Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.
Termination Compensation Termination Compensation equal to two (2) times the Executive's Base Period Income shall be paid to the Executive in a single sum payment in cash on the thirtieth (30th) business day after the later of (a) the Control Change Date and (b) the date of the Executive's employment termination; provided that if at the time of the Executive's termination of employment the Executive is a Specified Employee, then payment of the Termination Compensation to the Executive shall be made on the first day of the seventh (7th) month following the Executive's employment termination.
Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -
Compensation for Overtime 9.5.1 All overtime hours, except those overtime hours exceeding twelve (12) hours in one day, shall be compensated at a rate of pay equal to time and one-half the regular rate of pay of the employee. Those overtime hours exceeding twelve (12) in one day shall be compensated at a rate of pay equal to two times the regular pay of the employee.
Consideration for Performance The consideration to be paid to the Contractor under this Agreement will be compensation for all the Contractor’s expenses incurred in the performance of this Agreement, unless otherwise expressly provided.
Termination for Non-Performance Should a party to this Agreement fail to materially perform in accordance with the terms and conditions of this Agreement, this Agreement may be terminated by the performing party if the performing party first provides written notice to the non-performing party which notice shall specify the non-performance, provide both a demand to cure the non-performance and reasonable time to cure the non-performance, and state a date upon which the Agreement shall be terminated if there is a failure to timely cure the non- performance. For purpose of this Section 4.4, “reasonable time” shall be not less than five (5) business days. In the event of a failure to timely cure a non- performance and upon the date of the resulting termination for non-performance, the Contractor shall prepare a final accounting and final invoice of charges for all performed but unpaid Services and authorized reimbursable expenses. Such final accounting and final invoice shall be delivered to the Town within fifteen (15) days of the date of termination; thereafter, no other invoice, xxxx, or other form of statement of charges owing to the Contractor shall be submitted to or accepted by the Town. Provided that notice of non-performance is provided in accordance with this Section 4.4, nothing in this Section 4.4 shall prevent, preclude, or limit any claim or action for default or breach of contract resulting from non-performance by a Party.
Compensation for Employees Employees shall receive compensation at the biweekly or hourly rate for the range and step or flat rate assigned to the class in which they are employed.
Special Compensation The Company shall pay to the Executive a lump sum equal to three times the sum of (a) the highest per annum base rate of salary in effect with respect to the Executive during the three-year period immediately prior to the termination of employment plus (b) the Highest Bonus Amount. Such lump sum shall be paid by the Company to the Executive within ten business days after the Executive's termination of employment, unless the provisions of Section 3(e) below apply. The amount of the aggregate lump sum provided by this Section 3(c), whether paid immediately or deferred, shall not be counted as compensation for purposes of any other benefit plan or program applicable to the Executive.
Developer Compensation for Emergency Services If, during an Emergency State, the Developer provides services at the request or direction of the NYISO or Connecting Transmission Owner, the Developer will be compensated for such services in accordance with the NYISO Services Tariff.
Supplemental Compensation Pursuant to Section 7 of the Agreement, Supplemental Compensation will be paid as follows:
