Transfer of Servicing Between Master Servicer and Special Servicer; Record Keeping (a) Upon determining that any Serviced Loan has become a Specially Serviced Loan, the Master Servicer shall promptly give written notice thereof to the Special Servicer, any related Serviced Companion Loan Holder (in the case of a Serviced Loan Combination), the Operating Advisor, the Certificate Administrator, the Trustee, the related Directing Holder (prior to the occurrence and continuance of a Consultation Termination Event with respect to the related Mortgage Loan) and, for posting to the Rule 17g-5 Information Provider’s Website pursuant to Section 12.13 of this Agreement, the Rule 17g-5 Information Provider and shall promptly deliver a copy of the Servicing File to the Special Servicer and concurrently provide a copy of such Servicing File to the Operating Advisor and shall use its reasonable efforts to provide the Special Servicer with all information, documents (but excluding the original documents constituting the Mortgage File, but including copies thereof) and records (including records stored electronically on computer tapes, magnetic discs and the like) relating to such Serviced Loan and reasonably requested by the Special Servicer to enable it to assume its duties hereunder with respect thereto without acting through a Sub-Servicer. The Master Servicer shall use its reasonable efforts to comply with the preceding sentence within five (5) Business Days of the date such Serviced Loan became a Specially Serviced Loan and in any event shall continue to act as Master Servicer and administrator of such Serviced Loan until the Special Servicer has commenced the servicing of such Serviced Loan, which shall occur upon the receipt by the Special Servicer of the Servicing File. With respect to each such Serviced Loan that becomes a Specially Serviced Loan, the Master Servicer shall instruct the related Mortgagor to continue to remit all payments in respect of such Serviced Loan to the Master Servicer. The Master Servicer shall forward any notices it would otherwise send to the Mortgagor of such a Specially Serviced Loan to the Special Servicer who shall send such notice to the related Mortgagor. Upon determining that a Specially Serviced Loan has become a Corrected Loan, the Special Servicer shall promptly give written notice thereof to the Master Servicer, the Trustee, the Operating Advisor, the Certificate Administrator, any related Serviced Companion Loan Holder, the related Directing Holder (prior to the occurrence and continuance of a Consultation Termination Event with respect to the related Mortgage Loan) and, for posting to the Rule 17g-5 Information Provider’s Website pursuant to Section 12.13 of this Agreement, the Rule 17g-5 Information Provider and, upon giving such notice and the return of the Servicing File to the Master Servicer, such Serviced Loan shall cease to be a Specially Serviced Loan in accordance with the first proviso of the definition of Specially Serviced Loans, the Special Servicer’s obligation to service such Serviced Loan shall terminate and the obligations of the Master Servicer to service and administer such Serviced Loan as a Serviced Loan that is not a Specially Serviced Loan shall resume. In addition, if the related Mortgagor has been instructed, pursuant to the preceding paragraph, to make payments to the Special Servicer, upon such determination, the Special Servicer shall instruct the related Mortgagor to remit all payments in respect of such Specially Serviced Loan directly to the Master Servicer.
(b) In servicing any Specially Serviced Loan, the Special Servicer shall provide to the Custodian originals of documents included within the definition of “Mortgage File” for inclusion in the related Mortgage File (to the extent such documents are in the possession of the Special Servicer) and copies of any additional related Serviced Loan information, including correspondence with the related Mortgagor, and the Special Servicer shall promptly provide copies of all of the foregoing to the Master Servicer as well as copies of any analysis or internal review prepared by or for the benefit of the Special Servicer.
(c) Notwithstanding the provisions of subsections (a) and (b) of this Section 3.22, the Master Servicer shall maintain ongoing payment records with respect to each of the Specially Serviced Loans and, upon request, shall provide the Special Servicer and the Operating Advisor with any information reasonably required by the Special Servicer or the Operating Advisor to perform its duties under this Agreement to the extent such information is within the Master Servicer’s possession. Upon request, the Special Servicer shall provide the Master Servicer and the Operating Advisor with any information reasonably required by the Master Servicer or the Operating Advisor to perform its duties under this Agreement to the extent such information is within the Special Servicer’s possession.
