RESPONSIBILITIES OF CITY City or its representative shall issue all communications to Contractor. City has the authority to request changes in the work in accordance with the terms of this Agreement and with the terms in Exhibit A – Scope of Work. City has the authority to stop work or to suspend any work.
Responsibilities of Contractor A. The Contractor shall perform all work on the described project as required by the Contract documents. The work to be performed includes the labor and services necessary to produce such replacement, and all materials, supplies, tools, transportation, equipment, and machinery required for replacement.
B. This project bid includes all materials, labor and equipment to complete the reconstruction and resurfacing of streets as outlined in the Project Manual for WWREYN - XXXXXXXX SANITARY SEWER - PHASE 1 dated March 25th, 2021 as outlined in Attachment A.
Responsibilities of Client a. Client shall exclusively retain the services of Consultant to perform the Scope of Work, in accordance with, and subject to, the other provisions of this Agreement.
b. Client shall provide access for Consultant and its subcontractors to the Site, and shall enter into access agreements with other third party property owners, as necessary for Consultant to complete the performance of the Scope of Work.
c. Client shall, as necessary to complete the Scope of Work: (i) cooperate and assist Consultant with the preparation and submittal, to PADEP, PAUSTIF, local governing authorities and others, of all information and documents including, without limitation, correspondence, notices, reports, data submittals, restrictive covenants, engineering and institutional controls, and the like; and (ii) implement and maintain any engineering or institutional controls.
d. Client shall transmit to Consultant copies of all documentation, correspondence, reports, and the like, sent or received by Client, regarding the Scope of Work at the Site.
e. Client shall make a good faith effort to minimize any and all interference with the progress of the Scope of Work if the Site is remodeled or otherwise modified. Client shall also make a good faith effort to place this condition on third parties that are not a party to this Agreement including, but not limited to, current owners, future owners, current operators, future operators, current lessees and future lessees.
Responsibilities of Customer 5.1 To the extent that the Supplier requires access to the Customer Site to perform the Services, the Customer shall provide such access during Normal Business Hours and to provide a suitable work environment to enable the Supplier to perform such Services subject to the Supplier complying with such internal policies and procedures of the Customer (including those relating to security and health and safety) as may be notified to the Supplier in writing from time to time.
5.2 The Customer shall co-operate with the Supplier in all matters relating to the Services and shall appoint a Representative (“Customer Representative”), who shall have authority to commit the Customer on all matters relating to the relevant Service.
5.3 The Customer agrees and acknowledges the terms of the applicable Licence Agreements, Customer Agreement and that such terms shall form part of this Agreement. For the avoidance of doubt, in the event the applicable Licence Agreements and/or Customer Agreement is not applicable to the Services being received or delivered by the Supplier to the Customer under this Agreement, such agreements shall not apply.
5.4 Customer shall;
(a) adhere to the Acceptable Use Policy;
(b) be a bona fide licenced user of all Third-Party Software used in the provision of the Services;
(c) co-operate with the Supplier in all matters relating to the Services as reasonably requested by the Supplier;
(d) adhere to the dates scheduled for provision of Services by the Supplier to the Customer as stated in the applicable Statement of Work or otherwise agreed between the Parties in writing. In the event the Customer wishes to reschedule or cancel the dates for the provision of Services, liquidated damages (“Liquidated Damages”) will become payable from the Customer to Supplier on the following basis:
(i) If dates are changed or cancelled at the Customer’s request more than 14 days before the scheduled start date no Liquidated Damages are payable.
(ii) If dates are changed or cancelled between 7 days and 14 days before the scheduled start date Liquidated Damages equivalent to 50% of the Fees for the Services to be provided at that time will be payable.
(iii) If dates are changed or cancelled less than 7 days before the scheduled start date Liquidated Damages equivalent to 100% of the Fees for the Services to be provided at that time will be payable.
