Allocation of Funds to Project by Authority Sample Clauses

Allocation of Funds to Project by Authority. Authority and Developer acknowledge and agree that Authority has been appropriated the sum of up to Four Million Eight Hundred Thousand Dollars ($4,800,000) to be allocated and disbursed as Authority reasonably determines necessary in order to prepare the Plan, plan for implementation of the Plan, and to carry out the Plan contemplated by this Revitalization Agreement and all implementing agreements hereto (“Authority Appropriation”). Authority and Developer agree that the Authority Appropriation shall be expended in accordance with the Budget. Notwithstanding, the actual allocation of the Authority Appropriation as it relates to the implementation of the Project shall be determined pursuant to one or more financing plans prepared by Developer and approved by Authority for each Phase (each, a “Phase Allocation”). If, at any time, Authority reasonably determines that the costs incurred, or likely to be incurred, by Authority to implement the Plan cumulatively for the multiple Phases of the Project will exceed the Authority Appropriation, then Authority may, by notice to Developer, terminate all of this Revitalization Agreement expressly excepting (a) Article 12 that shall survive such termination, and (b) any Interim Agreement, Phase Affordable Housing Agreement, and Phase Implementation Agreement into which Developer and Authority have theretofore entered. Notwithstanding any such termination by Authority, Authority shall be obligated to pay for any amounts incurred prior to such termination which are consistent with the Budget.
AutoNDA by SimpleDocs

Related to Allocation of Funds to Project by Authority

  • Authorization and Application of Overtime An employee who is required to work overtime shall be entitled to overtime compensation when the overtime worked is authorized in advance.

  • Authorization of Receipt of Funds by the Trustee Under the Collateral Documents Subject to the provisions of the Intercreditor Agreements, the Trustee is authorized to receive any funds for the benefit of the Holders distributed under the Collateral Documents, and to make further distributions of such funds to the Holders according to the provisions of this Indenture.

  • Authorization of Receipt of Funds by the Trustee Under the Security Documents Subject to the provisions of the Intercreditor Agreement, the Trustee is authorized to receive any funds for the benefit of the Holders distributed under the Security Documents, and to make further distributions of such funds to the Holders according to the provisions of this Indenture.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Maintenance of Fund's Assets Abroad The Fund, acting through its Board or its duly authorized representative, hereby instructs the Delegate pursuant to the terms of the Custodian Agreement dated as of the date hereof executed by and between the Fund and the Delegate (the Custodian Agreement) to place and maintain the Fund's Assets in countries outside the United States in accordance with Instructions received from the Fund’s Investment Advisor. Such instruction shall constitute an Instruction under the terms of the Custodian Agreement. The Fund acknowledges that (a) the Delegate shall perform services hereunder only with respect to the countries where it accepts delegation as Foreign Custody Manager as indicated on the Delegate’s Global Custody Network Listing; (b) depending on conditions in the particular country, advance notice may be required before the Delegate shall be able to perform its duties hereunder in or with respect to such country (such advance notice to be reasonable in light of the specific facts and circumstances attendant to performance of duties in such country); and (c) nothing in this Delegation Schedule shall require the Delegate to provide delegated or custodial services in any country, and there may from time to time be countries as to which the Delegate determines it will not provide delegation services.