Construction Bonds, Insurance and Supervision (i) The Recipient shall require that each of its Contractors furnish a performance and payment bond in an amount at least equal to 100 percent (100%) of its contract price as security for the faithful performance of its contract.
(ii) The Recipient shall require that each of its construction contractors and each subcontractor maintain during the life of its contract or subcontract appropriate Workers Compensation Insurance, Public Liability, Property Damage and Vehicle Liability Insurance.
(iii) The Recipient shall provide and maintain competent and adequate project management covering the supervision and inspection of the development and construction of the Project and bearing the responsibility of ensuring that construction conforms with the approved surveys, plans, profiles, cross sections and specifications and certifying to the OPWC and the Recipient at the completion of construction that construction is in accordance with the approved surveys, plans, profiles, cross sections and specifications or approved amendments thereto.
Construction Representatives Landlord appoints the following person(s) as Landlord's representative ("Landlord's Representative") to act for Landlord in all matters covered by this Work Letter: ------------------------ ------------------------ ------------------------ Tenant appoints the following person(s) as Tenant's representative ("Tenant Representative") to act for Tenant in all matters covered by this Work Letter. ------------------------ ------------------------ ------------------------ All communications with respect to the matters covered by this Work Letter are to be made to Landlord's Representative or Tenant's Representative, as the case may be, in writing, in compliance with the notice provisions of the Lease. Either party may change its representative under this Work Letter at any time by written notice to the other party in compliance with the notice provisions of the Lease.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Lost Shareholder Due Diligence Searches and Servicing The Trust hereby acknowledges that USBFS has an arrangement with an outside vendor to conduct lost shareholder searches required by Rule 17Ad-17 under the Securities Exchange Act of 1934, as amended. Costs associated with such searches will be passed through to the Trust as an out-of-pocket expense in accordance with the fee schedule set forth in Exhibit C hereto. If a shareholder remains lost and the shareholder’s account unresolved after completion of the mandatory Rule 17Ad-17 search, the Trust hereby authorizes vendor to enter, at its discretion, into fee sharing arrangements with the lost shareholder (or such lost shareholder’s representative or executor) to conduct a more in-depth search in order to locate the lost shareholder before the shareholder’s assets escheat to the applicable state. The Trust hereby acknowledges that USBFS is not a party to these arrangements and does not receive any revenue sharing or other fees relating to these arrangements. Furthermore, the Trust hereby acknowledges that vendor may receive up to 35% of the lost shareholder’s assets as compensation for its efforts in locating the lost shareholder.
CONCERNING CUSTODIAN (a) The Custodian shall be held to a standard of reasonable care in carrying out the provisions of this Agreement; provided, however, that the Custodian shall be held to different standard of care of imposed by any other provision of this Agreement or imposed upon Custodian by any applicable law or regulation, which by its terms cannot be contractually modified or waived. Except as otherwise expressly provided herein, Custodian shall not be liable for any costs, expenses, damages, liabilities or claims, including attorneys' and accountants' fees (collectively, “Losses”), incurred by or asserted against the Fund, except those Losses arising out of Custodian's own negligence or willful misconduct. Custodian shall have no liability whatsoever for the action or inaction of any Depositories or of any Foreign Depositories, except in each case to the extent such action or inaction is a direct result of the Custodian' s failure to fulfill its duties hereunder. With respect to any Losses incurred by the Fund as a result of the acts or any failures to act by any Subcustodian (other than a BNY Affiliate), Custodian shall take appropriate action to recover such Losses from such Subcustodian; and Custodian's sole responsibility and liability to the Fund shall be limited to amounts so received from such Subcustodian ( exclusive of costs and expenses incurred by Custodian). In no event shall Custodian be liable to the Fund or any third party for special, indirect or consequential damages, or lost profits or loss of business, arising in connection with this Agreement, nor shall Custodian or any Subcustodian be liable: (i) for acting in accordance with any Certificate or Oral Instructions actually received by Custodian and reasonably believed by Custodian to be given by an Authorized Person; (ii) for acting in accordance with Instructions without reviewing the same; (iii) for conclusively presuming that all Instructions are given only by person(s) duly authorized; (00 for conclusively presuming that all disbursements of cash directed by the Fund, whether by a Certificate, an Oral Instruction, or an Instruction, are in accordance with Section 2(i) of Article II hereof; (y) for holding property in any particular country, including, but not limited to, Losses resulting from nationalization, expropriation or other governmental actions; regulation of the banking or securities industry; exchange or currency controls or restrictions, devaluations or