property Trustee of such Trust fails to enforce its rights under this Indenture as the holder of the Securities held 71 81 as the assets of Firstar Capital Trust any holder of Capital Securities may institute legal proceedings directly against the Company to enforce such Property Trustee's rights under this Indenture without first instituting any legal proceedings against such Property Trustee or any other person or entity. Notwithstanding the foregoing, if an Event of Default has occurred and is continuing and such event is attributable to the failure of the Company to pay principal of or premium, if any, or interest on the Securities when due, the Company acknowledges that a holder of Capital Securities may directly institute a proceeding for enforcement of payment to such holder of the principal of or premium, if any, or interest on the Securities having a principal amount equal to the aggregate liquidation amount of the Capital Securities of such holder on or after the respective due date specified in the Securities.

  • ACKNOWLEDGEMENT OF ADDENDA The Bidder shall acknowledge receipt of any addenda issued to this solicitation by completing the blocks below or by completion of the applicable information on the addendum and returning it not later than the date and time for receipt of the bid. Failure to acknowledge an addendum that has a material impact on this solicitation may negatively impact the responsiveness of your bid. Material impacts include but are not limited to changes to specifications, scope of work/services, delivery time, performance period, quantities, bonds, letters of credit, insurance, or qualifications. Addendum No. , Date Addendum No. , Date Addendum No. , Date Addendum No. , Date The Bidder represents that the following principals are authorized to sign bids, negotiate and/or sign contracts and related documents to which the bidder will be duly bound. Principal is defined as an employee, officer or other technical or professional in a position capable of substantially influencing the development or outcome of an activity required to perform the covered transaction. Name Title Telephone Number/Email (Signature) (Date) (Title) (Name of Business) The Bidder shall complete and submit the following information with the bid: Partnership Non-Profit Joint Venture* Corporation Principal Place of Business (Florida Statute Chapter 607): City/County/State THE PRINCIPAL PLACE OF BUSINESS SHALL BE THE ADDRESS OF THE BIDDER’S PRINCIPAL OFFICE AS IDENTIFIED BY THE FLORIDA DIVISION OF CORPORATIONS. Federal I.D. number is: * Joint venture firms must complete and submit with their Bid Response the form titled “Information for Determining Joint Venture Eligibility”, and a copy of the formal agreement between all joint venture parties. This joint venture agreement must indicate the parties’ respective roles, responsibilities and levels of participation for the project. If proposing as a Joint Venture, the Joint Venture shall obtain and maintain all contractually required insurance in the name of the Joint Venture as required by the Contract. Individual insurance in the name of the parties to the Joint venture will not be accepted. Failure to timely submit the required form along with an attached written copy of the joint venture agreement may result in disqualification of your Bid Response List at least three (3) clients during the past ten (10) years for which you provided a comparable amount of goods or services substantially similar to those specified in the solicitation in the spaces provided below. Provide the Company name, contact person, address, email address, telephone number, and date services were performed, as described.

  • Acknowledgement of Risk (a) The Purchaser acknowledges and understands that its investment in the Securities involves a significant degree of risk, including, without limitation, (i) the Company remains a clinical stage business and requires substantial funds in addition to the proceeds from the sale of the Securities, (ii) an investment in the Company is speculative, and only Purchasers who can afford the loss of their entire investment should consider investing in the Company and the Securities, (iii) the Purchaser may not be able to liquidate its investment, (iv) transferability of the Securities is extremely limited, (v) in the event of a disposition of the Securities, the Purchaser could sustain the loss of its entire investment, and (vi) the Company has not paid any dividends on its Common Stock since inception and does not anticipate the payment of dividends in the foreseeable future. Such risks are more fully set forth in the SEC Documents; (b) The Purchaser is able to bear the economic risk of holding the Securities for an indefinite period, and has knowledge and experience in financial and business matters such that it is capable of evaluating the risks of the investment in the Securities; and (c) The Purchaser has, in connection with the Purchaser’s decision to purchase Securities, not relied upon any representations or other information (whether oral or written) other than as set forth in the representations and warranties of the Company contained herein and the information disclosed in the SEC Documents, and the Purchaser has, with respect to all matters relating to this Agreement and the offer and sale of the Securities, relied solely upon the advice of such Purchaser’s own counsel and has not relied upon or consulted any counsel to the Company.

