RELOCATION OF TENANT Upon prior written notice to Tenant, Landlord shall have the right to relocate Tenant to new space (the “Relocation Space”) within the Project that is comparable in size, utility, and condition to the Premises, including similar Tenant Improvements. Such relocation will be effective on a date specified by Landlord in its relocation notice, which date will not be less than ninety (90) days after the date of such notice. If Landlord relocates Tenant, Landlord will reimburse Tenant for Tenant’s reasonable out-of-pocket expenses for moving Tenant’s furniture, equipment, and supplies from the Premises to the Relocation Space, and other reasonable relocation costs. Tenant shall be entitled to concurrently occupy both the Premises and Relocation Space for a period not to exceed twenty (20) days in order to effectuate its relocation in a minimally non-disruptive manner. Upon such relocation, the Relocation Space will be deemed to be the Premises and the terms of this Lease will remain in full force and effect and apply to the Relocation Space. No amendment or other instrument shall be necessary to effectuate the relocation contemplated by this Section; however, if requested by Landlord, Tenant shall execute and deliver to Landlord an appropriate amendment document within twenty (20) days after Landlord’s request therefor. If Tenant fails to execute and deliver such relocation amendment within such time period, or if Tenant fails to relocate within the time period stated in Landlord’s relocation notice to Tenant (or, if the Relocation Space is not available on the date specified in Landlord’s relocation notice, as soon thereafter as the Relocation Space becomes available and is tendered to Tenant in the condition required by this Lease), then, in addition to Landlord’s other remedies set forth in this Lease, at law and/or in equity, Landlord may terminate this Lease by notifying Tenant in writing thereof at least sixty (60) days prior to the termination date contained in Landlord’s termination notice. Landlord’s exercise of its rights as permitted by this Section shall not (a) constitute a constructive eviction, an interference with Tenant’s right of quiet enjoyment, or a disturbance of Tenant’s right to use the Premises; and (b) subject Landlord to damages, including, but not limited to, damages for loss of goodwill, business, or profits. Time is of the essence with respect to Tenant’s obligations under this Section.
End of tenancy 4.6.1 Return possession of the Property at the end of the tenancy in the same good clean state and condition as it was in at the beginning of the tenancy and make good, pay for the repair of, or replace all such items of the fixtures, fittings, furniture and effects as shall be broken, lost, damaged or destroyed during the tenancy (reasonable wear and tear and damage for which the Landlord has agreed to insure excepted).
4.6.2 Return all keys to the Property to the Landlord’s Agent by 12 noon on the last day of the tenancy (or sooner by mutual arrangement).
4.6.3 Pay for the washing (including ironing or pressing) of all the linen and the cleaning (including ironing and pressing where appropriate) of all blankets, bedding, carpets and curtains which have been soiled during the tenancy (reasonable use thereof nevertheless excepted) or arrange the washing and cleaning themselves all at their own expense.
4.6.4 Leave the oven in the same state of cleanliness as it is listed in the inventory.
4.6.5 Leave the fixtures fittings, furniture and effects at the end of the tenancy in the rooms and places in which they were at the beginning of the tenancy.
4.6.6 Remove all rubbish from the Property, except one dustbin or black refuse sack’s worth which may be left in the appropriate place for collection, before returning the Property to the Landlord.
4.6.7 Pay the reasonable costs, reasonably incurred and which cannot be mitigated, if the Tenant fails to keep the appointment to check the inventory at the end of the tenancy and another has to be scheduled.
4.6.8 The Landlord is not liable to compensate the Tenant for any works the Tenant has carried out to the Property, whether carried out with or without the Landlord’s consent, unless the consent to do the works specifically included an agreement to compensate the Tenant.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Franchisee A “franchisee” is a retailer or distributor who is authorized or permitted, under a franchise, to use a trademark in connection with the sale, consignment, or distribution of motor fuel.
No Release of Tenant No transfer permitted by this Article Nine, whether with or without Landlord's consent, shall release Tenant or change Tenant's primary liability to pay the rent and to perform all other obligations of Tenant under this Lease. Landlord's acceptance of rent from any other person is not a waiver of any provision of this Article Nine. Consent to one transfer is not a consent to any subsequent transfer. If Tenant's transferee defaults under this Lease, Landlord may proceed directly against Tenant without pursuing remedies against the transferee. Landlord may consent to subsequent assignments or modifications of this Lease by Tenant's transferee, without notifying Tenant or obtaining its consent. Such action shall not relieve Tenant's liability under this Lease.
Termination of Tenancy Any termination of the lease must also comply with all applicable state or local laws, ordinances, regulations, or similar requirements, including as may be applicable emergency orders restricting evictions during declared emergencies or disasters; and Owner/Representative Initials: Tenant Initials:
Developer Developer shall construct and complete, in a good and workmanlike manner, the Work for the Guaranteed Maximum Price including any adjustment(s) to the Guaranteed Maximum Price pursuant to provisions herein regarding changes to the Guaranteed Maximum Price. Except as otherwise noted, Developer shall provide and pay for all labor, materials, equipment, permits (excluding DSA), fees, licenses, facilities, transportation, taxes, bonds and insurance, and services necessary for the proper execution and completion of the Work, except as indicated herein.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
