DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State. 8.3.2 Any claim for extension of time shall be made in writing to the Architect not more than twenty days after the commencement of the delay; otherwise it shall be waived. In the case of a continuing delay only one claim is necessary. The Contractor shall provide an estimate of the probable effect of such delay on the progress of the Work. 8.3.3 This Paragraph 8.3 does not exclude the recovery of damages for delay by either party under other provisions of the Contract Documents.
Provisions of General Application (a) All accounting terms not specifically defined herein shall be construed in accordance with GAAP. (b) The terms defined in this Article include the plural as well as the singular. (c) The words "herein," "hereof" and "hereunder" and other words of similar import refer to this Agreement as a whole. All references to Articles and Sections shall be deemed to refer to Articles and Sections of this Agreement.
Other Provisions of General Application Section 7.1 Notices to the Rights Agent, Parent and the Stockholders’ Representative. Any notice, request, instruction or other document to be given hereunder by any party to the others shall be in writing and delivered personally or sent by registered or certified mail, postage prepaid, by electronic mail (except with respect to the Rights Agent), by facsimile transmission only with respect to the Rights Agent or overnight courier, provided that with respect to notices deliverable to the Stockholders’ Representative, such notices shall be delivered solely via electronic mail or facsimile: If to Parent or the Company: Eros International Plc First Names House Victoria Road Xxxxxxx Isle of Man IM2 4DF British Isles Attention: Xxxx Xxxxxxx, Chief Corporate and Strategy Officer Email: xxxx.xxxxxxx@xxxxxxxx.xxx with a copy (which shall not constitute notice) to: Xxxxxx, Xxxx & Xxxxxxxx LLP 000 Xxxxx Xxxxx Xxxxxx Xxx Xxxxxxx, Xxxxxxxxxx 00000-0000 Attention: Xxxxx Xxxxxx Xxxxx Xxxxxx Email: xxxxxxx@xxxxxxxxxx.xxx xxxxxxx@xxxxxxxxxx.xxx If to the Rights Agent: Computershare Trust Company, N.A., Computershare Inc. 000 Xxxxxx Xxxxxx Canton, MA 02021 Attention: Client Services Facsimile: (000) 000-0000 If to the Stockholders’ Representative: Fortis Advisors LLC Attention: Notices Department (Project World Cup) Email: xxxxxxx@xxxxxxxxx.xxx Facsimile: (000) 000-0000 with a copy (which shall not constitute notice) to: Xxxxxxxx & Xxxxx LLP 000 Xxxxx Xxxxxx Xxxxxx, Xxxxx 0000 Xxx Xxxxxxx, Xxxxxxxxxx 00000 Attention: Xxxx X. Xxxxxx, P.C. Email: xxxx.xxxxxx@xxxxxxxx.xxx or to such other persons or addresses as may be designated in writing by the party to receive such notice as provided above. Any notice, request, instruction or other document given as provided above shall be deemed given to the receiving party upon actual receipt, if delivered personally; three (3) business days after deposit in the mail, if sent by registered or certified mail; upon confirmation of successful transmission if sent by electronic mail; or on the next business day after deposit with an overnight courier, if sent by an overnight courier.
Limitations on Activities Anything else in this Agreement to the contrary notwithstanding, the Advisor shall refrain from taking any action which, in its sole judgment made in good faith, would (a) adversely affect the status of the Corporation as a REIT, (b) subject the Corporation to regulation under the Investment Corporation Act of 1940, as amended, or (c) violate any law, rule, regulation or statement of policy of any governmental body or agency having jurisdiction over the Corporation, its Shares or its Securities, or otherwise not be permitted by the Charter or Bylaws of the Corporation, except if such action shall be ordered by the Board of Directors, in which case the Advisor shall notify promptly the Board of Directors of the Advisor’s judgment of the potential impact of such action and shall refrain from taking such action until it receives further clarification or instructions from the Board of Directors. In such event the Advisor shall have no liability for acting in accordance with the specific instructions of the Board of Directors so given. Notwithstanding the foregoing, the Advisor, its members, managers, directors, officers, employees and stockholders, and members, managers, stockholders, directors and officers of the Advisor’s Affiliates, shall not be liable to the Corporation or to the Board of Directors or stockholders for any act or omission by the Advisor, its members, managers, directors, officers or employees, or stockholders, members, managers, directors or officers of the Advisor’s Affiliates taken or omitted to be taken in the performance of their duties under this Agreement except as provided in Paragraph 19 of this Agreement.
General Provisions Applicable to Loans and Letters of Credit 4.1. Interest Rates and Payment Dates 4.2. Conversion and Continuation Options 4.3. Minimum Amounts of Sets
Definitions and Other Provisions of General Application SECTION 101.
Waivers and Extensions Any party to this Agreement may waive any right, breach or default which such party has the right to waive, provided that such waiver will not be effective against the waiving party unless it is in writing, is signed by such party, and specifically refers to this Agreement. Waivers may be made in advance or after the right waived has arisen or the breach or default waived has occurred. Any waiver may be conditional. No waiver of any breach of any agreement or provision herein contained shall be deemed a waiver of any preceding or succeeding breach thereof nor of any other agreement or provision herein contained. No waiver or extension of time for performance of any obligations or acts shall be deemed a waiver or extension of the time for performance of any other obligations or acts.
Limitations on Actions Any action brought under this Contract, except an action for breach of warranty, shall be brought within the shorter of the statutory limitations period and the period of three years from the date of final payment without any tolling of this statutory limitations period for any reason whatsoever.
Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.
Class Proceedings and Consolidations No party hereto shall be entitled to join or consolidate disputes by or against others in any arbitration, except parties who have executed any Loan Document, or to include in any arbitration any dispute as a representative or member of a class, or to act in any arbitration in the interest of the general public or in a private attorney general capacity.