Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.
TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
Indemnity by the Company The Company hereby agrees to indemnify and hold harmless Consultant and each person and affiliate associated with Consultant against any and all losses, claims, damages, liabilities and expenses (including reasonable costs of investigation and legal counsel fees), and in addition to any liability the Company may otherwise have, arising out of, related to or based upon any violation of law, rule or regulation by the Company or the Company’s agents, employees, representatives or affiliates.
Information to Be Provided by the Company In connection with any Securitization Transaction, the Company shall use its best efforts to (i) within five (5) Business Days, but in no event later than ten (10) Business Days, following written request by the Purchaser or any Depositor, provide to the Purchaser and such Depositor (or, as applicable, cause each Third-Party Originator to provide), in writing and in form and substance reasonably satisfactory to the Purchaser and such Depositor, the information and materials specified in paragraphs (a), (b), (c) and (f) of this Section, and (ii) as promptly as practicable following notice to or discovery by the Company, provide to the Purchaser and any Depositor (in writing and in form and substance reasonably satisfactory to the Purchaser and such Depositor) the information specified in paragraph (d) of this Section.
(a) If so requested in writing by the Purchaser or any Depositor, the Company shall provide such information regarding (i) the Company, as originator of the Mortgage Loans (including as an acquirer of Mortgage Loans from a Qualified Correspondent), or (ii) each Third-Party Originator, as is requested for the purpose of compliance with Items 1103(a)(l), 1105, 1110, 1117 and 1119 of Regulation AB. Such information shall include, at a minimum:
(A) the originator’s form of organization;
(B) a description of the originator’s origination program and how long the originator has been engaged in originating residential mortgage loans, which description shall include a discussion of the originator’s experience in originating mortgage loans of a similar type as the Mortgage Loans; information regarding the size and composition of the originator’s origination portfolio; and information that may be material, in the good faith judgment of the Purchaser or any Depositor, to an analysis of the performance of the Mortgage Loans, including the originators’ credit-granting or underwriting criteria for mortgage loans of similar type(s) as the Mortgage Loans and such other information as the Purchaser or any Depositor may reasonably request for the purpose of compliance with Item 1110(b)(2) of Regulation AB;
(C) a description of any legal or governmental proceedings pending (or known to be contemplated) against the Company and each Third-Party Originator that would be material to securityholders; and
(D) a description of any affiliation or relationship between the Company, each Third-Party Originator and any of the following parties to a Securitization Transaction, as such parties are identified to the Company by the Purchaser or any Depositor in writing in advance of such Securitization Transaction:
(1) the sponsor;
(2) the depositor;
(3) the issuing entity;
(4) any servicer;
(5) any trustee;
(6) any originator;
(7) any significant obligor;
(8) any enhancement or support provider; and
(9) any other material transaction party.
(b) If so requested in writing by the Purchaser or any Depositor, the Company shall provide (or, as applicable, cause each Third-Party Originator to provide) Static Pool Information solely with respect to securitized pools of mortgage loans (of a similar type as the Mortgage Loans, as reasonably identified by the Purchaser as provided below) that were included in securitizations that closed during the five (5) years preceding the closing date of the related Securitization Transaction. Such Static Pool Information shall be prepared by the Company (or Third-Party Originator) on the basis of its reasonable, good faith interpretation of the requirements of Item 1105(a)(3) of Regulation AB. To the extent that there is reasonably available to the Company (or Third-Party Originator) Static Pool Information with respect to more than one mortgage loan type, the Purchaser or any Depositor shall be entitled to specify whether some or all of such information shall be provided pursuant to this paragraph. The content of such Static Pool Information may be in the form customarily provided by the Company, and need not be customized for the Purchaser or any Depositor. Such Static Pool Information for each prior securitized pool shall be presented in increments no less frequently than quarterly over the life of the mortgage loans included in such prior securitized pool. The most recent periodic increment must be as of a date no later than 135 days prior to the date of the prospectus or other offering document in which the Static Pool Information is to be included or incorporated by reference. The Static Pool Information shall be provided in an electronic format that provides a permanent record of the information provided, such as a portable document format (pdf) file, or other such electronic format reasonably required by the Purchaser or the Depositor, as applicable. Promptly following notice or discovery of a material error in Static Pool Information provided pursuant to the immediately preceding paragraph (including an omission to include therein information required to be provided pursuant to such paragraph) during the applicable offering period for the securities, the Company shall provide corrected Static Pool Information to the Purchaser or any Depositor, as applicable, in the same format in which Static Pool Information was previously provided to such party by the Company. If so requested in writing by the Purchaser or any Depositor, the Company shall provide (or, as applicable, cause each Third-Party Originator to provide), at the expense of the requesting party (to the extent of any additional incremental expense associated with delivery pursuant to this Regulation AB Addendum), such statements and agreed-upon procedures letters of certified public accountants reasonably acceptable to the Purchaser or Depositor, as applicable, pertaining to Static Pool Information relating to securitizations closed on or after January 1, 2006, as the Purchaser or such Depositor shall reasonably request. Such statements and letters shall be addressed to and be for the benefit of such parties as the Purchaser or such Depositor shall designate, which may include, by way of example, any Sponsor, any Depositor and any broker dealer acting as underwriter, placement agent or initial purchaser with respect to a Securitization Transaction. Any such statement or letter may take the form of a standard, generally applicable document accompanied by a reliance letter authorizing reliance by the addressees designated by the Purchaser or such Depositor.
