Sale Area Map The boundaries of “Sale Area” and any subdivision thereof, are as shown on the at- tached “Sale Area Map” that is made a part hereof, and were, before timber sale advertisement, designated on the ground by Forest Service to meet the anticipated needs of the parties. The location of Sale Area and its approximate acreage are stated in A1. Subdivisions may be revised and additional ones may be established only by written agreement. Subdivisions or cutting units may be eliminated from Sale Area under conditions described in B6.36. Catastrophically Damaged areas may be re- moved from Sale Area under B8.32. Where applicable, the following are also identified on Sale Area Map:
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Construction Cost Adjustment Contracting Officer, as provided in B5.21, B5.212, B5.251, B5.252, and B5.253, shall adjust Specified Road construction cost estimates in the Schedule of Items and show the adjustments as credits or debits to Timber Sale Account in the month when the road segment is accepted.
Designated on Sale Area Map Purchaser shall keep roads and trails needed for fire protection or other purposes and designated on Sale Area Map reasonably free of equipment and products, slash, and debris resulting from Purchaser’s Operations. Purchaser shall make timely restoration of any such im- provements damaged by Purchaser’s Operations and, when necessary because of such operations, shall move such improvements, as specified in C6.22. B6.221 Protection of Improvements Not Owned by Forest Service. Forest Service will notify all utility companies, or other parties affected, and make ar- rangements for all necessary adjustments of the public utility fixtures, pipelines, and other appurtenances likely to be affected by Purchaser’s Operations. When Purchaser’s Operations are adjacent to proper- ties of railway, telephone, or power companies, or other property, work shall not begin until Purchaser has identi- fied actions necessary to prevent damage. Purchaser shall cooperate with the owners of any un- derground or overhead utility lines in their removal and/or rearrangement operations in order that these operations may progress in a reasonable manner, utility duplication or rearrangement work may be reduced to a minimum, and services shall not be unnecessarily interrupted. In the event of interruption to utility services because of accidental breakage or as a result of lines being ex- posed or unsupported, Purchaser shall promptly notify the proper authority and shall cooperate with that authority in the restoration of service until the service is restored. When materials are to be hauled across the tracks of any railway, Forest Service will make arrangements with the railroad for the use of any existing crossing or for any new crossing required. Purchaser shall make arrange- ments for use of alternate crossings. All construction work to be performed by Purchaser on the railroad right-of-way shall not damage railroad company’s property. B6.222 Protection of Property. In construc- tion and reconstruction of Specified Roads, Purchaser shall not unnecessarily remove, deface, injure, or destroy trees, shrubs, or other natural features, unless specifically authorized. To the extent practicable, Purchaser shall confine operations to within the clearing limit or other ar- eas designated in the contract and prevent the depositing of rocks, excavated materials, stumps, or other debris outside these limits. Material that falls outside these limits shall be re- trieved, disposed of, or incorporated in the work to the ex- tent practicable and necessary to protect adjacent re- source values, unless otherwise agreed. B6.23 Protection of Land Survey Monuments. Forest Service shall appropriately designate on the ground all known survey monuments, section corners, and other corner accessories. Forest Service shall post identifying signs on two sides of each known bearing tree. Forest Service shall arrange protective or per- petuative action that does not cause unnecessary delay to Purchaser in authorized clearings, such as Clearcutting Units and road construction, and in other instances where damage to monuments, section corners, and other corner accessories is unavoidable. Purchaser shall protect all known survey monuments, witness corners, reference monuments, and bearing trees against avoidable destruction, obliteration, or damage during Purchaser’s Operations. If any known monuments, corners, or accessories are destroyed, obliterated, or damaged by Purchaser’s Operations, Purchaser shall hire the appropriate county surveyor or a registered land sur- veyor to reestablish or restore at the same location the monuments, corners, or accessories. Such surveyors shall use procedures in accordance with the Bureau of Land Management “Manual of Instructions for the Survey of the Public Lands of the United States” for General Land Office surveys and in accordance with State law for others. Purchaser shall record such survey in appropriate county records.
Project Commencement The Grantee shall begin the grant-funded project <<on or before insert date>> <<within 90 days of the original start date of the grant term or grant execution date, whichever is later,>>, unless otherwise approved by System Agency. If project commencement is delayed, the Grantee must submit in writing to the assigned contract manager, the steps taken to initiate the project, the reasons for the delay, and the expected start date. System Agency may require Grantee to take immediate remedial or corrective action in response to any delay.
Phase I a. In Phase I, the project will be connected as a tap to the Transmission Owner’s 230kV transmission line MWP-2 via one 230kV circuit breaker in series with one of two ring bus breakers for stuck breaker protection (one in each direction) and a tie-line breaker, as shown on the one-line diagram labeled CL-E-IA-01 attached to this Appendix A as Figure 1. The changes to the existing MWP-2 line protection for this arrangement are described in Phase I System Upgrades in Section II of this Appendix A.
Sale Area When portions of the sale area become subject to a foreign or domestic governmental regulation or order that will likely prevent timber harvest for a period that will exceed the expiration date of this contract, and Purchaser has complied with this contract, the following shall apply:
ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.
Project Completion Part 1 – Material Completion
Construction Development of the Project The Allottee has seen the proposed layout plan/demarcation-cum-zoning/sanctioned plans, / site plan / building plan, specifications, amenities and facilities, etc. depicted in the advertisement / brochure / agreement / website (as the case may be) regarding the Project where the Said Independent Floor for residential usage along with parking is located and has accepted the floor / site plan, Payment Plan and the specifications, amenities, facilities, etc. [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the bye-laws such as Haryana Building Code, 2017, FAR, density norms, provisions prescribed, approved plans, terms and condition of the license/ allotment as well as registration of RERA, etc. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the provisions and norms prescribed by the relevant State laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act and Rules made thereunder or as per approvals/instructions/ guidelines of the competent authorities, and any breach of this term by the Promoter shall constitute a material breach of the Agreement.
