Buyer’s Check Meters Sample Clauses

Buyer’s Check Meters. At Buyer’s option, Buyer may install, own and operate Electric Metering Devices at the Point of Delivery (“Buyer’s Check Meters”). Seller shall, and shall cause each of its contractors and Subcontractors to grant access to Buyer to the Buyer’s Check Meters during normal working hours and subject to Seller’s and Seller’s contractors’ and/or Subcontractors’ reasonable safety requirements and procedures. Commencing on the first date on which Facility Energy is received from the Facility, and continuing throughout the Delivery Term, Buyer shall provide to Seller on a real-time basis read- only access to Buyer’s Check Meters. Buyer’s Check Meters shall be for check purposes only and shall not be used for the measurement of Facility Energy, except as provided in Section 11.4(e) above. The installation, operation and maintenance of Buyer’s Check Meters shall be performed entirely by Buyer or its agent at Buyer’s sole cost and expense.
Sample 1
AutoNDA by SimpleDocs

Related to Buyer’s Check Meters

  • Check Meters Developer, at its option and expense, may install and operate, on its premises and on its side of the Point of Interconnection, one or more check meters to check Connecting Transmission Owner’s meters. Such check meters shall be for check purposes only and shall not be used for the measurement of power flows for purposes of this Agreement, except as provided in Article 7.4 below. The check meters shall be subject at all reasonable times to inspection and examination by Connecting Transmission Owner or its designee. The installation, operation and maintenance thereof shall be performed entirely by Developer in accordance with Good Utility Practice.

  • Delivery Schedule The scheduled months of delivery of the Aircraft are listed in the attached Table 1. Exhibit B describes certain responsibilities for both Customer and Boeing in order to accomplish the delivery of the Aircraft.

  • ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.

  • BUYER’S INITIALS Contractor may, in its sole discretion, choose to refund or credit the value of a change order, option, or amenity requested by Xxxxx(s) instead of making the proposed change. If Contractor shall fail to include any extras which have been ordered and paid for by Buyer(s), Contractor’s sole liability shall be to deduct the cost of any such extra from the total cost of the Property.

  • Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.

  • Seller’s Conditions The obligations of Seller at the Closing are subject, at the option of Seller, to the satisfaction or waiver at or prior to the Closing of the following conditions precedent:

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Outage Repair Standard In the event of an outage or trouble in any Service being provided by a Party hereunder, the Providing Party will follow Verizon’s standard procedures for isolating and clearing the outage or trouble.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Buyer’s Deliveries At the Closing, Buyer shall deliver the following to Seller:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!