Architectural Plans Clause Samples

The 'Architectural Plans' clause defines the requirements and responsibilities related to the creation, submission, and approval of architectural drawings and specifications for a project. Typically, it outlines who is responsible for preparing the plans, the standards or codes they must meet, and the process for review and approval by relevant parties such as the client or regulatory authorities. This clause ensures that all parties have a clear understanding of the design expectations and that the project proceeds in accordance with agreed-upon plans, thereby minimizing misunderstandings and facilitating compliance with legal or contractual obligations.
POPULAR SAMPLE Copied 6 times
Architectural Plans. The Seller shall have approval rights as follows: i. Subject to the approvals granted by Seller as provided in Section 1.02 above, the exterior design and materials (including color) and location of all improvements and house models to be constructed by Purchaser on the Lots and all Lot plans for Lots shall be subject to review and approval by Seller, such approval not to be unreasonably withheld. ii. Applications are to be submitted in duplicate. All approvals or disapprovals shall be in writing. iii. The Seller shall approve or disapprove submissions within thirty (30) days of receipt. If no approval or disapproval is communicated within said thirty (30) days, requests shall be deemed approved. Reasons will be submitted for disapproval. Once a model has been approved, it may be continued throughout the Lots, but identical elevations shall not be built adjacent to or directly across the street from each other. iv. In the event of any exterior changes to the architectural plans, Purchaser must obtain the approval thereof by Seller and the Association (as hereinafter defined), such approvals not to be unreasonably withheld.
View Source
Architectural Plans. An assignment of Seller’s rights, if any, to any architectural drawings and site plans for the Property and bluelined copies of such drawings and plans (to the extent in Seller’s possession).
View Source
Architectural Plans. After Landlord approves the Space Plan, Tenant shall cause the Architect to prepare and deliver to Landlord four (4) copies of the final architectural (and, if applicable, structural) working drawings for the Tenant Improvement Work that are in a form sufficient to enable the Contractor and its subcontractors to bid on the work (the “Architectural Plans”). The Architectural Plans shall conform to the approved Space Plan and the Landlord Requirements and shall include, without limitation, (i) all interior and special finishes; (ii) all electrical requirements, (iii) all telephone requirements, (iv) all special HVAC requirements, (v) all plumbing requirements, and (vi) all other information that is necessary, in the judgment of Landlord, to complete the Engineering Drawings. Landlord shall provide Tenant with notice approving or reasonably disapproving the Architectural Plans (or the applicable component thereof) within five (5) business days after the later of Landlord’s receipt thereof or the mutual execution and delivery of this Agreement. If Landlord disapproves the Architectural Plans (or any component thereof), Landlord’s notice of disapproval shall describe with reasonable specificity the basis for such disapproval and the changes that would be necessary to resolve Landlord’s objections. If Landlord disapproves the Architectural Plans (or any component thereof), Tenant shall cause the Architectural Plans to be modified and resubmitted to Landlord for its approval. Such procedure shall be repeated as necessary until Landlord has approved the Architectural Plans (or the applicable component thereof). No revision may be made to the approved Architectural Plans (the “Approved Architectural Plans”) without Landlord’s prior consent as described in Section 2.7 below. Immediately following Landlord’s approval of the Architectural Plans, Tenant shall deliver to Landlord a CD ROM of the backgrounds of the Approved Architectural Plans in accordance with Landlord’s CAD Format Requirements (as hereinafter defined).
View Source
Architectural Plans 
View SourceView Similar (13)

Related to Architectural Plans

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • Improvement Plans A professional improvement plan is a clearly articulated assistance program for a teacher whose student growth measure dimension of the evaluation is below the expected level of student growth. For the purposes of this agreement, improvement plans shall be based on the individual student growth measure level, and not for overall subjects or classes taught.

  • Final Plans No later than thirty (30) days following the approval of the Preliminary Plans, Tenant shall submit to Landlord a proposed set of Final Plans for approval by Landlord. Landlord’s approval of such proposed Final plans shall not be unreasonably withheld, conditioned or delayed, provided that (a) the Tenant Improvements, as set forth on such plans, comply with all applicable governmental laws, codes, rules, and regulations, and (b) such plans are sufficiently detailed to allow construction of the Tenant Improvements in a good and workmanlike manner. Landlord shall advise Tenant of Landlord’s approval or disapproval of the proposed Final Plans. If Landlord disapproves any aspect of the proposed Final Plans, Landlord shall so notify Tenant and specify how any such disapproved item may be made acceptable to Landlord. The proposed Final Plans shall then be revised and re-submitted to Landlord and Landlord and Tenant shall agree upon and sign the Final Plans as soon as reasonably practicable. The proposed Final Plans will be deemed to be complete and become the Final Plans upon execution thereof by Landlord and Tenant, and thereupon such Final Plans shall be deemed to be a part of this Lease and incorporated into this Lease by reference. Approval by Landlord of the Final Plans shall not be a representation or warranty of Landlord that such plans are adequate for any use, purpose, or condition, or that such plans comply with any applicable law or code, but shall merely be the consent of Landlord to the Final Plans. All changes in the Final Plans must receive the prior written approval of Landlord, and in the event of any such approved change, Tenant shall, upon completion of the Tenant Improvements, furnish Landlord with an accurate, reproducible “as-built” plan of the Tenant Improvements as constructed.

  • Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Plans and Specifications After Landlord receives and approves Tenant’s Space Plan as provided above, Tenant will cause Tenant’s Architect to prepare the Plans and Specifications for the Tenant Improvements. Landlord will approve or disapprove (specifically describing any reasons for disapproval) the Plans and Specifications in writing within ten (10) Business Days after receiving them. If Landlord disapproves the Plans and Specifications, Tenant will provide appropriately revised Plans and Specifications to Landlord for approval (or disapproval) within five (5) Business Days on the same basis as set forth above. After Landlord’s approval, Tenant will submit the Plans and Specifications for permits and construction bids. No deviation from the Building Standard will be permitted in the Space Plan or the Plans and Specifications, provided reasonable deviations with respect to the ceiling, lighting, painting, flooring and wall covering may be permitted with Landlord’s approval. Landlord will not approve any deviations which Landlord believes (a) do not conform to applicable codes, ordinances and other Laws or are disapproved by any governmental agency, (b) require services beyond the level normally provided to other tenants in the Building, or (c) are of a nature or quality that are inconsistent with Landlord’s overall plan or objectives for the Building. No approval by Landlord of any deviation constitutes an acknowledgment by Landlord that such deviations are in conformance with applicable codes, ordinances and other Laws. In the event that Landlord’s approval shall be required in this Tenant Improvements Agreement, then notwithstanding anything to the contrary set forth in the Lease, Landlord’s approval shall not be unreasonably withheld, conditioned, or delayed.