Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):
2.2.1.1 Payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in Section 3.1 of this Tenant Work Letter, the costs of Tenant’s project manager (if any) and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter;
2.2.1.2 The payment of plan check, permit and license fees relating to construction of the Tenant Improvements;
2.2.1.3 The cost of construction of the Tenant Improvements, including, without limitation, contractors’ fees and general conditions, testing and inspection costs, costs of utilities, trash removal, parking and hoists, and the costs of after-hours freight elevator usage.
2.2.1.4 The cost of any changes in the Base, Shell and Core work when such changes are required by the Construction Drawings (including if such changes are due to the fact that such work is prepared on an unoccupied basis), such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith;
2.2.1.5 The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”);
2.2.1.6 Sales and use taxes;
2.2.1.7 The “Coordination Fee,” as that term is defined in Section 4.2.2.2 of this Tenant Work Letter; and
2.2.1.8 All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements.
Construction Allowance (a) Landlord shall provide to Tenant a construction allowance not to exceed $135.00 per rentable square foot in the Relocation Premises (the “Construction Allowance”) to be applied toward the Total Construction Costs, as adjusted for any changes to the Tenant Work. If the Total Construction Costs are estimated to exceed the Construction Allowance by more than $5.00 per rentable square foot of the Relocation Premises, then no advance of the Construction Allowance shall be made by Landlord until Tenant has first paid to the contractor from its own funds (and provided reasonable evidence thereof to Landlord) the anticipated amount by which the projected Total Construction Costs exceed the amount of the Construction Allowance. Thereafter, Landlord shall pay to Tenant (or at Tenant’s request directly to Tenant’s general contractor) the Construction Allowance in multiple disbursements (but not more than once in any calendar month) following the receipt by Landlord of the following items: (i) a request for payment and sworn statements of Tenant and contractor, (ii) final or partial lien waivers, as the case may be, from all persons performing work or supplying or fabricating materials for the Tenant Work, fully executed, acknowledged and in recordable form, which waivers may be conditioned upon receipt of payment, (iii) the Architect’s certification that the Tenant Work for which reimbursement has been requested has been finally completed, including (with respect to the last application for payment only) any punch-list items, on the appropriate AIA form or another form approved by Landlord, and, (iv) with respect to the disbursement of the last 10% of the Construction Allowance, (1) the permanent certificate of occupancy issued for the Relocation Premises, if required by applicable law, (2) the record drawing in CAD format, PDF format and hard copy required by Section 5 above, and (3) an estoppel certificate confirming such factual matters as Landlord or Landlord’s Mortgagee may reasonably request (collectively, a “Completed Application for Payment”). Landlord shall pay the amount requested in the applicable Completed Application for Payment to Tenant within 30 days following Tenant’s submission of the Completed Application for Payment. If, however, the Completed Application for Payment is incomplete or incorrect, Landlord shall promptly notify Tenant of the same and Landlord’s payment of such request shall be deferred until 30 days following Landlord’s receipt of the corrected Completed Application for Payment. Notwithstanding anything to the contrary contained in this Exhibit, Landlord shall not be obligated to make any disbursement of the Construction Allowance during the pendency of any of the following: (1) Landlord has received written notice of any unpaid claims relating to any portion of the Tenant Work or materials in connection therewith covered by previously funded applications for payment, (2) there is an unbonded lien outstanding against the Building or the Relocation Premises or Tenant’s interest therein by reason of work done, or claimed to have been done, or materials supplied or specifically fabricated, claimed to have been supplied or specifically fabricated, to or for Tenant or the Relocation Premises, (3) the conditions to the advance of the Construction Allowance are not satisfied, or (4) Tenant is in Default under the Lease.
(b) The Construction Allowance must be used on Tenant Work performed within the Relocation Premises and the Total Construction Costs and may not be used to pay for furniture, fixtures or equipment or as rent abatement, HOWEVER, notwithstanding the foregoing, provided Tenant is not in Default, Tenant may use a portion of the Construction Allowance, not to exceed an amount equal to $35.00 per rentable square foot of the Relocation Premises, to pay for furniture, fixtures or equipment, moving costs, cabling costs, and other soft costs associated with the Relocation Premises. Should Tenant elect to use a portion of the Construction Allowance to pay for such soft costs, at Landlord’s request Tenant shall execute and deliver a letter to Landlord confirming the exact amount of the Construction Allowance used to pay for such soft costs. Should Tenant elect to use a portion of the Construction Allowance to pay for such costs, Tenant shall provide Landlord with a written request that includes copies of paid invoices or receipts for reimbursement of such costs, and Landlord shall reimburse Tenant for such amounts within 30 days of receipt of Tenant’s request. Tenant shall provide lien waivers as appropriate. No portion of the Construction Allowance may be used as a credit against Rent due under the Lease.
(c) The Construction Allowance must be used (i.e. work performed and invoices submitted to Landlord) by June 30, 2020, or the Construction Allowance shall be deemed forfeited with no further obligation by Landlord with respect thereto.