  • ACKNOWLEDGEMENT AND CONSENT The Company is a party to the Company Collateral Documents, in each case as amended through the date hereof, pursuant to which the Company has created Liens in favor of the Agent on certain Collateral to secure the Obligations. The Parent Guarantor is a party to the Parent Collateral Documents, in each case as amended through the date hereof, pursuant to which the Parent Guarantor has created Liens in favor of the Agent on certain Collateral and pledged certain Collateral to the Agent to secure the Obligations of the Parent Guarantor. Certain Subsidiaries of the Company are parties to the Subsidiary Guaranty and/or one or more of the Subsidiary Collateral Documents, in each case as amended through the date hereof, pursuant to which such Subsidiaries have (i) guarantied the Obligations and/or (ii) created Liens in favor of the Agent on certain Collateral. The Company, the Parent Guarantor and such Subsidiaries are collectively referred to herein as the "Credit Support Parties", and the Company Collateral Documents, the Parent Collateral Documents, the Subsidiary Guaranty and the Subsidiary Collateral Documents are collectively referred to herein as the "Credit Support Documents". Each Credit Support Party hereby acknowledges that it has reviewed the terms and provisions of the Credit Agreement as amended by this Amendment and consents to the amendment of the Credit Agreement effected as of the date hereof pursuant to this Amendment. Each Credit Support Party acknowledges and agrees that any of the Credit Support Documents to which it is a party or otherwise bound shall continue in full force and effect. Each Credit Support Party hereby confirms that each Credit Support Document to which it is a party or otherwise bound and all Collateral encumbered thereby will continue to guaranty or secure, as the case may be, the payment and performance of all obligations guaranteed or secured thereby, as the case may be. Each Credit Support Party (other than the Company and the Parent Guarantor) acknowledges and agrees that (i) notwithstanding the conditions to effectiveness set forth in this Amendment, such Credit Support Party is not required by the terms of the Credit Agreement or any other Loan Document to consent to the amendments to the Credit Agreement effected pursuant to this Amendment and (ii) nothing in the Credit Agreement, this Amendment or any other Loan Document shall be deemed to require the consent of such Credit Support Party to any future amendments to the Credit Agreement.

  • Acknowledgement and Agreement By execution below, the Transferor expressly acknowledges and consents to the pledge of the 2024-1 SUBI Certificate and the 2024-1 SUBI and the assignment of all rights and obligations of the Transferor related thereto by the Transferee to the Indenture Trustee pursuant to the Indenture for the benefit of the Noteholders. In addition, the Transferor hereby acknowledges and agrees that for so long as the Notes are Outstanding, the Indenture Trustee will have the right to exercise all powers, privileges and claims of the Transferee under this Agreement.

  • ACKNOWLEDGEMENT OF RECEIPT I acknowledge that I have received the Dog into my possession.

  • Acknowledgement of Risks Client hereby acknowledges, that: (i) Digital Assets are not legal tender, are not backed by any government, and are not subject to protections afforded by the Federal Deposit Insurance Corporation or Securities Investor Protection Corporation; (ii) Legislative and regulatory changes or actions at the state, federal, or international level may adversely affect the use, transfer, exchange, and/or value of Digital Assets; (iii) transactions in Digital Assets are irreversible, and, accordingly, Digital Assets lost due to fraudulent or accidental transactions may not be recoverable; (iv) certain Digital Assets transactions will be deemed to be made when recorded on a public blockchain ledger, which is not necessarily the date or time that Client initiates the transaction or such transaction enters the pool; (v) the value of Digital Assets may be derived from the continued willingness of market participants to exchange any government issued currency (“Fiat Currency”) for Digital Assets, which may result in the permanent and total loss of value of a Digital Asset should the market for that Digital Asset disappear; (vi) the volatility of the value of Digital Assets relative to Fiat Currency may result in significant losses; (vii) Digital Assets may be susceptible to an increased risk of fraud or cyber-attack; (viii) the nature of Digital Assets means that any technological difficulties experienced by a Coinbase Entity may prevent the access or use of Client Digital Assets; and (ix) any bond or trust account maintained by Coinbase Entities for the benefit of its customers may not be sufficient to cover all losses (including Losses) incurred by customers.

  • Acknowledgement and Waiver 6.1 The Subscriber has acknowledged that the decision to purchase the Shares was solely made on the Company Information. The Subscriber hereby waives, to the fullest extent permitted by law, any rights of withdrawal, rescission or compensation for damages to which the Subscriber might be entitled in connection with the distribution of any of the Shares.

  • Acknowledgement 5. Staff and the Respondent agree with the facts set out in Part IV herein for the purposes of this Settlement Agreement only and further agree that this agreement of facts is without prejudice to the Respondent or Staff in any other proceeding of any kind including, but without limiting the generality of the foregoing, any proceedings brought by the MFDA (subject to Part IX) or any civil or other proceedings which may be brought by any other person or agency, whether or not this Settlement Agreement is accepted by the Hearing Panel.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!