ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Engineer Responsibilities No subcontract relieves the Engineer of any responsibilities under this contract.
Engineers Responsibility The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed.
Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.
Client’s Responsibilities (a) Client agrees to advise Consultant regarding Client's Project requirements and to provide all relevant information, surveys, data and previous reports accessible to Client which Consultant may reasonably require.
(b) Client shall designate a Project Representative to whom all communications from Consultant shall be directed and who shall have limited administrative authority on behalf of Client to receive and transmit information and make decisions with respect to the Project. Said representative shall not, however, have authority to bind Client as to matters of governmental policy or fiscal policy, nor to contract for additions or obligations exceeding a value which is the lesser of $5000 or 5% of the maximum contract price.
(c) Client shall examine all documents presented by Consultant, and render decisions pertaining thereto within a reasonable time. The Client's approval of any drawings, specifications, reports, documents or other materials or product furnished hereunder shall not in any way relieve Consultant of responsibility for the professional adequacy of its work.
(d) Client shall perform its obligations and render decisions within a reasonable time under the circumstances presented. Based upon the nature of Client and its requirements, a period of 14 days shall be presumed reasonable for any decision not involving policy decision or significant financial impact, when all information reasonably necessary for Client to responsibly render a decision has been furnished. A period of 46 days shall be presumed reasonable for Client to act with respect to any matter involving policy or significant financial impact. The above periods of presumed reasonableness shall be extended where information reasonably required is not within the custody or control of Client but must be procured from others.
Owner Responsibilities The project owner or the engineer or architect of record acting as the owner’s agent shall fund special inspection services.
Contractor Responsibilities 19.1. Contractor shall perform national criminal history checks for Ohio, Indiana, and Kentucky, and 10-panel drug screening tests on all prospective employees performing work under this RFP or coming onto a CMHA property and any resulting contract and provide summaries of the results to the Authority if requested. For the purposes of this section, the term “employees” includes contractor. Prospective employees whose criminal background check discloses a misdemeanor or felony involving crimes of moral turpitude, sexual offenses or harm to persons or property shall not be employed to perform work under this RFP or any resulting contract. Contractor is required to perform drug screening of all employees and to ensure acceptable test results. Criminal history and drug screening checks will be completed at the sole expense of the contractor. Any employee of the Contractor suspected of being under the influence of drugs and or alcohol will be reported to the appropriate personnel at CMHA and/or other local law enforcement. If the employee is determined to be under the influence of drugs or alcohol in any form or manner, or believed by proper authority to be dealing in illicit sale of alcohol or drugs they will be removed and shall not be allowed to return to any job site on the Authority’s property. The Contractor’s contract may be suspended and/or terminated should such a situation occur or if the Contractor fails to submit results pursuant to this section.
19.1.1. If CMHA requests additional drug screening, the test shall be performed within 24 hours and the summary shall be sent directly to CMHA from the testing facility.
19.2. Contractor(s) shall provide uniforms and ID Badges identifying Contractor for all employees working on CMHA’s properties. No employees will be allowed on CMHA’s properties out of uniform and without his/her ID badge on his/her person. Contractor(s) must submit a picture of the uniform and a sample of his/her ID badge if requested by CMHA.
19.3. Contractor’s personnel shall be neat and conduct all work in a professional and efficient manner. If any employee of Contractor is deemed unacceptable by CMHA, Contractor shall immediately replace such personnel with an acceptable substitute to CMHA.
19.4. Contractor(s) shall practice acceptable safety precautions so as not to cause harm to any persons or property while performing services under this RFP or any resulting contract. Contractor(s) shall follow industry safety standards, and use only industry approved safety equipment in accordance with the manufacturer’s specifications in the performance of all duties.
19.5. Contractor(s) shall pay all of its employees, including any and all approved Sub-Contractors, at least the legal minimum wages as determined by the United States Department of Labor and the United States Department of Housing and Urban Development and Department of Labor Prevailing Wage. Wage Determinations can be accessed via the Department of Labor website, xxx.xxxx.xxx.