fluctuations; availability of cash or Securities or market conditions which prevent the transfer of property or execution of Securities transactions or affect the value of property; (yi) for any Losses due to forces beyond the control of Custodian, including without limitation strikes, work stoppages, acts of war or terrorism, insurrection, revolution, nuclear or natural catastrophes or acts of God, or interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; (yii) for the insolvency of any Subcustodian (other than a BNY Affiliate), any Depository, or, except to the extent such action or inaction is a direct result of the Custodian's failure to fulfill its duties hereunder, any Foreign Depository; or (yiii)l for any Losses arising from the applicability of any law or regulation now or hereafter in effect, or from the occurrence of any event, including, without limitation, implementation or adoption of any rules or procedures of a Foreign Depository, which may affect, limit prevent or impose costs or burdens on, the transferability, convertibility, or availability of any currency or Composite Currency Unit in any country or on the transfer of any Securities, and in no event shall Custodian be obligated to substitute another currency for a currency (including a currency that is a component of a Composite Currency Unit) whose transferability, convertibility or availability has been affected, limited, or prevented by such law, regulation or event and to the extent that any such law, regulation or event imposes a cost or charge upon Custodian in relation to the transferability, convertibility, or availability of any cash currency or Composite Currency Unit, such cost or charge shall be for the account of the Fund, and Custodian may treat any account denominated in an affected currency as a group of separate accounts denominated in the relevant component currencies.
(b) Custodian may enter into subcontracts, agreements and understandings with any BNY Affiliate, whenever and on such terms and conditions as it deems necessary or appropriate to perform its services hereunder. No such subcontract, agreement or understanding shall discharge Custodian from its obligations hereunder.
(c) The Fund agrees to indemnify Custodian and hold Custodian harmless from and against any and all Losses sustained or incurred by or asserted against Custodian by reason of or as a result of any action or inaction, or arising out of Custodian's performance hereunder, including reasonable fees and expenses of counsel incurred by Custodian in a successful defense of claims by the Fund; provided however, that the Fund shall not indemnify Custodian for those Losses arising out of Custodian's own negligence or willful misconduct. This indemnity shall be a continuing obligation of the Fund, its successors and assigns, notwithstanding the termination of this Agreement.
2. Without limiting the generality of the foregoing, Custodian sep be under no obligation to inquire into, and shall not be liable for:
(a) Any Losses incurred by the Fund or any other person as a result of the receipt or acceptance of fraudulent, forged or invalid Securities, or Securities which are otherwise not freely transferable or deliverable without encumbrance in any relevant market;
(b) The validity of the issue of any Securities purchased, sold, or written by or for the Fund, the legality of the purchase, sale or writing thereof, or the propriety of the amount paid or received therefor;
(c) The legality of the sale or redemption of any Shares, or the propriety of the amount to be received or paid therefor;
(d) The legality of the declaration or payment of any dividend or distribution by the Fund;
(e) The legality of any borrowing by the Fund;
(f) The legality of any loan of portfolio Securities, nor shall Custodian be under any duty or obligation to see to it that any cash or collateral delivered to it by a broker, dealer or financial institution or held by it at any time as a result of such loan of portfolio Securities is adequate security for the Fund against any loss it might sustain as a result of such loan, which duty or obligation shall be the sole responsibility of the Fund. In addition, Custodian shall be under no duty or obligation to see that any broker, dealer or financial institution to which portfolio Securities of the Fund are lent makes payment to it of any dividends or interest which are payable to or for the account of the Fund during the period of such loan or at the termination of such loan, provided, however that Custodian shall promptly notify the Fund in the event that such dividends or interest are not paid and received when due;
(g) The sufficiency or value of any amounts of money and/or Securities held in any Special Account in connection with transactions by the Fund; whether any broker, dealer, futures commission merchant or clearing member makes payment to the Fund of any variation margin payment or similar payment which the Fund may be entitled to receive from such broker, dealer, futures commission merchant or clearing member, or whether any payment received by Custodian from any broker, dealer, futures commission merchant or clearing member is the amount the Fund is entitled to receive, or to notify the Fund of Custodian's receiptor non-receipt of any such payment; or
(h) Whether any Securities at any time delivered to, or held by it or by any Subcustodian, for the account of a Fund are such as properly may be held by the Fund under the provisions of its then current prospectus and statement of additional information, or to ascertain whether any transactions by the Fund, whether or not involving Custodian, are such transactions as may properly be engaged in by the Fund.
