Environmental Inspection at End of Agreement Term A. At Authority’s discretion, at least one hundred and twenty (120) days before the expiration or early termination of the Term as provided herein, Company will conduct an environmental inspection and examination of the Company Premises. At its discretion, Authority may complete environmental reviews to determine if recognized environmental conditions exist that could warrant soil and groundwater sampling. If warranted by the findings of Company or Authority’s inspection or if requested by Authority, a compliance audit or site assessment will be performed within the aforementioned time period by a qualified professional acceptable to Authority who will report the findings to Authority. The cost for professional consulting or engineering services required for such audit will be at the expense of Company. If a site assessment is conducted, Company agrees to pay all associated laboratory and testing fees incurred to test and analyze samples collected during the site assessment process. The Authority may also choose to conduct the compliance audit or site assessment. If the results of the assessment indicate that the Company Premises have been impacted by the release of Hazardous Substances, Company will immediately take such action as is necessary and will provide a substantial guaranty in a form and content acceptable to Authority that Company will clean up the contamination at its own expense, at no expense to Authority, and in accordance with Applicable Laws to the extent that it is obligated to do so by virtue of the foregoing provisions of this Article.
Response/Compliance with Audit or Inspection Findings A. Grantee must act to ensure its and its Subcontractors’ compliance with all corrections necessary to address any finding of noncompliance with any law, regulation, audit requirement, or generally accepted accounting principle, or any other deficiency identified in any audit, review, or inspection of the Contract and the services and Deliverables provided. Any such correction will be at Grantee’s or its Subcontractor's sole expense. Whether Xxxxxxx's action corrects the noncompliance shall be solely the decision of the System Agency.
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Inspection Checklist (check one) ☐ In order to avoid disagreements about the condition of the Premises, at the time of accepting possession of the Premises, Tenant will complete the Inspection Checklist incorporated herein by reference and attached hereto as Exhibit B and record any damage or deficiencies that exist at the commencement of the Term. Landlord will be liable for the cost of any cleaning or repair to correct damages found at the time of the inspection. Tenant will be liable for the cost of any cleaning and/or repair to correct damages found at the end of the Term if not recorded on the inspection checklist, normal wear and tear excepted. ☐ The Tenant is NOT required to complete an inspection checklist.
Project Reports; Completion Report 1. The Recipient shall monitor and evaluate the progress of the Project and prepare Project Reports in accordance with the provisions of Section 2.06 of the Standard Conditions and on the basis of indicators agreed with the World Bank. Each Project Report shall cover the period of one (1) calendar semester, and shall be furnished to the World Bank not later than one (1) month after the end of the period covered by such report.
Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.
Search, Enquiry, Investigation, Examination And Verification a. The Property is sold on an “as is where is basis” subject to all the necessary inspection, search (including but not limited to the status of title), enquiry (including but not limited to the terms of consent to transfer and/or assignment and outstanding charges), investigation, examination and verification of which the Purchaser is already advised to conduct prior to the auction and which the Purchaser warrants to the Assignee has been conducted by the Purchaser’s independent legal advisors at the time of execution of the Memorandum.
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
OIG INSPECTION, AUDIT, AND REVIEW RIGHTS In addition to any other rights OIG may have by statute, regulation, or contract, OIG or its duly authorized representative(s) may conduct interviews, examine or request copies of Xxxxxx’x books, records, and other documents and supporting materials and/or conduct on-site reviews of any of Xxxxxx’x locations for the purpose of verifying and evaluating: (a) Xxxxxx’x compliance with the terms of this IA and (b) Xxxxxx’x compliance with the requirements of the Federal health care programs. The documentation described above shall be made available by Xxxxxx to OIG or its duly authorized representative(s) at all reasonable times for inspection, audit, and/or reproduction. Furthermore, for purposes of this provision, OIG or its duly authorized representative(s) may interview Xxxxxx and any of Xxxxxx’x employees or contractors who consent to be interviewed at the individual’s place of business during normal business hours or at such other place and time as may be mutually agreed upon between the individual and OIG. Xxxxxx shall assist OIG or its duly authorized representative(s) in contacting and arranging interviews with such individuals upon OIG’s request. Xxxxxx’x employees and contractors may elect to be interviewed with or without a representative of Xxxxxx present.
SITE VISITS AND RECORD REVIEW The Applicant shall allow authorized employees of the District, the Comptroller, the Appraisal District, and the State Auditor’s Office to have reasonable access to the Applicant’s Qualified Property and business records from the Application Review Start Date through the Final Termination Date, in order to inspect the project to determine compliance with the terms hereof or as necessary to properly appraise the Taxable Value of the Applicant’s Qualified Property.
