Equipment Failures In the event of equipment failures beyond the Administrator's control, the Administrator shall take reasonable and prompt steps to minimize service interruptions but shall have no liability with respect thereto. The Administrator shall develop and maintain a plan for recovery from equipment failures which may include contractual arrangements with appropriate parties making reasonable provision for emergency use of electronic data processing equipment to the extent appropriate equipment is available.
Potential Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no amounts payable under this Agreement shall be paid to the Participant prior to the expiration of the 6-month period following his “separation from service” (within the meaning of Treasury Regulation Section 1.409A-1(h)) (a “Separation from Service”) to the extent that the Company determines that paying such amounts prior to the expiration of such 6-month period would result in a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first business day following the end of the applicable 6-month period (or such earlier date upon which such amounts can be paid under Section 409A of the Code without resulting in a prohibited distribution, including as a result of the Participant’s death), such amounts shall be paid to the Participant.
Lenders’ Failure to Perform All Advances (other than Swing Loans and Agent Advances) shall be made by the Lenders contemporaneously and in accordance with their Pro Rata Shares. It is understood that (i) no Lender shall be responsible for any failure by any other Lender to perform its obligation to make any Advance (or other extension of credit) hereunder, nor shall any Commitment of any Lender be increased or decreased as a result of any failure by any other Lender to perform its obligations hereunder, and (ii) no failure by any Lender to perform its obligations hereunder shall excuse any other Lender from its obligations hereunder.
COST OF THE WORK (1) The term “
Epidemic Failure In the event that CONTRACTUAL PRODUCTS under warranty have the same or similar functional defect during a time period of three (3) months and the number of defected CONTRACTUAL PRODUCTS exceed [***] of the quantity delivered within this time period, this [***] = CERTAIN INFORMATION ON THIS PAGE HAS BEEN OMITTED AND FILED SEPARATELY WITH THE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THE OMITTED PORTIONS. shall be an “Epidemic Failure” as mentioned in the following. The term “Epidemic Failure” shall exclusively apply to delivered CONTRACTUAL PRODUCTS with a number of pieces of more than ten thousand (>10.000) during three (3) months. If either CONTRACTUAL PARTY learns of the existence or likely existence of an Epidemic Failure, then such CONTRACTUAL PARTY will inform the other CONTRACTUAL PARTY as soon as possible. The CONTRACTUAL PARTIES shall then work together to jointly devise a containment action plan. As soon thereafter as reasonably possible, the CONTRACTUAL PARTIES will develop a corrective action plan to remedy the Epidemic Failure. Phoenix Contact shall use its best efforts to implement such remedy as quickly as possible at Phoenix Contact’s own expense, which efforts shall include receiving all shipments of affected Product back (freight collect), repairing or replacing all such affected Products in accordance with the agreed remedy devised by the Parties, shipping the repaired or replaced Products back to ENPHASE at Phoenix Contact’s expense, and implementing the agreed remedy in all newly manufactured Products. Phoenix Contact shall be responsible for the reasonable following costs and expenses actually incurred and substantiated as a result of all aspects of implementing the agreed remedy on the affected Products: reasonable costs of the retrieval, packing, shipping and transportation of such Products, and the re-deployment of repaired or replacement Products (including all labor, consulting, contractor and the like charges, incurred by ENPHASE, only if Phoenix Contact has agreed in writing that ENPHASE is allowed to do the aforementioned activities). For the avoidance of doubt all damages defined in Article 11.4 shall be direct damages and shall be subject to Article 14.2.
HAZARDOUS SUBSTANCE CONDITIONS If a Hazardous Substance Condition occurs, unless Lessee is legally responsible therefor (in which case Lessee shall make the investigation and remediation thereof required by Applicable Requirements and this Lease shall continue in full force and effect, but subject to Lessor's rights under Paragraph 6.2(c) and Paragraph 13), Lessor may at Lessor's option either (i) investigate and remediate such Hazardous Substance Condition, if required, as soon as reasonably possible at Lessor's expense, in which event this Lease shall continue in full force and effect, or (ii) if the estimated cost to investigate and remediate such condition exceeds twelve (12) times the then monthly Base Rent or $100,000 whichever is greater, give written notice to Lessee within thirty (30) days after receipt by Lessor of knowledge of the occurrence of such Hazardous Substance Condition of Lessor's desire to terminate this Lease as of the date sixty (60) days following the date of such notice. In the event Lessor elects to give such notice of Lessor's intention to terminate this Lease, Lessee shall have the right within ten (10) days after the receipt of such notice to give written notice to Lessor of Lessee's commitment to pay for the excess costs of (a) investigation and remediation of such Hazardous Substance Condition to the extent required by Applicable Requirements, over (b) an amount equal to twelve (12) times the then monthly Base Rent or $100,000, whichever is greater. Lessee shall provide Lessor with the funds required of Lessee or satisfactory assurance thereof within thirty (30) days following said commitment by Lessee. In such event this Lease shall continue in full force and effect, and Lessor shall proceed to make such investigation and remediation as soon as reasonably possible after the required funds are available. If Lessee does not give such notice and provide the required funds or assurance thereof within the time period specified above, this Lease shall terminate as of the date specified in Lessor's notice of termination.
Cost of Metering The Issuer shall not be obligated to pay any costs associated with the routine metering duties set forth in this Section 2, including the costs of installing, replacing and maintaining meters, nor shall the Issuer be entitled to any credit against the Servicing Fee for any cost savings realized by the Servicer as a result of new metering and/or billing technologies.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Performance; No Event of Default The Borrower shall have performed and complied in all respects with all terms and conditions herein required to be performed or complied with by it prior to or at the time hereof, and there shall exist no Default or Event of Default.