(e) inform the Supplier of all health and safety rules and regulations and any other reasonable security requirements that apply at any of the Customer’s premises;
(f) in respect of any Microsoft funded services, sign and deliver the Microsoft Proof of Execution (XXX) within 7 days of the date of issue by Microsoft. In the event that the Customer does not return the XXX within the 7 days’ notice period, the Supplier may be entitled to charge the Customer the amounts directly and the Customer shall follow the payment terms in this Agreement.;
(g) maintain continuous global admin access to the Customer’s relevant Microsoft
(h) Where a Microsoft Cloud service is deployed / utilised within the project the Customer shall assign the Supplier to be the Digital Partner of Record for a minimum of twelve (12) months from project completion date;
(i) provide appropriate hardware interface, software and access authorisation to enable remote diagnosis, should such capability be required;
(j) provide all information and make available all resources as reasonably requested by Supplier in the execution of its obligations under this Agreement;
(k) use all reasonable efforts to follow the reasonable instructions of Supplier support personnel with respect to the resolution of defects;
(l) gather all relevant information prior to requesting assistance in respect of any defects including detailed defect description, and procedures required to replicate a problem if possible. Any additional information which may help in the diagnosis of a defect should be included such as network configuration details;
(m) agree that if, in the course of performing the Services, it is reasonably necessary for the Supplier’s performance of its obligations under a Statement of Work for Supplier to access or use any equipment, software or data of the Customer (or which is in the possession of the Customer) then it shall where it is able to do so grant to Supplier a non-exclusive, royalty free, terminable licence to use the same solely for the purpose of delivering the Services only for as long as is strictly necessary to deliver such Services; and
(n) provide network and user access between Customer’s and Supplier’s data centres.
5.5 To the extent that the Supplier requires access to the Customer’s Operating Environment to perform the Dedicated Support, the Customer shall use reasonable endeavours to provide such access during Normal Business Hours and to provide a suitable work environment to enable the Supplier to perform such Dedicated Support subject to the Supplier complying with such internal policies and procedures of the Customer (including those relating to security and health and safety) as may be notified to the Supplier in writing from time to time.
5.6 The Customer shall (unless otherwise specified in the Statement of Work or as otherwise set out in this Agreement):
(a) use the Services only for lawful purposes and in accordance with this Agreement;
(b) keep secure from third parties any passwords issued to the Customer by the Supplier;
(c) install or, permit the Supplier to install, the current version of software required to provide the Dedicated Support from time to time when upgrades or fixes occur and to provide a reasonable level of assistance in implementation and testing;
(d) provide notice of intention to change applicable Customer-side Equipment or Customer Operating Environment or data-feeds that will directly impact the Dedicated Support;
(e) comply with all applicable laws and regulations with respect to its activities under this Agreement, including those set out in Clause 20;
(f) carry out all other Customer responsibilities set out in this Agreement and the Statement of Work in a timely and efficient manner. In the event of any delays in the Customer's provision of such assistance as agreed by the Parties, the Supplier may adjust any timetable or delivery schedule set out in this Agreement as reasonably necessary;
(g) use the Third-Party Software and/or Software correctly in accordance with its operating instructions;
(h) notify Supplier promptly of any problems with the Third-Party Software and/or Software; and
(i) use only versions of the Third-Party Software and/or Software covered by Microsoft in mainstream or extended support unless otherwise agreed in writing.
5.7 In the event that the Customer is in breach of its obligations under the Agreement (excluding payment obligations) then the Supplier shall provide written notice of such breach, specifying in detail the nature of the breach and providing thirty (30) Business Days’ notice to remedy such breach if capable of remedy. If the Customer fails to remedy such breach the Supplier shall be entitled to terminate or suspend the Services without prejudice to any pre-existing rights and obligations of either Party. The Supplier shall have no liability or responsibility should the Services fail to comply with the Statement of Work and/or Service Level Agreements as a direct result of the Customer (including without limitation any of its employees, subcontractors or any of its staff) being in breach of the Agreement.
5.8 In the event that the Customer is in breach of its payment obligations under the Agreement then the Supplier shall provide written notice of such breach, specifying in detail the nature of the breach and providing thirty (30) days notice to remedy such breach if capable of remedy. If the Customer fails to remedy such breach the Supplier shall be entitled to terminate or suspend the Services without prejudice to any pre- existing rights and obligations of either Party. The Supplier shall have no liability or responsibility should the Services fail to comply with the Statement of Work and/or Service Level Agreements as a direct result of the Customer (including without limitation any of its employees, subcontractors or any of its staff) being in breach of the Agreement.
