Administrative Stream Workload Management. The parties will examine the viability of applying the outcomes of the Operational Workload Management Kit to administrative stream employees.
Administrative Stream Workload Management Sample Clauses
Related to Administrative Stream Workload Management
Workload Management 11.1 The parties to this Agreement acknowledge that employees and management have a responsibility to maintain a balanced workload and recognise the adverse affects that excessive workloads may have on employee/s and the quality of resident/client care. 11.2 To ensure that employee concerns involving excessive workloads are effectively dealt with by Management the following procedures should be applied: (a) Step 1: In the first instance, employee/s should discuss the issue with their immediate supervisor and, where appropriate, explore solutions. (b) Step 2: If a solution cannot be identified and implemented, the matter should be referred to an appropriate senior manager for further discussion. (c) Step 3: If a solution still cannot be identified and implemented, the matter should be referred to the Facility Manager for further discussion. (d) Step 4: The outcome of the discussions at each level and any proposed solutions should be recorded in writing and fed back to the effected employees. 11.3 Workload management must be an agenda item at staff meetings on at least a quarterly basis. Items in relation to workloads must be recorded in the minutes of the staff meeting, as well as actions to be taken to resolve the workloads issue/s. Resolution of workload issues should be based on the following criteria including but not limited to: (a) Clinical assessment of residents’ needs; (b) The demand of the environment such as facility layout; (c) Statutory obligation, (including, but not limited to, work health and safety legislation); (d) The requirements of nurse regulatory legislation; (e) Reasonable workloads (such as roster arrangements); (f) Accreditation standards; and (g) Budgetary considerations. 11.4 If the issue is still unresolved, the employee/s may advance the matter through Clause 9 Dispute Resolution Procedure. Arbitration of workload management issues may only occur by agreement of the employer and the employee representative, which may include the union/s.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Project Management Plan Developer is responsible for all quality assurance and quality control activities necessary to manage the Work, including the Utility Adjustment Work. Developer shall undertake all aspects of quality assurance and quality control for the Project and Work in accordance with the approved Project Management Plan and
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:
Patch Management All workstations, laptops and other systems that process and/or 20 store PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or 21 transmits on behalf of COUNTY must have critical security patches applied, with system reboot if 22 necessary. There must be a documented patch management process which determines installation 23 timeframe based on risk assessment and vendor recommendations. At a maximum, all applicable 24 patches must be installed within thirty (30) calendar or business days of vendor release. Applications 25 and systems that cannot be patched due to operational reasons must have compensatory controls 26 implemented to minimize risk, where possible.
Project Management and Coordination The Engineer shall coordinate all subconsultant activity to include quality of and consistency of work and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.
Administrative Services Agreement The Administrative Services Agreement has been duly authorized, executed and delivered by the Company and is a valid and binding agreement of the Company, enforceable against the Company in accordance with its terms except as the enforceability thereof may be limited by bankruptcy, insolvency, or similar laws affecting creditors’ rights generally from time to time in effect and by equitable principles of general applicability.
Administrative Services In addition to the portfolio management services specified above in section 2, you shall furnish at your expense for the use of the Fund such office space and facilities in the United States as the Fund may require for its reasonable needs, and you (or one or more of your affiliates designated by you) shall render to the Trust administrative services on behalf of the Fund necessary for operating as an open end investment company and not provided by persons not parties to this Agreement including, but not limited to, preparing reports to and meeting materials for the Trust's Board of Trustees and reports and notices to Fund shareholders; supervising, negotiating contractual arrangements with, to the extent appropriate, and monitoring the performance of, accounting agents, custodians, depositories, transfer agents and pricing agents, accountants, attorneys, printers, underwriters, brokers and dealers, insurers and other persons in any capacity deemed to be necessary or desirable to Fund operations; preparing and making filings with the Securities and Exchange Commission (the "SEC") and other regulatory and self-regulatory organizations, including, but not limited to, preliminary and definitive proxy materials, post-effective amendments to the Registration Statement, semi-annual reports on Form N-SAR and notices pursuant to Rule 24f-2 under the 1940 Act; overseeing the tabulation of proxies by the Fund's transfer agent; assisting in the preparation and filing of the Fund's federal, state and local tax returns; preparing and filing the Fund's federal excise tax return pursuant to Section 4982 of the Code; providing assistance with investor and public relations matters; monitoring the valuation of portfolio securities and the calculation of net asset value; monitoring the registration of Shares of the Fund under applicable federal and state securities laws; maintaining or causing to be maintained for the Fund all books, records and reports and any other information required under the 1940 Act, to the extent that such books, records and reports and other information are not maintained by the Fund's custodian or other agents of the Fund; assisting in establishing the accounting policies of the Fund; assisting in the resolution of accounting issues that may arise with respect to the Fund's operations and consulting with the Fund's independent accountants, legal counsel and the Fund's other agents as necessary in connection therewith; establishing and monitoring the Fund's operating expense budgets; reviewing the Fund's bills; processing the payment of bills that have been approved by an authorized person; assisting the Fund in determining the amount of dividends and distributions available to be paid by the Fund to its shareholders, preparing and arranging for the printing of dividend notices to shareholders, and providing the transfer and dividend paying agent, the custodian, and the accounting agent with such information as is required for such parties to effect the payment of dividends and distributions; and otherwise assisting the Trust as it may reasonably request in the conduct of the Fund's business, subject to the direction and control of the Trust's Board of Trustees. Nothing in this Agreement shall be deemed to shift to you or to diminish the obligations of any agent of the Fund or any other person not a party to this Agreement which is obligated to provide services to the Fund.