3. Custodian may, with respect to questions of law specifically regarding an Account, obtain the advice and opinion of counsel to the independent trustees of a Fund or other counsel that is mutually agreed upon by the Funds and the Custodian and shall be fully protected with respect to anything done or omitted by it in good faith in conformity with such advice.
4. Custodian shall be under no obligation to take action to collect any amount payable on Securities in default, or if payment is refused after due demand and presentment.
5. Custodian shall have no duty or responsibility to inquire into, make recommendations, supervise, or determine the suitability of any transactions affecting any Account.
6. The Fund shall pay to Custodian the fees and charges as may be specifically agreed upon from time to time and such other fees and charges at Custodian's standard rates for such services as maybe applicable. The Fund shall reimburse Custodian for all costs associated with the conversion of the Fund's Securities hereunder and the transfer of Securities and records kept in connection with this Agreement. The Fund shall also reimburse Custodian, at cost, for out-of-pocket expenses which are a normal incident of the services provided hereunder.
7. Custodian has the right to debit any cash account for any amount payable by the Fund in connection with any and all obligations of the Fund to Custodian. In addition to the rights of Custodian under applicable law and other agreements, at any time when the Fund shall not have honored any of its obligations to Custodian, Custodian shall have the right without notice to the Fund to retain or set-off, against such obligations of the Fund, any Securities or cash Custodian or a BNY Affiliate may directly or indirectly hold for the account of the Fund, and any obligations (whether matured or unmatured) that Custodian or a BNY Affiliate may have to the Fund in any currency or Composite Currency Unit. Any such asset of, or obligation to, the Fund may be transferred to Custodian and any BNY Affiliate in order to effect the above rights.
8. The Fund agrees to forward to Custodian a Certificate or Instructions confirming Oral Instructions by the close of business of the same day that such Oral Instructions are given to Custodian. The Fund agrees that the fact that such confirming Certificate or Instructions are not received or that a contrary Certificate or contrary Instructions are received by Custodian shall in no way affect the validity or enforceability of transactions authorized by such Oral Instructions and effected by Custodian. If the Fund elects to transmit Instructions through an on-line communications system offered by Custodian, the Fund's use thereof shall be subject to the Terms and Conditions attached as Appendix J hereto, and Custodian shall provide user and authorization codes, passwords and authentication keys only to an Authorized Person or a person reasonably believed by Custodian to be an Authorized Person.
9. The books and records pertaining to the Fund which are in possession of Custodian shall be the property of the Fund. Such books and records shall be prepared and maintained as required by the '40 Act and the rules thereunder. The Fund, or its authorized representatives, shall have access to such books and records during Custodian's normal business hours. Upon the reasonable request of the Fund, copies of any such books and records shall be provided by Custodian to the Fund or its authorized representative. Upon the reasonable request of the Fund, Custodian shall provide in hard copy or on computer disc any records included in any such delivery which are maintained by Custodian on a computer disc, or are similarly maintained.
10. It is understood that Custodian is authorized to supply any information regarding the Accounts which is required by any law, regulation or rule now or hereafter in effect. The Custodian shall provide the Fund with any report obtained by the Custodian on the system of internal accounting control of a Depository, and with such reports on its own system of internal accounting control as the Fund may reasonably request from time to time.
11. Custodian shall have no duties or responsibilities whatsoever except such duties and responsibilities as are specifically set forth in this Agreement, and no covenant or obligation shall be implied against Custodian in connection with this Agreement.
