Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
EDD Independent Subrecipient Reporting Requirements Effective January 1, 2001, the County of Orange is required to file in accordance with subdivision (a) of Section 6041A of the Internal Revenue Code for services received from a “service provider” to whom the County pays $600 or more or with whom the County enters into a contract for $600 or more within a single calendar year. The purpose of this reporting requirement is to increase child support collection by helping to locate parents who are delinquent in their child support obligations. The term “service provider” is defined in California Unemployment Insurance Code Section 1088.8, Subparagraph B.2 as “an individual who is not an employee of the service recipient for California purposes and who received compensation or executes a contract for services performed for that service recipient within or without the State.” The term is further defined by the California Employment Development Department to refer specifically to independent Subrecipients. An independent Subrecipient is defined as “an individual who is not an employee of the ... government entity for California purposes and who receives compensation or executes a contract for services performed for that ... government entity either in or outside of California.” The reporting requirement does not apply to corporations, general partnerships, limited liability partnerships, and limited liability companies. Additional information on this reporting requirement can be found at the California Employment Development Department web site located at xxxx://xxx.xxx.xx.xxx/Employer_Services.htm
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Requirements Pertaining Only to Federal Grants and Subrecipient Agreements If this Agreement is a grant that is funded in whole or in part by Federal funds:
SERVICE REQUIREMENTS FOR REFERRED CLIENTS A. Agent agrees to respond to any communications from a Referred Client within two (2) hours after receipt if such communication is received between 9:00am to 5:00pm local time. For communications received outside of these hours, Agent agrees to respond by 10:00am the next day.
B. Agent agrees to update XXXX.xxx with status updates within 48 hours after initial communication with a Referred Client and upon every significant status change until closing or abandoned. Updates shall be made by Agent via email to xxxxxxxxxxxx@xxxx.xxx.
C. Vacations or extended absences shall be reported, with length of pause, to XXXX.xxx via email to
D. Agent will not add Referred Client to any email list or calling list without the express permission of Referred Client.
E. Agent agrees XXXX.xxx has the right to survey the Referred Client at any time.
F. If Agent is contacted by a Referred Client that Agent is unwilling or unable to assist, Agent shall direct such Referred Client back to XXXX.xxx for assistance and notify XXXX.xxx at xxxxxxxxxxxx@xxxx.xxx.
G. Agent agrees that XXXX.xxx has no obligation to provide Agent with any number of referrals and that prospective clients are free to select the agent they wish to work with for any particular real estate transaction.
CERTIFICATION REGARDING DRUG-FREE WORKPLACE REQUIREMENTS 1. The Contractor certifies that it will provide a drug-free workplace by:
a. Publishing a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Contractor’s workplace and specifying the actions that will be taken against employees for violation of such prohibition;
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
OBLIGATIONS AND ACTIVITIES OF CONTRACTOR AS BUSINESS ASSOCIATE 1. CONTRACTOR agrees not to use or further disclose PHI COUNTY discloses to CONTRACTOR other than as permitted or required by this Business Associate Contract or as required by law.
2. XXXXXXXXXX agrees to use appropriate safeguards, as provided for in this Business Associate Contract and the Agreement, to prevent use or disclosure of PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY other than as provided for by this Business Associate Contract.
3. XXXXXXXXXX agrees to comply with the HIPAA Security Rule at Subpart C of 45 CFR Part 164 with respect to electronic PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY.
4. CONTRACTOR agrees to mitigate, to the extent practicable, any harmful effect that is known to CONTRACTOR of a Use or Disclosure of PHI by CONTRACTOR in violation of the requirements of this Business Associate Contract.
5. XXXXXXXXXX agrees to report to COUNTY immediately any Use or Disclosure of PHI not provided for by this Business Associate Contract of which CONTRACTOR becomes aware. CONTRACTOR must report Breaches of Unsecured PHI in accordance with Paragraph E below and as required by 45 CFR § 164.410.
6. CONTRACTOR agrees to ensure that any Subcontractors that create, receive, maintain, or transmit PHI on behalf of CONTRACTOR agree to the same restrictions and conditions that apply through this Business Associate Contract to CONTRACTOR with respect to such information.
7. CONTRACTOR agrees to provide access, within fifteen (15) calendar days of receipt of a written request by COUNTY, to PHI in a Designated Record Set, to COUNTY or, as directed by COUNTY, to an Individual in order to meet the requirements under 45 CFR § 164.524. If CONTRACTOR maintains an Electronic Health Record with PHI, and an individual requests a copy of such information in an electronic format, CONTRACTOR shall provide such information in an electronic format.
8. CONTRACTOR agrees to make any amendment(s) to PHI in a Designated Record Set that COUNTY directs or agrees to pursuant to 45 CFR § 164.526 at the request of COUNTY or an Individual, within thirty (30) calendar days of receipt of said request by COUNTY. XXXXXXXXXX agrees to notify COUNTY in writing no later than ten (10) calendar days after said amendment is completed.
9. CONTRACTOR agrees to make internal practices, books, and records, including policies and procedures, relating to the use and disclosure of PHI received from, or created or received by CONTRACTOR on behalf of, COUNTY available to COUNTY and the Secretary in a time and manner as determined by COUNTY or as designated by the Secretary for purposes of the Secretary determining COUNTY’S compliance with the HIPAA Privacy Rule.
10. CONTRACTOR agrees to document any Disclosures of PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY, and to make information related to such Disclosures available as would be required for COUNTY to respond to a request by an Individual for an accounting of Disclosures of PHI in accordance with 45 CFR § 164.528.
11. CONTRACTOR agrees to provide COUNTY or an Individual, as directed by COUNTY, in a time and manner to be determined by COUNTY, that information collected in accordance with the Agreement, in order to permit COUNTY to respond to a request by an Individual for an accounting of Disclosures of PHI in accordance with 45 CFR § 164.528.
12. XXXXXXXXXX agrees that to the extent CONTRACTOR carries out COUNTY’s obligation under the HIPAA Privacy and/or Security rules CONTRACTOR will comply with the requirements of 45 CFR Part 164 that apply to COUNTY in the performance of such obligation.
13. If CONTRACTOR receives Social Security data from COUNTY provided to COUNTY by a state agency, upon request by COUNTY, CONTRACTOR shall provide COUNTY with a list of all employees, subcontractors and agents who have access to the Social Security data, including employees, agents, subcontractors and agents of its subcontractors.
14. CONTRACTOR will notify COUNTY if CONTRACTOR is named as a defendant in a criminal proceeding for a violation of HIPAA. COUNTY may terminate the Agreement, if CONTRACTOR is found guilty of a criminal violation in connection with HIPAA. COUNTY may terminate the Agreement, if a finding or stipulation that CONTRACTOR has violated any standard or requirement of the privacy or security provisions of HIPAA, or other security or privacy laws are made in any administrative or civil proceeding in which CONTRACTOR is a party or has been joined. COUNTY will consider the nature and seriousness of the violation in deciding whether or not to terminate the Agreement.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
