Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Termination Due to Death If the Optionee’s employment terminates by reason of the Optionee’s death, any portion of this Stock Option outstanding on such date, to the extent exercisable on the date of death, may thereafter be exercised by the Optionee’s legal representative or legatee for a period of 12 months from the date of death or until the Expiration Date, if earlier. Any portion of this Stock Option that is not exercisable on the date of death shall terminate immediately and be of no further force or effect.
Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.
Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement: a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions. b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract. (1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance. (2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email. (3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination. c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.
Termination Due to Death or Disability The expiration of one (1) year from the date of the death of the Optionee or cessation of an Optionee’s employment or contractual relationship by reason of disability (as defined in Section 5.1(g) of the Plan). If an Optionee’s employment or contractual relationship is terminated by death, any Option held by the Optionee shall be exercisable only by the person or persons to whom such Optionee’s rights under such Option shall pass by the Optionee’s will or by the laws of descent and distribution.
Termination Due to Retirement Subject to Section 7 below, in the event of Termination due to Retirement, then (regardless of any subsequent death of the Employee) the Option will continue to vest pursuant to Section 3, and the last date on which the Option may be exercised is the day prior to the Expiration Date.
Termination for Nonpayment In the event of the nonpayment of fees owed to DSI, DSI shall provide written notice of delinquency to all parties to this Agreement. Any party to this Agreement shall have the right to make the payment to DSI to cure the default. If the past due payment is not received in full by DSI within one month of the date of such notice, then DSI shall have the right to terminate this Agreement at any time thereafter by sending written notice of termination to all parties. DSI shall have no obligation to take any action under this Agreement so long as any payment due to DSI remains unpaid.
Substantial Performance This Contract shall be deemed to be substantially performed only when fully performed according to its terms and conditions and any written amendments or supplements.
