Contract Quarterly Sales Reports The Contractor shall submit complete Quarterly Sales Reports to the Department’s Contract Manager within 30 calendar days after the close of each State fiscal quarter (the State’s fiscal quarters close on September 30, December 31, March 31, and June 30). Reports must be submitted in MS Excel using the DMS Quarterly Sales Report Format, which can be accessed at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. Initiation and submission of the most recent version of the Quarterly Sales Report posted on the DMS website is the responsibility of the Contractor without prompting or notification from the Department’s Contract Manager. If no orders are received during the quarter, the Contractor must email the DMS Contract Manager confirming there was no activity.
Forecast Customer shall provide Flextronics, on a monthly basis, a rolling [***] forecast indicating Customer’s monthly Product requirements. The first [***] of the forecast will constitute Customer’s written purchase order for all Work to be completed within the first [***] period. Such purchase orders will be issued in accordance with Section 3.2 below.
Rolling Forecasts No later than ten (10) days of the Commencement Date, the Client shall provide Patheon with a written non-binding 18 month forecast of the volume of the Drug Product that the Client then anticipates will be required to be produced and delivered to the Client during each month of that 18 month period. Such forecast will be updated by the Client monthly on a rolling 18 month basis and updated forthwith upon the Client determining that the volumes contemplated in the most recent of such forecasts has changed by more than 20%. The most recent 18 month forecast shall prevail.
Rolling Forecast (i) On or before the fifteenth (15th) calendar day of each month during the Term (as defined in Section 6.1 herein), Buyer shall provide Seller with an updated eighteen (18) month forecast of the Products to be manufactured and supplied (each a “Forecast”) for the eighteen (18) month period beginning on the first day of the following calendar month. The first two months of each Forecast will restate the balance of the Firm Order period of the prior Forecast, and the first three (3) months of the Forecast shall constitute the new Firm Order period for which Buyer is obligated to purchase and take delivery of the forecasted Product, and the supply required for the last month of such new Firm Order period shall not be more than one (1) full Standard Manufacturing Batch from the quantity specified for such month in the previous Forecast (or Initial Forecast, as the case may be). Except as provided in Section 2.2(a), Purchase Orders setting forth Buyer’s monthly Product requirements will be issued for the last month of each Firm Order period no later than the fifteenth calendar day of the first month of each Firm Order period, and such Purchase Order will be in agreement with the Firm Order period of the Forecast. If a Purchase Order for any month is not submitted by such deadline, Buyer shall be deemed to have submitted a Purchase Order for such month for the amount of Product set forth in Buyer’s Forecast for such month.
(ii) The remainder of the Forecast shall set forth Buyer’s best estimate of its Product production and supply requirements for the remainder of the Forecast period. Each portion of such Forecast that is not deemed to be a Firm Order shall not be deemed to create a binding obligation on Buyer to purchase and take delivery of Products nor a binding obligation of Seller to deliver Products, except as otherwise provided in Section 2.2(f).
(iii) Forecast and Purchase Orders shall be in full Standard Manufacturing Batches. If a Product has multiple SKUs, then the composite of the forecasted SKU must equate to the Standard Manufacturing Batch. One Purchase Order shall be issued for each full Standard Manufacturing Batch of Product and contain the required information set forth in Section 2.2(e) hereof.
Required Vendor Sales Reporting By responding to this Solicitation, you agree to report to TIPS all sales made under any awarded Agreement with TIPS. Vendor is required to report all sales under the TIPS contract to TIPS. If the TIPS Member entity requesting a price from the awarded Vendor requests the TIPS contract, Vendor must include the TIPS Contract number on any communications with the TIPS Member entity. If awarded, you will be provided access to the Vendor Portal. To report sales, login to the TIPS Vendor Portal and click on the PO’s and Payments tab. Pages 3-7 of the Vendor Portal User Guide will walk you through the process of reporting sales to TIPS. Please refer to the TIPS Accounting FAQ’s for more information about reporting sales and if you have further questions, contact the Accounting Team at xxxxxxxxxx@xxxx-xxx.xxx. The Vendor or vendor assigned dealers are responsible for keeping record of all sales that go through the TIPS Agreement and submitting same to TIPS.
Quarterly Sales Reports The Contractor shall submit a completed Quarterly Sales Report electronically, in the required format, to the Department’s Contract Manager within thirty (30) calendar days after close of each quarter. The quarterly sales report can be found here: xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. The Contract Quarterly Sales Report will include all sales and orders associated with this Contract from Customers received during the reporting period. Initiation and submission of the Sales Report is the responsibility of the Contractor without prompting or notification from the DMS Contract Manager. Failure to provide the quarterly sales report will result in the imposition of financial consequences and may result in the Contractor being found in default and the termination of the Contract. Initiation and submission of the quarterly sales report are the responsibility of the Contractor without prompting or notification by the Department. Sales will be reviewed on a quarterly basis. If no sales are recorded during the period, the Contractor must submit a report stating that there was no activity. If no sales are recorded in two consecutive quarters, the Contractor may be placed in probationary status or the Department may terminate the Contract. Quarter 1 – (July-September) – due 30 calendar days after the close of the period Quarter 2 – (October-December) – due 30 calendar days after the close of the period Quarter 3 – (January-March) – due 30 calendar days after the close of the period Quarter 4 – (April-June) due 30 calendar days after the close of the period Exceptions may be made if a delay in submitting reports is attributable to circumstances that are clearly beyond the control of the Contractor. The burden of proof of unavoidable delay shall rest with the Contractor and shall be supplied in a written form and submitted to the Department. The Department reserves the right to request additional sales information as needed.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Quarterly Contractor Performance Reporting Customers shall complete a Contractor Performance Survey (Exhibit I) for each Contractor on a Quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated in Contract Exhibit D, Section 17, Additional Special Contract Conditions. The completed Contractor Performance Survey(s) will be used by the Department as a performance-reporting tool to measure the performance of Contractors. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MyFloridaMarketPlace or on the Department's website).
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Product Returns Client will have the responsibility for handling customer returns of the Products. Patheon will give Client any assistance that Client may reasonably require to handle the returns.
