Project Agreement 1.1 If applicable, the Department will recommend approval of the project by the Federal Highway Administration.
1.2 The Sponsor agrees to comply with Title VI of the Civil Rights Act of 1964, 78 Stat. § 252, 42 U.S.C. § 2000d et seq., and all requirements imposed by or pursuant to Title 49, Code of Federal Regulations, Part 21 - “Nondiscrimination in federally assisted programs of the Department of Transportation - effectuation of Title VI of the Civil Rights Act 1964".
1.3 The DEPARTMENT and SPONSOR mutually recognize that each party is a governmental entity subject to the provisions of the Governmental Tort Claims Act (51 O.S. § 151 et seq.). The DEPARTMENT and SPONSOR hereby mutually agree that each is and may be held severally liable for any and all claims, demands, and suits in law or equity, of any nature whatsoever, paying for damages or otherwise, arising from any negligent act or omission of any of their respective employees, agents or contractors which may occur during the prosecution or performance of this Agreement to the extent provided in the Governmental Tort Claims Act. Each party agrees to severally bear all costs of investigation and defense of claims arising under the Governmental Tort Claims Act and any judgments which may be rendered in such cause to the limits provided by law. Nothing in this section shall be interpreted or construed to waive any legal defense which may be available to a party or any exemption, limitation or exception which may be provided by the Governmental Tort Claims Act.
1.4 The Sponsor understands that should it fail to fulfill its responsibilities under this Agreement, such a failure will disqualify the Sponsor from future Federal-aid funding participation on any proposed project. Federal-aid funds are to be withheld until such a time as an engineering staff, satisfactory to the Department has been properly established and functioning, the deficiencies in regulations have been corrected or the improvements to be constructed under this Agreement are brought to a satisfactory condition of maintenance.
Project Agreements Provided that where the company commences work on a project where a site agreement exists to which the company is contractually obligated or where a site agreement exists between the union and the client or their agent that provides for higher rates of pay and conditions, the conditions contained in any such site agreement will take precedence over this Agreement for the duration of the project.
Project Plan Development of Project Plan Upon the Authorized User’s request, the Contractor must develop a Project Plan. This Project Plan may include Implementation personnel, installation timeframes, escalation procedures and an acceptance plan as appropriate for the Services requested. Specific requirements of the plan will be defined in the RFQ. In response to the RFQ, the Contractor must agree to furnish all labor and supervision necessary to successfully perform Services procured from this Lot. Project Plan Document The Contractor will provide to the Authorized User, a Project Plan that may contain the following items: • Name of the Project Manager, Contact Phone Numbers and E-Mail Address; • Names of the Project Team Members, Contact Phone Numbers and E-Mail Address; • A list of Implementation milestones based on the Authorized User’s desired installation date; • A list of responsibilities of the Authorized User during system Implementation; • A list of designated Contractor Authorized Personnel; • Escalation procedures including management personnel contact numbers; • Full and complete documentation of all Implementation work; • Samples of knowledge transfer documentation; and • When applicable, a list of all materials and supplies required to complete the Implementation described in the RFQ. Materials and Supplies Required to Complete Implementation In the event that there are items required to complete an Implementation, the Contractor may request the items be added to its Contract if the items meet the scope of the Contract. Negotiation of Final Project Plan If the Authorized User chooses to require a full Project Plan, the State further reserves the right for Authorized Users to negotiate the final Project Plan with the apparent RFQ awardee. Such negotiation must not substantively change the scope of the RFQ plan, but can alter timeframes or other incidental factors of the final Project Plan. The Authorized User will provide the Contractor a minimum of five (5) business days’ notice of the final negotiation date. The Authorized User reserves the right to move to the next responsible and responsive bidder if Contractor negotiations are unsuccessful.
Construction Contract If federal funds are included as part of the financing of the non-OPWC portion of the Project, federal law may prevail, including, but not limited to, application of Xxxxx Xxxxx prevailing wage rates, the Xxxxxxxx “Anti-Kickback” Act, the Contract Work Hours and Safety Standards Act, and any federal environmental regulations. Recipient is solely responsible for ensuring compliance with federal requirements applicable to its Local Subdivision Contribution. Notwithstanding the above, the following provisions apply to construction contracts under this Agreement:
Project Documents In addition to any other pertinent and necessary Project documents, the following documents shall be used in the development of the Project:
A. TxDOT 2011 Texas Manual of Uniform Traffic Control Devices for Streets and Highways, including latest revisions
B. Texas Department of Transportation's Standard Specifications for Construction of Highways, Streets, and Bridges, 2014 (English units)
Project Work Plan The Statement of Work is the formal document incorporated into the Grant. The Project Work Plan documents how the Grantee will achieve the performance measures outlined in the Grant. Changes to the Statement of Work require an amendment. Project Work Plans may be changed with written approval from PEI and the Grantee.
Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.
Development Agreement As soon as reasonably practicable following the ISO’s selection of a transmission Generator Deactivation Solution, the ISO shall tender to the Developer that proposed the selected transmission Generator Deactivation Solution a draft Development Agreement, with draft appendices completed by the ISO to the extent practicable, for review and completion by the Developer. The draft Development Agreement shall be in the form of the ISO’s Commission-approved Development Agreement for its reliability planning process, which is in Appendix C in Section 31.7 of Attachment Y of the ISO OATT, as amended by the ISO to reflect the Generator Deactivation Process. The ISO and the Developer shall finalize the Development Agreement and appendices as soon as reasonably practicable after the ISO’s tendering of the draft Development Agreement. For purposes of finalizing the Development Agreement, the ISO and Developer shall develop the description and dates for the milestones necessary to develop and construct the selected project by the required in-service date identified in the Generator Deactivation Assessment, including the milestones for obtaining all necessary authorizations. Any milestone that requires action by a Connecting Transmission Owner or Affected System Operator identified pursuant to Attachment P of the ISO OATT to complete must be included as an Advisory Milestone, as that term is defined in the Development Agreement. If the ISO or the Developer determines that negotiations are at an impasse, the ISO may file the Development Agreement in unexecuted form with the Commission on its own, or following the Developer’s request in writing that the agreement be filed unexecuted. If the Development Agreement is executed by both parties, the ISO shall file the agreement with the Commission for its acceptance within ten (10) Business Days after the execution of the Development Agreement by both parties. If the Developer requests that the Development Agreement be filed unexecuted, the ISO shall file the agreement at the Commission within ten (10) Business Days of receipt of the request from the Developer. The ISO will draft, to the extent practicable, the portions of the Development Agreement and appendices that are in dispute and will provide an explanation to the Commission of any matters as to which the parties disagree. The Developer will provide in a separate filing any comments that it has on the unexecuted agreement, including any alternative positions it may have with respect to the disputed provisions. Upon the ISO’s and the Developer’s execution of the Development Agreement or the ISO’s filing of an unexecuted Development Agreement with the Commission, the ISO and the Developer shall perform their respective obligations in accordance with the terms of the Development Agreement that are not in dispute, subject to modification by the Commission. The Connecting Transmission Owner(s) and Affected System Operator(s) that are identified in Attachment P of the ISO OATT in connection with the selected transmission Generator Deactivation Solution shall act in good faith in timely performing their obligations that are required for the Developer to satisfy its obligations under the Development Agreement.
Material Project Documents (a) The Company shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party and take reasonable actions to enforce all of its rights thereunder, other than to the extent the same could not reasonably be expected to have a Material Adverse Effect, (ii) subject to the provisions of clause (b) of this Section 9.8, maintain the System Leases (other than Leases constituting System Leases only pursuant to clause (5) of the definition thereof) in full force and effect, and (iii) maintain the Leases (other than the System Leases referred to in the foregoing clause (ii) of this Section 9.8(a)) to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect.
(b) If the term of a Lease with the Company or one of its Subsidiaries expires and the Qualified Lessee under such Lease has either ceased operating the related assets or has ceased paying rent as required under the applicable Lease, the Company shall, or shall cause a Subsidiary, as applicable, to enter into a supplement or a new Lease with respect to the related leasehold assets with a Qualified Lessee that provides for rent that, when combined with all other expected revenue, will, in the reasonable judgment of the Company, as of the commencement date of such supplement or new Lease, generate sufficient revenue to satisfy the requirements of Section 9.9 and will not otherwise result in a materially worse position for the Company as compared to the terms of the applicable expired Lease. Each such new Lease shall have a term of at least five years. Notwithstanding the foregoing, if (i) such expired Lease relates to transmission and/or distribution assets that are not generating significant revenue, (ii) the failure to renew such Lease would not constitute a Material Adverse Effect and (iii) the Company reasonably believes it will generate sufficient revenue and hold sufficient assets (without giving effect to the leasehold assets with respect to such Lease) to satisfy the requirements of Section 9.9, then this Section 9.8(b) will not require a supplement or new lease with respect to such leasehold assets.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