19.6. Upon completion of the work, Contractor(s) shall clean up the area where the work was performed and Contractor(s) shall remove any debris generated by the products and/or services at CMHA premises. At no time, will Contractor(s) discard debris into any CMHA refuse container.
19.7. Contractor(s) shall clearly mark all work areas that might reasonably be expected to endanger the health and safety of residents, guests, or any other persons. Contractor(s) will provide such signs, markers and barricades as required to identify all work areas and minimize inherent dangers.
19.8. The contractor shall be responsible for notifying CMHA immediately of any damages (i.e. fire, container leaking) deemed to be a health or safety hazard whether the damage is caused by the contractor or other means.
19.9. The Contractor shall be responsible for safeguarding all CMHA property provided for Contractor use. At the close of each workday, CMHA facilities, property and materials shall be inspected and secured.
Supplier’s Responsibilities 14.1 The Supplier shall supply all the Goods and Related Services included in the Scope of Supply in accordance with GCC Clause 12, and the Delivery and Completion Schedule, as per GCC Clause 13.
OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever:
(a) The scope of services to be provided and performed by the CONTRACTOR hereunder;
(b) The time the CONTRACTOR is obligated to commence and complete all such services; or
(c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR.
2.2. The Project Coordinator shall:
(a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement;
(b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and
(c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder.
2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR.
3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by September 30, 2005. Based on the mutual agreement of both parties, this contract may be renewed a maximum of two one-year periods thereafter.
3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension.
3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period.
3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.
COUNTY’S RESPONSIBILITIES A. A County program liaison will monitor the submission of all correspondence required in this Agreement, including, but not limited to:
1. Quarterly Treatment Reports;
2. Financial reports such as annual budgets, cost allocation plans, and cost reports;
3. Incident reports;
4. Outcome data;
5. Monthly XXXXX Reports
6. Other requested reports
B. A County program liaison may visit Contractor during the contract term. The visits shall be for the purpose of reviewing any aspect of Contractor’s program operations. The visit may include, but is not limited to:
1. Review all pertinent participant records.
2. Conduct appropriate interviews/discussions with participants served by Contractor.
3. Review and monitor all correspondence and reports submitted by Contractor related to Contractor’s services provided under this Agreement.
4. Meet with appropriate program management and operations staff.
5. Conduct site visit(s) to Contractor’s program(s) at least once during the term of the Agreement to review all aspects of program operations. Site visit(s) may include a review of Contractor’s programmatic and fiscal documentation related to required reports on services specified in the Exhibits.
a. Provide a written site review report documenting areas of compliance and any necessary corrective action(s) required.
6. A County program liaison may attend an organized activity of a selected component or selected components of Contractor’s program(s) at least once during the contract term.
C. AODS will conduct periodic mandatory treatment provider meetings with representatives of all contracted service providers and appropriate staff.
D. Provide ongoing technical assistance as needed.
E. AODS shall act as intermediary on behalf of each contracted alcohol and drug service provider in the submission of the California Outcomes Measurement System (CalOMS) data submissions to the State of California.
I. GENERAL ADMINISTRATIVE REQUIREMENTS
A. Attend each of the following meetings:
1. Contractor shall attend periodic mandatory meetings; and
2. Drug and Alcohol Information System for You (DAISY) User Group meeting.
3. Other meetings as required by the County
B. Contractor shall acknowledge the San Mateo County Alcohol and Other Drug Services (AODS) and/or the County of San Mateo as a funding source on newly developed promotional materials.
C. Subcontracting requirements:
1. Pursuant to paragraph 12 of the body of this Agreement, Contractor may subcontract for provision of services described in this Agreement with written approval of the Director of the Human Services Agency or her designee. If Contractor subcontracts for any services under this Agreement, Contractor will guarantee that any and all subcontractors have and maintain the same level of insurance coverage required of the Contractor under this Agreement. Contractor and County will be listed as additional insured on all applicable insurance of subcontractor.