Responsibilities of Consultant a. Consultant, as an independent contractor to Client, shall perform the Scope of Work (Exhibit A) in accordance with, and subject to, the other provisions of this Agreement.
b. The Scope of Work shall be performed in accordance with all applicable federal, state, and local rules and regulations including, but not limited to, the requirements of the Storage Tank and Spill Prevention Act (Act 32 of 1989, as amended) and Pa. Code, Title 25, Chapter 245, established under the Land Recycling and Environmental Remediation Standards Act (Act 2 of 1995) and Pa. Code, Chapter 250 (Administration of Land Recycling Program).
c. Consultant shall perform the Scope of Work for an amount not to exceed the Base Contract Price (“BCP”) of $[insert BCP] plus any Cost Adders, Optional Milestones and/or Unit Costs, subject to all other provisions of this Agreement.
d. Consultant shall participate in periodic site meetings with the Client and PAUSTIF for site status updates. Consultant will be provided no less than ten (10) days written notice of the date, time, and location of the meeting by the Client/PAUSTIF through their third party administrator.
Certain Duties and Responsibilities of Trustee (a) The Trustee, prior to the occurrence of an Event of Default with respect to the Securities of a series and after the curing of all Events of Default with respect to the Securities of that series that may have occurred, shall undertake to perform with respect to the Securities of such series such duties and only such duties as are specifically set forth in this Indenture, and no implied covenants shall be read into this Indenture against the Trustee. In case an Event of Default with respect to the Securities of a series has occurred (that has not been cured or waived), the Trustee shall exercise with respect to Securities of that series such of the rights and powers vested in it by this Indenture, and use the same degree of care and skill in their exercise, as a prudent man would exercise or use under the circumstances in the conduct of his or her own affairs.
(b) No provision of this Indenture shall be construed to relieve the Trustee from liability for its own negligent action, its own negligent failure to act, or its own willful misconduct, except that:
(i) prior to the occurrence of an Event of Default with respect to the Securities of a series and after the curing or waiving of all such Events of Default with respect to that series that may have occurred:
(A) the duties and obligations of the Trustee shall with respect to the Securities of such series be determined solely by the express provisions of this Indenture, and the Trustee shall not be liable with respect to the Securities of such series except for the performance of such duties and obligations as are specifically set forth in this Indenture, and no implied covenants or obligations shall be read into this Indenture against the Trustee; and
(B) in the absence of bad faith on the part of the Trustee, the Trustee may with respect to the Securities of such series conclusively rely, as to the truth of the statements and the correctness of the opinions expressed therein, upon any certificates or opinions furnished to the Trustee and conforming to the requirements of this Indenture; but in the case of any such certificates or opinions that by any provision hereof are specifically required to be furnished to the Trustee, the Trustee shall be under a duty to examine the same to determine whether or not they conform to the requirements of this Indenture;
(ii) the Trustee shall not be liable to any Securityholder or to any other Person for any error of judgment made in good faith by a Responsible Officer or Responsible Officers of the Trustee, unless it shall be proved that the Trustee was negligent in ascertaining the pertinent facts;
(iii) the Trustee shall not be liable with respect to any action taken or omitted to be taken by it in good faith in accordance with the direction of the holders of not less than a majority in principal amount of the Securities of any series at the time Outstanding relating to the time, method and place of conducting any proceeding for any remedy available to the Trustee, or exercising any trust or power conferred upon the Trustee under this Indenture with respect to the Securities of that series;
(iv) none of the provisions contained in this Indenture shall require the Trustee to expend or risk its own funds or otherwise incur personal financial liability in the performance of any of its duties or in the exercise of any of its rights or powers if there is reasonable ground for believing that the repayment of such funds or liability is not reasonably assured to it under the terms of this Indenture or adequate indemnity against such risk is not reasonably assured to it;
(v) The Trustee shall not be required to give any bond or surety in respect of the performance of its powers or duties hereunder;
(vi) The permissive right of the Trustee to do things enumerated in this Indenture shall not be construed as a duty of the Trustee; and
(vii) No Trustee shall have any duty or responsibility for any act or omission of any other Trustee appointed with respect to a series of Securities hereunder.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.
