RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
Project Specific Milestones In addition to the milestones stated in Section 212.5 of the Tariff, as applicable, during the term of this ISA, Interconnection Customer shall ensure that it meets each of the following development milestones:
6.1 Substantial Site work completed. On or before December 31, 2020 Interconnection Customer must demonstrate completion of at least 20% of project site construction. At this time, Interconnection Customer must submit to Interconnected Transmission Owner and Transmission Provider initial drawings, certified by a professional engineer, of the Customer Interconnection Facilities.
6.2 Delivery of major electrical equipment. On or before December 31, 2021, Interconnection Customer must demonstrate that all generating units have been delivered to Interconnection Customer’s project site.
Product Specific Terms these terms apply to specific Products referenced in this section.
MSAA Indicator Technical Specification Document This Agreement shall be interpreted with reference to the MSAA Indicator Technical Specifications document.
Product Specifications (a) Supplier shall manufacture all Products according to the Specifications in effect as of the date of this Agreement, with such changes or additions to the Specifications of the Products related thereto as shall be requested by Buyer in accordance with this Section or as otherwise agreed in writing by the Parties. All other Products shall be manufactured with such Specifications as the Parties shall agree in writing.
(b) Buyer may request changed or additional Specifications for any Product by delivering written notice thereof to Supplier not less than one hundred twenty (120) days in advance of the first Firm Order for such Product to be supplied with such changed or additional Specifications. Notwithstanding the foregoing, if additional advance time would reasonably be required in order to implement the manufacturing processes for production of a Product with any changed or additional Specifications, and to commence manufacture and delivery thereof, Supplier shall so notify Buyer, and Supplier shall not be required to commence delivery of such Product until the passage of such additional time.
(c) Supplier shall be required to accommodate any change of, or additions to, the Specifications for any Product, if and only if (i) in Supplier’s good faith judgment, such changed or additional Specifications would not require Supplier to violate good manufacturing practice, (ii) the representation and warranty of Buyer deemed made pursuant to Subsection (e) below is true and correct, and (iii) Buyer agrees to reimburse Supplier for the incremental costs and expenses incurred by Supplier in accommodating the changed or additional Specifications, including the costs of acquiring any new machinery and tooling. For the avoidance of doubt, such costs and expenses shall be payable by Buyer separately from the cost of Products at such time or times as Supplier shall request.
(d) Supplier shall notify Buyer in writing within thirty (30) days of its receipt of any request for changed or additional Specifications (i) whether Supplier will honor such changed or additional Specifications, (ii) if Supplier declines to honor such changed or additional Specifications, the basis therefor and (iii) if applicable, the estimated costs and expenses that Buyer will be required to reimburse Supplier in respect of the requested changes or additions, as provided in Subsection (c) above. Buyer shall notify Supplier in writing within fifteen (15) days after receiving notice of any required reimbursement whether Buyer agrees to assume such reimbursement obligation.
(e) By its request for any changed or additional Specifications for any Product, Buyer shall be deemed to represent and warrant to Supplier that the manufacture and sale of the Product incorporating Buyer’s changed or additional Specifications, as a result of such incorporation, will not and could not reasonably be expected to (i) violate or conflict with any contract, agreement, arrangement or understanding to which Buyer and/or any of its Affiliates is a party, including this Agreement and any other contract, agreement, arrangement or understanding with Supplier and/or its Affiliates, (ii) infringe on any trademark, service xxxx, copyright, patent, trade secret or other intellectual property rights of any Person, or (iii) violate any Applicable Law. Buyer shall indemnify and hold Supplier and its Affiliates harmless (including with respect to reasonable attorneys’ fees and disbursements) from any breach of this representation and warranty.
Quality Specifications SANMINA-SCI shall comply with the quality specifications set forth in its Quality Manual, incorporated by reference herein, a copy of which is available from SANMINA-SCI upon request.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Preceptor A per diem Registered Nurse 2 may serve as a preceptor after successfully completing a preceptor workshop or equivalent documented training and agreeing to and being appointed to be specifically responsible for planning, organizing, and evaluating the new skill development of one or more RNs as appropriate enrolled in a defined orientation program, the parameters of which have been set forth in writing by the Employer. This includes teaching, clinical supervision, role modeling, feedback, evaluation (verbal and written) and follow up of the new or transferring employee. The per diem RN 2 preceptor is eligible to receive preceptor premium pay when actually engaged in preceptor role responsibilities with/on behalf of the orienting RN. A per diem RN 2 substituting for the original preceptor during a period of absence and who has been designated to carry out the preceptor's complete responsibility (including following and/or adjusting the plan to meet learning needs and providing oral and written evaluation input) will receive preceptor pay. A preceptor may be assigned to a student when it is determined by the Employer that the employee has completed the required preceptor training or has agreed to and been appointed a preceptor. The employee is specifically responsible for planning, organizing, and evaluating the new skill development of the student as appropriately enrolled in a defined program, the parameters of which have been set forth in writing by the Employer. This includes teaching, clinical supervision, role modeling, feedback, evaluation (verbal and written) and follow up of the student.
Product Testing No later than [**] prior to a scheduled Delivery ARIAD US shall send to ARIAD SWISSCO the Delivery Documents for review. Following such review, unless within [**] of receipt of the Delivery Documents ARIAD SWISSCO gives written notice of rejection of the Product to be delivered, stating the reasons for such rejection, the Delivery shall proceed, and both Parties shall organize the same. Upon arrival at ARIAD SWISSCO nominated site it shall visually inspect the shipment of the Product to identify any damage to the external packaging. ARIAD SWISSCO may reject any shipment (or portion thereof) of the Product that is damaged by providing to ARIAD US reasonable evidence of damage within [**] after Delivery of such Product. If ARIAD SWISSCO does not so reject any shipment (or portion thereof) of the Product within [**] of Delivery of such Product, ARIAD SWISSCO shall be deemed to have accepted such shipment of the Product; provided, however, that in the case of the Product having any Latent Defect, ARIAD SWISSCO shall notify ARIAD US promptly once it becomes aware that a Product contains a Latent Defect and subsequently may reject such Product by giving written notice to ARIAD US of ARIAD SWISSCO’s rejection of such Product and shipping a representative sample of such Product or other evidence of Non-Conformance to ARIAD US within [**] after becoming aware of such Latent Defect, which notice shall include a description of the Latent Defect.
Licensed Product The term “Licensed Product” shall mean any product (a) the manufacture, use, importation, sale or offer for sale of which would, in the absence of the license granted by this Agreement, infringe a Valid Claim of any of the Licensed Patent Rights, or (b) that is comprised of, utilizes or incorporates Licensed Biological Materials, or (c) that is discovered, developed or made using a Licensed Process.