  • CERTIFICATION REGARDING USE OF CONTRACT FUNDS FOR LOBBYING This provision is applicable to all Federal-aid construction contracts and to all related subcontracts which exceed $100,000 (49 CFR 20). 1. The prospective participant certifies, by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that: a. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement. b. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions. 2. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by 31 U.S.C. 1352. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. 3. The prospective participant also agrees by submitting its bid or proposal that the participant shall require that the language of this certification be included in all lower tier subcontracts, which exceed $100,000 and that all such recipients shall certify and disclose accordingly. This provision is applicable to all Federal-aid projects funded under the Appalachian Regional Development Act of 1965. 1. During the performance of this contract, the contractor undertaking to do work which is, or reasonably may be, done as on-site work, shall give preference to qualified persons who regularly reside in the labor area as designated by the DOL wherein the contract work is situated, or the subregion, or the Appalachian counties of the State wherein the contract work is situated, except: a. To the extent that qualified persons regularly residing in the area are not available. b. For the reasonable needs of the contractor to employ supervisory or specially experienced personnel necessary to assure an efficient execution of the contract work. c. For the obligation of the contractor to offer employment to present or former employees as the result of a lawful collective bargaining contract, provided that the number of nonresident persons employed under this subparagraph (1c) shall not exceed 20 percent of the total number of employees employed by the contractor on the contract work, except as provided in subparagraph (4) below. 2. The contractor shall place a job order with the State Employment Service indicating (a) the classifications of the laborers, mechanics and other employees required to perform the contract work, (b) the number of employees required in each classification, (c) the date on which the participant estimates such employees will be required, and (d) any other pertinent information required by the State Employment Service to complete the job order form. The job order may be placed with the State Employment Service in writing or by telephone. If during the course of the contract work, the information submitted by the contractor in the original job order is substantially modified, the participant shall promptly notify the State Employment Service. 3. The contractor shall give full consideration to all qualified job applicants referred to him by the State Employment Service. The contractor is not required to grant employment to any job applicants who, in his opinion, are not qualified to perform the classification of work required. 4. If, within one week following the placing of a job order by the contractor with the State Employment Service, the State Employment Service is unable to refer any qualified job applicants to the contractor, or less than the number requested, the State Employment Service will forward a certificate to the contractor indicating the unavailability of applicants. Such certificate shall be made a part of the contractor's permanent project records. Upon receipt of this certificate, the contractor may employ persons who do not normally reside in the labor area to fill positions covered by the certificate, notwithstanding the provisions of subparagraph (1c) above. 5. The provisions of 23 CFR 633.207(e) allow the contracting agency to provide a contractual preference for the use of mineral resource materials native to the Appalachian region. 6. The contractor shall include the provisions of Sections 1 through 4 of this Attachment A in every subcontract for work which is, or reasonably may be, done as on-site work.

  • Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.

  • Authorization of Overtime All overtime work must be authorized by the employee's immediate Manager.