12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any.
12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
Responsibilities of Both Parties 6.1 The CLEC providing the circuit between CLEC’s office and SBC-12STATE’s office shall make such circuits available for use in connection with the DA services covered herein. When the total traffic exceeds the capability of the existing circuits, additional circuits will be provided by the CLEC.
6.2 Where applicable, if additional ADAX cards and ASN Routers (with sync and token ring cards) are necessary, they will be provided by SBC-12STATE, and CLEC will reimburse SBC-12STATE for the cost, plus Engineering, Furnish and Installation.
RESPONSIBILITIES OF PARTIES A. BST will include billing number information associated with resold exchange lines or SPNP arrangements in its LIDB. The Local Exchange Company will request any toll billing exceptions via the Local Service Request (LSR) form used to order resold exchange lines, or the SPNP service request form used to order SPNP arrangements.
B. Under normal operating conditions, BST shall include the billing number information in its LIDB upon completion of the service order establishing either the resold local exchange service or the SPNP arrangement, provided that BST shall not be held responsible for any delay or failure in performance to the extent such delay or failure is caused by circumstances or conditions beyond BST’s reasonable control. BST will store in its LIDB an unlimited volume of the working telephone numbers associated with either the resold local exchange lines or the SPNP arrangements. For resold local exchange lines or for SPNP arrangements, BST will issue line-based calling cards only in the name of Local Exchange Company. BST will not issue line- based calling cards in the name of Local Exchange Company’s individual end users. In the event that Local Exchange Company wants to include calling card numbers assigned by the Local Exchange Company in the BST LIDB, a separate agreement is required.
C. BST will provide responses to on-line, call-by-call queries to the stored information for the specific purposes listed in the next paragraph.
D. BST is authorized to use the billing number information to perform the following functions for authorized users on an on-line basis:
1. Validate a 14 digit Calling Card number where the first 10 digits are a line number or special billing number assigned by BST, and where the last four digits (PIN) are a security code assigned by BST.
2. Determine whether the Local Exchange Company has identified the billing number as one which should not be billed for collect or third number calls, or both.
RESPONSIBILITIES OF THE OWNER The Owner agrees to: Provide all documentation, records, and disclosures as required by law or required by the Agent to manage and operate the Property, and immediately notify the Agent if the Owner becomes aware of any change in such documentation, records or disclosures, or any matter affecting the habitability of the Property; Indemnify, defend, and hold harmless the Agent, and all persons in the Agent's firm, regardless of responsibility, from all costs, expenses suits, liabilities, damages, attorneys fees, and claims of every type, including, but not limited to, those arising out of injury or death of any person, or damage to any real or personal property of any person, including the Owner, for: Any repairs performed by the Owner or by others hired directly by the Owner; or Those relating to the management, leasing, rental, security deposit, or operation of the Property by the Agent, or any person in the Agent's company, or the performance or exercise of any of the duties, powers, or authorities granted to the Agent; This sub-section, and all rights to the Agent’s indemnification, shall be considered void if the Agent exemplifies any willful acts of gross negligence; Maintain the Property in a condition fit for human habitation as required by applicable State and local laws; Pay all interest on Tenants’ security deposits if required by applicable laws; Carry and pay for: Public and premises liability insurance in an amount of no less than one-million dollars ($1,000,000.00); and Property damage and worker’s compensation insurance adequate to protect the interests of the Owner and the Agent. The Agent shall be, and the Owner authorizes Agent to be, named as an additional insured party on the Owner’s policies; and Pay any late charges, penalties and/or interest imposed by lenders or other parties for failure to make payment only if the failure is due to insufficient funds in the Agent’s trust account available for such payment. In addition, the Owner agrees to replace any funds required if there are insufficient funds in the Agent’s trust account to cover such responsibilities of the Owner.