(d) If Landlord defaults in Landlord’s obligation to pay the Construction Allowance pursuant to Section 9 of this Exhibit B-1, or any portion thereof, within five (5) days after the date the same is due, then Tenant shall have the right to give Landlord a second written notice (“Offset Exercise Notice”) requesting payment of such unpaid amounts and notifying Landlord that Tenant intends to offset against rent if not paid. In the event that Landlord fails to contest in good faith or fully pay such amounts within ten (10) business days after such Offset Exercise Notice is received by Landlord, then provided no Default exists Tenant may withhold and offset such unpaid sums from and against 25% of Base Rent next due until paid.
Landlord’s Expenses In the event Tenant shall assign this Lease or sublet the Premises or request the consent of Landlord to any Transfer, then Tenant shall pay Landlord's reasonable costs and expenses incurred in connection therewith, including, but not limited to, attorneys', architects', accountants', engineers' or other consultants' fees.
Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted at the end of each design phase in accordance with this Agreement. The Construction Cost Budget does not include the compensation of the Architect and the Architect’s Consultants, the cost of land, rights-of-way, financing or other costs which are the responsibility of the District, including construction management.
Improvement Allowance a. Landlord shall contribute the Improvement Allowance towards the Improvement Costs in accordance with the terms of this Section. All Improvement Costs incurred by Landlord shall be deducted from the Improvement Allowance, and applied by Landlord to pay the Improvement Costs, as such costs are incurred. The Improvement Allowance shall remain available to be used by Tenant through October 31, 2014 (the “Allowance Expiration Date”). Any portion of the Improvement Allowance remaining undisbursed after the Allowance Expiration Date shall be retained by Landlord and Tenant shall not be entitled to any payment, Rent reduction or offset for any unused part of the Improvement Allowance. In no event shall Landlord be obligated to expend more than the Improvement Allowance.
b. Prior to commencement of construction of any Initial Improvements, Landlord shall submit to Tenant a written estimate (the “Estimate”) of the Improvement Costs. The Estimate shall include “allowance(s),” defined as an estimate of cost for an item of work not sufficiently defined in the documents to allow a fixed price to be obtained by the general contractor for which the Improvement Costs are to be increased or decreased, respectively, by the precise amount that the actual cost of the allowance item is either in excess of or less than the amount of the allowance for that item. Tenant shall approve the Estimate in writing within five (5) business days of Tenant’s receipt thereof. If Tenant does not approve or disapprove the Estimate in writing within said period, Tenant shall be deemed to have approved the Estimate. Landlord shall be under no obligation to construct any of the Initial Improvements until Tenant has expressly approved the Estimate.
c. If based on the Estimate, the Improvement Costs will exceed the Improvement Allowance, then prior to commencement of construction of any Initial Improvements, Tenant shall pay to Landlord one hundred percent (100%) of such projected excess amount. Landlord shall keep Tenant reasonably informed with respect to construction progress of the Initial Improvements, the occupancy of the Premises by Tenant and costs thereof. Landlord shall submit to Tenant monthly progress statements illustrating the cost to date of constructing the Initial Improvements. The statements of costs submitted to Landlord by Landlord’s contractors shall be conclusive for purposes of determining the actual cost of the items described therein. The amounts payable by Tenant hereunder constitute Rent payable pursuant to the Lease, and the failure to timely pay same constitutes a Default by Tenant as if Tenant shall have failed to pay Rent. Within ten (10) days after submission by Landlord of the foregoing statement, Tenant shall pay Landlord the amount, as set forth in such notice, by which the Improvement Costs exceeds the Improvement Allowance plus any amount previously paid by Tenant to Landlord. Landlord shall not disburse the Improvement Allowance until after Landlord disburses funds paid by Tenant for excess costs and provided that the Improvement Allowance is estimated to be sufficient to pay all remaining costs. Landlord shall disburse first the funds paid by Tenant and then the Improvement Allowance directly to the general contractor and to suppliers and subcontractors as Landlord deems appropriate. As soon as reasonably practical upon completion of the Initial Improvements, Landlord shall prepare and submit to Tenant a statement showing, in reasonable detail an accounting for the Improvement Costs and the total amount payable hereunder by Landlord to Tenant or Tenant to Landlord. Within ten (10) days after submission by Landlord of the foregoing statement, Tenant shall pay Landlord the amount, as set forth in such notice, by which the Improvement Costs exceeded the Improvement Allowance and any funds previously paid by Tenant to Landlord. If the Improvement Costs are less than the Improvement Allowance and any funds previously paid by Tenant to Landlord, then the excess funds previously paid by Tenant to Landlord shall be used to offset Base Rent; and Tenant shall not be entitled to any payment, Rent reduction or offset for any unused part of the Improvement Allowance.