(c) For the purpose of satisfying its reporting obligation under the Exchange Act with respect to any class of asset-backed securities, for so long as the Depositor is required to file reports under the Exchange Act with respect to a Securitization Transaction, the Company shall (or shall cause each Third-Party Originator to) (i) provide prompt notice to the Purchaser, any Master Servicer and any Depositor in writing of (A) any litigation or governmental proceedings pending against the Company or any Third-Party Originator that would be material to securityholders and (B) any affiliations or relationships that develop following the closing date of a Securitization Transaction between the Company or any Third-Party Originator and any of the parties specified in clause (D) of paragraph (a) of this Section (and any other parties identified in writing by the requesting party) with respect to such Securitization Transaction, but only to the extent that such affiliations or relationships do not include the Purchaser, Depositor or any of their respective affiliates as a party, (C) any Event of Default of which it is aware or has received notice under the terms of the Agreement or any Reconstitution Agreement and (D) any merger or consolidation where the Company is not the surviving entity or sale of substantially all of the assets of the Company and (ii) provide to the Purchaser and any Depositor a description of such proceedings, affiliations or relationships.
Indemnification by the Custodian The Custodian agrees to indemnify the Issuer, the Owner Trustee, the Trust Collateral Agent and the Trustee for any and all liabilities, obligations, losses, damage, payments, costs or expenses of any kind whatsoever (including the fees and expenses of counsel) that may be imposed on, incurred or asserted against the Issuer, the Owner Trustee, the Trust Collateral Agent and the Trustee and their respective officers, directors, employees, agents, attorneys and successors and assigns as the result of any act or omission in any way relating to the maintenance and custody by the Custodian of the Receivable Files; provided, however, that the Custodian shall not be liable for any portion of any such liabilities, obligations, losses, damages, payments or costs or expenses due to the Issuer’s, the Owner Trustee’s, the Trust Collateral Agent’s or the Trustee’s or the officers’, directors’, employees’ and agents’ thereof own willful misfeasance, bad faith or gross negligence. In no event shall the Custodian be liable to any third party for acts or omissions of the Custodian.
Cooperation by the Indemnified Party The Indemnified Party shall reasonably cooperate with and assist the Indemnifying Party in determining the validity of any claim for indemnity by the Indemnified Party and in defending against a Third-Party Claim. In connection with any fact, matter, event or circumstance that may give rise to a claim against any Indemnifying Party under this Agreement, the Indemnified Party shall ensure that each relevant member of the Indemnified Party’s Group: (i) shall preserve all material evidence relevant to the claim to the extent within the control of the Indemnified Party’s Group, (ii) shall allow the Indemnifying Party to investigate the fact, matter, event or circumstance alleged to give rise to such claim and whether and to what extent any amount is payable in respect of such claim, and (iii) shall (at the Indemnified Party’s expense) disclose to the Indemnifying Party all material of which it is aware which relates to the claim and provide, and procure that any other relevant members of the Indemnified Party’s Group shall provide (at the Indemnified Party’s expense), all such information and assistance, including reasonable access to premises and personnel, and the right to examine and copy or photograph any assets, accounts, documents and records, as the Indemnifying Party may reasonably request, subject to the Indemnifying Party agreeing in such form as the Indemnified Party may reasonably require to keep all such information confidential and to use it only for the purpose of investigating and defending the claim in question; provided that the foregoing shall not require the Indemnified Party to disclose any documents or information that may be reasonably expected to result in a violation of applicable Law or the loss or waiver of any attorney-client, work product or similar legal privilege; provided further that the Indemnified Party and the Indemnifying Party shall work in good faith to put in place appropriate substitute disclosure arrangements to permit such disclosure without such violation, loss or waiver.