Sub-Advisor Compliance Policies and Procedures The Sub-Advisor shall promptly provide the Trust CCO with copies of: (i) the Sub-Advisor’s policies and procedures for compliance by the Sub-Advisor with the Federal Securities Laws (together, the “Sub-Advisor Compliance Procedures”), and (ii) any material changes to the Sub-Advisor Compliance Procedures. The Sub-Advisor shall cooperate fully with the Trust CCO so as to facilitate the Trust CCO’s performance of the Trust CCO’s responsibilities under Rule 38a-1 to review, evaluate and report to the Trust’s Board of Trustees on the operation of the Sub-Advisor Compliance Procedures, and shall promptly report to the Trust CCO any Material Compliance Matter arising under the Sub-Advisor Compliance Procedures involving the Sub-Advisor Assets. The Sub-Advisor shall provide to the Trust CCO: (i) quarterly reports confirming the Sub-Advisor’s compliance with the Sub-Advisor Compliance Procedures in managing the Sub-Advisor Assets, and (ii) certifications that there were no Material Compliance Matters involving the Sub-Advisor that arose under the Sub-Advisor Compliance Procedures that affected the Sub-Advisor Assets. At least annually, the Sub-Advisor shall provide a certification to the Trust CCO to the effect that the Sub-Advisor has in place and has implemented policies and procedures that are reasonably designed to ensure compliance by the Sub-Advisor with the Federal Securities Laws.
CERTIFICATION REGARDING USE OF CONTRACT FUNDS FOR LOBBYING This provision is applicable to all Federal-aid construction contracts and to all related subcontracts which exceed $100,000 (49 CFR 20).
1. The prospective participant certifies, by signing and submitting this bid or proposal, to the best of his or her knowledge and belief, that:
a. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.
b. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any Federal agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form-LLL, "Disclosure Form to Report Lobbying," in accordance with its instructions.
2. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by 31 U.S.C. 1352. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.
3. The prospective participant also agrees by submitting its bid or proposal that the participant shall require that the language of this certification be included in all lower tier subcontracts, which exceed $100,000 and that all such recipients shall certify and disclose accordingly. This provision is applicable to all Federal-aid projects funded under the Appalachian Regional Development Act of 1965.
1. During the performance of this contract, the contractor undertaking to do work which is, or reasonably may be, done as on-site work, shall give preference to qualified persons who regularly reside in the labor area as designated by the DOL wherein the contract work is situated, or the subregion, or the Appalachian counties of the State wherein the contract work is situated, except:
a. To the extent that qualified persons regularly residing in the area are not available.
b. For the reasonable needs of the contractor to employ supervisory or specially experienced personnel necessary to assure an efficient execution of the contract work.
c. For the obligation of the contractor to offer employment to present or former employees as the result of a lawful collective bargaining contract, provided that the number of nonresident persons employed under this subparagraph (1c) shall not exceed 20 percent of the total number of employees employed by the contractor on the contract work, except as provided in subparagraph (4) below.
2. The contractor shall place a job order with the State Employment Service indicating (a) the classifications of the laborers, mechanics and other employees required to perform the contract work, (b) the number of employees required in each classification, (c) the date on which the participant estimates such employees will be required, and (d) any other pertinent information required by the State Employment Service to complete the job order form. The job order may be placed with the State Employment Service in writing or by telephone. If during the course of the contract work, the information submitted by the contractor in the original job order is substantially modified, the participant shall promptly notify the State Employment Service.
3. The contractor shall give full consideration to all qualified job applicants referred to him by the State Employment Service. The contractor is not required to grant employment to any job applicants who, in his opinion, are not qualified to perform the classification of work required.
4. If, within one week following the placing of a job order by the contractor with the State Employment Service, the State Employment Service is unable to refer any qualified job applicants to the contractor, or less than the number requested, the State Employment Service will forward a certificate to the contractor indicating the unavailability of applicants. Such certificate shall be made a part of the contractor's permanent project records. Upon receipt of this certificate, the contractor may employ persons who do not normally reside in the labor area to fill positions covered by the certificate, notwithstanding the provisions of subparagraph (1c) above.
5. The provisions of 23 CFR 633.207(e) allow the contracting agency to provide a contractual preference for the use of mineral resource materials native to the Appalachian region.
6. The contractor shall include the provisions of Sections 1 through 4 of this Attachment A in every subcontract for work which is, or reasonably may be, done as on-site work.
Geotechnical Engineer « »« » « » « » « » « »
Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.