d. After the Improvement Allowance has been expended by Landlord, the principal amount of the Improvement Allowance, together with interest thereon calculated at the Default Rate, shall be amortized evenly over the Term, and so long as Tenant does not default in its monetary obligations under the Lease, and fail to cure such default within the applicable period of cure, if any, provided under this Lease, then the balance of the Improvement Allowance shall be reduced each month by the principal amount amortized each month, and upon Landlord’s receipt of the final payment of Rent due during the initial Term of this Lease, Tenant shall have no liability to Landlord for the repayment of any portion of the Improvement Allowance or the interest that accrued and was amortized over the initial Term of this Lease. In the event of an uncured Default by Tenant under this Lease, then in addition to all of Landlord’s other remedies available under this Lease, Tenant shalt also be liable to Landlord for the entire unreduced principal balance of the Improvement Allowance remaining as of the date of default, and interest on such balance shall accrue at the Default Rate.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
LANDLORD'S LIABILITY If Landlord defaults under this Agreement and if, as a consequence of such default, Tenant shall recover a money judgment against Landlord, such judgment shall be satisfied against the right, title and interest of Landlord in the Shopping Center including, but not limited to, the rents, proceeds and profits derived therefrom as the same may then be constituted and encumbered, and Landlord shall not be liable for any deficiency. In no event shall Tenant have the right to levy execution against any property of Landlord other than its right, title and interest in the Shopping Center including, but not limited to, the rents, proceeds and profits derived therefrom. Upon any such uncured default by Landlord, Tenant may exercise any of its rights provided at law or in equity; provided, however: (a) Tenant shall have no right to offset or xxxxx rent in the event of any default by Landlord under this Agreement, except to the extent offset rights are specifically provided to Tenant in this Agreement; (b) Tenant shall have no right to terminate this Agreement unless determined by a court of competent jurisdiction under applicable law taking into account the nature of the breach; and (c) Tenant’s rights and remedies hereunder shall be limited to the extent this Agreement otherwise expressly limits Tenant’s rights or remedies. Notwithstanding anything contained in this Agreement to the contrary, the obligations of Landlord under this Agreement (including any actual or alleged breach or default by Landlord) do not constitute personal obligations of the individual partners, directors, officers, members or shareholders of Landlord or Landlord’s partners, and Tenant shall not seek recourse against the individual partners, directors, officers, members or shareholders of Landlord or against Landlord’s partners or any other persons or entities having any interest in Landlord, or any of their personal assets for satisfaction of any liability with respect to this Agreement. Notwithstanding anything contained in this Agreement to the contrary, in no event shall Landlord or any Landlord’s officers, trustees, directors, partners, beneficiaries, joint venturers, members, stockholders, or other principals or representatives, disclosed or undisclosed (and their respective successors and assigns) ever be liable pursuant to this Agreement for lost profits or consequential, speculative or punitive damages.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
Improvements and Alterations (a) The Lessee, at the Lessee’s own cost and expense, (i) shall make alterations, renovations, repairs, improvements and additions to the Leased Property or any part thereof and substitutions and replacements therefor (collectively, “Alterations”) which are (A) necessary to repair or maintain the Improvements or the Site in the condition required by Section 9.1 or (B) necessary or advisable to restore the Improvements and the Site to its condition existing prior to a Casualty or Condemnation to the extent required pursuant to Article XIII, and (ii) so long as no Material Default or Event of Default has occurred and is continuing, may undertake Alterations on the Leased Property so long as such Alterations comply in all material respects with Applicable Laws and are consistent and comply with Section 9.1 and subsection (b) of this Section 9.2.
(b) The making of any Alterations pursuant to subsection (a)(i) above of this Section 9.2 must be in compliance with the following requirements: The Lessee shall not make any Alterations in violation of the terms of any restriction, easement, condition, covenant or other similar matter affecting title to or binding on the Improvements or the Site.
(i) No Alterations shall be undertaken until the Lessee shall have procured and paid for, so far as the same may be required from time to time, all permits and authorizations relating to such Alterations of all municipal and other Authorities having jurisdiction over the Improvements or the Site. Lessor, at the Lessee’s expense, shall join in the application for any such permit or authorization and execute and deliver any document in connection therewith, whenever such joinder is necessary or advisable; provided that, however, such joinder shall not constitute or be deemed to constitute, any assumption or responsibility or liability whatsoever.
(ii) The Alterations shall be completed in a good and workmanlike manner and in compliance in all material respects with all Applicable Laws then in effect and with the Insurance Requirements.
(iii) All Alterations shall, when completed, be of such a character as to not materially diminish (A) the utility of the Improvements as a corporate office complex including a corporate office building and any uses ancillary thereto, (B) the then current Fair Market Value as determined by reference to the Appraisal, or (C) the Fair Market Value as determined by reference to the Appraisal as of the scheduled expiration date of the Lease Term.
(iv) The Lessee shall have made adequate arrangements for payment of the cost of all Alterations when due so that the Improvements and the Site shall at all times be free of Liens for labor and materials supplied or claimed to have been supplied to the Improvements or the Site, other than Permitted Liens; provided, that the Lessee shall have the right to engage in Permitted Contests in accordance with Section 9.5.
(v) The Alterations must be located solely on the Site.