Additional Indemnification by the Servicer The Servicer shall indemnify the Master Servicer, the Depositor, the Trustee, the Securities Administrator, the Trust Fund and the NIMS Insurer and hold them harmless against any and all claims, losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and any other costs, fees and expenses (collectively, the “Liabilities”) that the indemnified party may sustain in any way related to the failure of the Servicer to perform its duties and service the Mortgage Loans in accordance with the terms of this Agreement (including but not limited to its obligation to provide the certification pursuant to Section 5.05(b) hereunder) or for any inaccurate or misleading information provided in the certification required pursuant to Section 5.05(b). The Servicer shall immediately notify the Master Servicer, the Depositor, the Trustee, the Securities Administrator or the NIMS Insurer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans that may result in such Liabilities, and the Servicer shall assume (with the prior written consent of the indemnified party) the defense of any such claim and pay all expenses in connection therewith, including counsel fees, promptly pay, discharge and satisfy any judgment or decree which may be entered against it or any indemnified party in respect of such claim and follow any written instructions received from the such indemnified party in connection with such claim. The Servicer shall be reimbursed promptly from the Trust Fund for all amounts advanced by it pursuant to the preceding sentence except when the claim is in any way related to the Servicer’s indemnification pursuant to Section 6.02, or the failure of the Servicer to service and administer the Mortgage Loans in accordance with the terms of this Agreement. In the event a dispute arises between the Servicer and an indemnified party with respect to any of the rights and obligations of the parties pursuant to this Agreement, and such dispute is adjudicated in a court of law, by an arbitration panel or any other judicial process, then the losing party (if the Trustee, the Trust Fund) shall indemnify and reimburse the winning party for all attorney’s fees and other costs and expenses related to the adjudication of said dispute.
Notification by the Indemnified Party If any Indemnified Party becomes aware of any fact, matter or circumstance that has given or may reasonably be expected to give rise to a claim for indemnification under this Article 8, the Indemnified Party shall at its own expense promptly (and in no event later than ten (10) Business Days after the applicable Indemnified Party becoming so aware) notify the Indemnifying Party in writing of any claim in respect of which indemnity may be sought under this Article 8 (including any pending or threatened claim or demand by a third party (including any Tax Authority)), that the applicable Indemnified Party has determined has given or could reasonably give rise to a right of indemnification under this Agreement (including a pending or threatened claim or demand asserted by a third party against the Indemnified Party, whether by litigation, by arbitration, as a result of an investigation, or otherwise (each, a “Third-Party Claim”)), setting out the provisions under this Agreement on which such claim is based, and such other information as is reasonably necessary to enable the Indemnifying Party to assess the merits of the potential claim, to act to preserve evidence and to make such provision as it may consider necessary (including details of the legal and factual basis of the claim and the evidence on which the party relies (including where the claim is the result of a Third-Party Claim, evidence of the Third-Party Claim) and, to the extent reasonably ascertainable, setting out its estimate of the amount of Losses which are, or are to be, the subject of the claim) and the Indemnified Party shall keep the Indemnifying Party reasonably and promptly informed of any developments (including additional information which may become available to it) in respect of such facts, matters or circumstances; provided, however, that any failure or delay in providing such notice shall not release the Indemnifying Party from any of its obligations under this Article 8 except to the extent the Indemnifying Party is prejudiced by such failure or delay.
For the Contractor Name: Xxxxx Xxxx Phone: 000-000-0000 Email: xxxxx@xxxxxxxxxxxxxxx.xxx
Additional Indemnification by the Servicer; Third Party Claims The Servicer shall indemnify the Seller, the Depositor, the Trustee and the Master Servicer (and each of their respective directors, officers, employees and agents) and the Trust Fund, and hold them harmless against any and all Costs that any such indemnified party may sustain in any way related to (i) the failure of the Servicer to perform its duties and service the Mortgage Loans in material compliance with the terms of this Agreement (including, but not limited to its obligation to provide the certification pursuant to Section 5.03(b) hereunder) or for any inaccurate or misleading information provided in the certification required pursuant to Section 5.03(b) or (ii) the failure of the Servicer to cause any event to occur or not to occur which would have occurred or would not have occurred, as applicable, if the Servicer were applying Accepted Servicing Practices under this Agreement. The Servicer shall immediately notify the Seller, the Depositor, the Master Servicer, the Trustee or any other relevant party if a claim is made by a third party with respect to this Agreement or the Mortgage Loans, assume (with the prior written consent of the indemnified party in the event of an indemnified claim) the defense of any such claim and pay all expenses in connection therewith, including counsel fees, promptly pay, discharge and satisfy any judgment or decree which may be entered against it or any other party in respect of such claim and follow any written instructions received from such indemnifying party in connection with such claim. Subject to the Servicer’s indemnification pursuant to Section 6.02, or the failure of the Servicer to service and administer the Mortgage Loans in material compliance with the terms of this Agreement, the Trust Fund shall indemnify the Servicer and hold the Servicer harmless against any and all Costs that the Servicer may sustain in connection with any legal action relating to this Agreement, the Certificates or the origination or Servicing of the Mortgage Loans by any prior owner or servicer, other than any Costs incurred by reason of the Servicer’s willful misfeasance, bad faith or negligence in the performance of duties hereunder or by reason of its reckless disregard of obligations and duties hereunder.