  • Application of Funds in the Collection Account The Master Servicer may, from time to time, make, or cause to be made, withdrawals from the Collection Account for the following purposes: (i) to reimburse itself or any Servicer for Advances made by it or by such Servicer pursuant to Section 5.04 or the applicable Servicing Agreement; provided, however, that the Master Servicer’s right to reimburse itself pursuant to this subclause is limited to amounts received on or in respect of particular Mortgage Loans (including, for this purpose, Liquidation Proceeds and amounts representing Insurance Proceeds with respect to the property subject to the related Mortgage) which represent late recoveries (net of the applicable Servicing Fee and the Master Servicing Fee) of payments of principal or interest respecting which any such Advance was made; provided, further, that following the final liquidation of a Mortgage Loan, the Master Servicer may reimburse itself for previously unreimbursed Advances in excess of Liquidation Proceeds or Insurance Proceeds with respect to such Mortgage Loans from any funds in the Collection Account, it being understood, in the case of any such reimbursement, that the Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders; (ii) to reimburse itself or any Servicer for any Servicing Advances made by it or by such Servicer that it or such Servicer determines in good faith will not be recoverable from amounts representing late recoveries of payments of principal or interest respecting the particular Mortgage Loan as to which such Servicing Advance was made or from Liquidation Proceeds or Insurance Proceeds with respect to such Mortgage Loan, it being understood, in the case of any such reimbursement, that such Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders; (iii) to reimburse itself or any Servicer from Liquidation Proceeds for Liquidation Expenses and for amounts expended by it pursuant to Sections 9.20 and 9.22(a) or the applicable Servicing Agreement in good faith in connection with the restoration of damaged property and, to the extent that Liquidation Proceeds after such reimbursement exceed the unpaid principal balance of the related Mortgage Loan, together with accrued and unpaid interest thereon at the applicable Mortgage Rate less the applicable Servicing Fee and the Master Servicing Fee for such Mortgage Loan to the Due Date next succeeding the date of its receipt of such Liquidation Proceeds, to pay to itself out of such excess the amount of any unpaid assumption fees, late payment charges or other Mortgagor charges on the related Mortgage Loan and to retain any excess remaining thereafter as additional servicing compensation, it being understood, in the case of any such reimbursement or payment, that such Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders; (iv) to reimburse itself or any Servicer for expenses incurred by and recoverable by or reimbursable to it or such Servicer pursuant to Section 9.04, 9.05, 9.06, 9.16 or 9.22(a) or pursuant to the applicable Servicing Agreement, and to reimburse itself for any expenses reimbursable to it pursuant to Section 10.01(c); (v) to pay to the applicable Person, with respect to each Mortgage Loan or REO Property acquired in respect thereof that has been repurchased by such Person pursuant to this Agreement, all amounts received thereon and not distributed on the date on which the related repurchase was effected; (vi) subject to Section 5.05, to pay to itself income earned on the investment of funds deposited in the Collection Account; (vii) to make payments to the Trustee for deposit into the Certificate Account in the amounts and in the manner provided for in Section 4.01(c); (viii) to make distributions of any Retained Interest to the Retained Interest Holder on each Distribution Date (other than any Retained Interest not deposited into the Collection Account in accordance with Section 4.01(d)(iii)); (ix) to make payment to itself, the Trustee and others pursuant to any provision of this Agreement; (x) to withdraw funds deposited in error in the Collection Account; (xi) to clear and terminate the Collection Account pursuant to Section 7.02; (xii) to reimburse a successor Master Servicer (solely in its capacity as successor Master Servicer), for any fee or advance occasioned by a termination of the Master Servicer, and the assumption of such duties by the Trustee or a successor Master Servicer appointed by the Trustee pursuant to Section 6.14, in each case to the extent not reimbursed by the terminated Master Servicer, it being understood, in the case of any such reimbursement or payment, that the right of the Master Servicer or the Trustee thereto shall be prior to the rights of the Certificateholders; and (xiii) to reimburse any Servicer for such amounts as are due thereto under the applicable Servicing Agreement and have not been retained by or paid to such Servicer to the extent provided in such Servicing Agreement. If provided in the related Servicing Agreement, each Servicer shall be entitled to retain as additional servicing compensation any Prepayment Interest Excess (to the extent not offset by Prepayment Interest Shortfalls). In the event that the Master Servicer fails on any Deposit Date to remit to the Trustee any amounts required to be so remitted to the Trustee pursuant to subclause (vii) by 12 noon (New York time) on such date, the Master Servicer shall pay the Trustee, for the account of the Trustee, interest calculated at the “prime rate” (as published in the “Money Rates” section of The Wall Street Journal) on such amounts not timely remitted for the period from and including that Deposit Date to but not including the related Distribution Date. In connection with withdrawals pursuant to subclauses (i), (iii), (iv) and (vi) above, the Master Servicer’s or Servicer’s entitlement thereto is limited to collections or other recoveries on the related Mortgage Loan, except as provided herein. The Master Servicer shall therefore keep and maintain a separate accounting for each Mortgage Loan it master services for the purpose of justifying any withdrawal from the Collection Account it maintains pursuant to subclauses (i), (iii), (iv) and (vi) above.

  • Authorization of the Indenture The Indenture has been duly authorized by the Company and duly qualified under the 1939 Act and, when duly executed and delivered by the Company and the Trustee, will constitute a valid and binding agreement of the Company, enforceable against the Company in accordance with its terms, except as the enforcement thereof may be limited by bankruptcy, insolvency (including, without limitation, all laws relating to fraudulent transfers), reorganization, moratorium or similar laws affecting enforcement of creditors’ rights generally and except as enforcement thereof is subject to general principles of equity (regardless of whether enforcement is considered in a proceeding in equity or at law).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!