CASUALTY DAMAGE A. If all or any part of the Premises is damaged by fire or other casualty, Tenant shall immediately notify Landlord in writing. During any period of time that all or a material portion of the Premises is rendered untenantable as a result of a fire or other casualty, the Rent shall xxxxx for the portion of the Premises that is untenantable and not used by Tenant. Landlord shall have the right to terminate this Lease if: (1) the Building or the Project shall be damaged so that, in Landlord’s reasonable judgment, substantial alteration or reconstruction of the Building or the Project shall be required (whether or not the Premises has been damaged); (2) Landlord is not permitted by Law to rebuild the Building or the Project in substantially the same form as existed before the fire or casualty; (3) the Premises have been materially damaged and there is less than eighteen (18) months of the Term remaining on the date of the casualty; (4) any Mortgagee requires that the insurance proceeds be applied to the payment of the mortgage debt; or (5) a material uninsured loss to the Building or the Project occurs. Landlord may exercise its right to terminate this Lease by notifying Tenant in writing within 90 days after the date of the casualty. If Landlord does not terminate this Lease, Landlord shall commence and proceed with reasonable diligence to repair and restore the Building and the Premises Improvements (excluding any Alterations that were performed by Tenant in violation of this Lease). However, in no event shall Landlord be required to spend more than the insurance proceeds received by Landlord. Landlord shall not be liable for any loss or damage to Tenant’s Property or to the business of Tenant resulting in any way from the fire or other casualty or from the repair and restoration of the damage. Landlord and Tenant hereby waive the provisions of any Law relating to the matters addressed in this Article, and agree that their respective rights for damage to or destruction of the Premises shall be those specifically provided in this Lease. Tenant shall have the right to terminate this Lease i 1: (a) a substantial portion of the Premises has been damaged by fire or other casualty and such damage cannot reasonably be repaired (as reasonably determined by Landlord) within 60 days after Landlord’s receipt of all required permits to restore the Premises; (b) there is less than eighteen (18) months of the Term remaining on the date of such casualty; and (c) Tenant provides Landlord with written notice of its intent to terminate within thirty (30) days after the date of the fire or other casualty.
Property Damages The User’s guests are required to respect all University property. • Guests may not remodel, alter, tamper with or move furniture, electrical or mechanical fixtures, or other University property. • The User agrees to refrain from the use of adhesives, nails, or items that may damage the premises. No decorations or temporary fixtures may be affixed to plants, trees, woodwork, buildings or any architectural feature with nails, tacks, staples, or any application that will cause irreversible damage to landscaping or structures. Duct tape and white masking tape are not permitted on any building, hardscape or lighting fixtures. Neither lights nor decorations may be placed on trees or plants. • Any outdoor signage must be reviewed and approved by University prior to installation. Stakes may not be placed deeper than 5 inches into the grass in order to protect sprinklers and other underground pipes. • Charges will be assessed on the Final Invoice for damages to buildings, furniture, lawns and/or equipment. The University will, to the best of its ability, try to document the names of guests when damages occur but cannot always obtain such information.
Property Damage Lessee shall obtain and maintain insurance coverage on all of Lessee's personal property, Trade Fixtures, and Lessee Owned Alterations and Utility Installations. Such insurance shall be full replacement cost coverage with a deductible of not to exceed $1,000 per occurrence. The proceeds from any such insurance shall be used by Lessee for the replacement of personal property, Trade Fixtures and Lessee Owned Alterations and Utility Installations. Lessee shall provide Lessor with written evidence that such insurance is in force.
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
Remedy Damages The Contractor shall promptly remedy damages and loss to property at the Site caused by the Contractor, by any Subcontractor, by anyone directly or indirectly employed by the Contractor or any such Subcontractor, or by anyone for whose acts the Contractor or any such Subcontractor may be liable. Should the Contractor cause damage to any Separate Contractor‘s work, the Contractor agrees, upon due notice, to settle with the Separate Contractor.
CLOSURE TO PREVENT DAMAGE In accordance with Contract Clause G-220 STATE SUSPENDS OPERATION, the Contract Administrator will suspend road work or hauling right-of-way timber, forest products, or rock under the following conditions: Wheel track rutting exceeds 6 inches on roads. Surface or base stability problems persist. Weather is such that satisfactory results cannot be obtained in an area of operations. When, in the opinion of the Contract Administrator excessive road damage or rutting may occur. Operations must stop unless authority to continue working or hauling is granted in writing by the Contract Administrator. In the event that surface or base stability problems persist, Purchaser shall cease operations, or perform corrective maintenance or repairs, subject to specifications within this road plan. Before and during any suspension, Purchaser shall protect the work from damage or deterioration.
Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11
DAMAGE TO FACILITIES The Student will promptly report damages and request necessary repairs, in accordance with established and published procedures. The Student is responsible for damages caused by the Student. Damages to shared or common areas not attributable to a responsible person are the joint responsibility of all persons sharing the space or area. UCF DHRL reserves the right to charge the Student for damages caused by the Student. Charges may include, but are not limited to, extraordinary pest control charges, repair of walls, furniture or fixtures, and damages to common areas. UCF DHRL also reserves the right to charge the Student for a portion of damages caused to spaces shared by the Student when the person responsible for damages to shared spaces cannot be identified.
Damage Liability The University is not liable for damage to or loss of personal property, failure or interruption of utilities, or for injury or inconvenience to persons (except to the extent set forth in Florida Statutes, Sec. 768.28) Students are encouraged to provide their own personal property loss insurance.
