Certification of Controller; Guaranteed Maximum Costs Sample Clauses

Certification of Controller; Guaranteed Maximum Costs. No funds shall be available under this Agreement until prior written authorization certified by the Controller. In addition, as set forth in Section 21.10-1 of the San Francisco Administrative Code: City's obligations hereunder shall not at any time exceed the amount certified by the Controller for the purpose and period stated in such certification. Except as may be provided by City ordinances governing emergency conditions, City and its employees and officers are not authorized to request Grantee to perform services or to provide materials, equipment and supplies that would result in Grantee performing services or providing materials, equipment and supplies that are beyond the scope of the services, materials, equipment and supplies specified in this Agreement unless this Agreement is amended in writing and approved as required by law to authorize the additional services, materials, equipment or supplies. City is not required to pay Grantee for services, materials, equipment or supplies that are provided by Grantee which are beyond the scope of the services, materials, equipment and supplies agreed upon herein and which were not approved by a written amendment to this Agreement having been lawfully executed by City. City and its employees and officers are not authorized to offer or promise to Grantee additional funding for this Agreement which would exceed the maximum amount of funding provided for herein. Additional funding for this Agreement in excess of the maximum provided herein shall require lawful approval and certification by the Controller. City is not required to honor any offered or promised additional funding which exceeds the maximum provided in this Agreement which requires lawful approval and certification of the Controller when the lawful approval and certification by the Controller has not been obtained. The Controller is not authorized to make payments on any agreement for which funds have not been certified as available in the budget or by supplemental appropriation.
Sample 1Sample 2Sample 3See All (38)
AutoNDA by SimpleDocs
Certification of Controller; Guaranteed Maximum Costs. No funds shall be available under this Agreement without prior written authorization certified by the San Diego Chief Financial Officer as set forth in Section 39 of the City of San Diego City Charter: “No contract, agreement, or other obligation for the expenditure of public funds shall be entered into by any officer of the City and no such contract shall be valid unless the Chief Financial Officer shall certify in writing that there has been made an appropriation to cover the expenditure and that there remains a sufficient balance to meet the demand thereof.”
Sample 1Sample 2Sample 3
Certification of Controller; Guaranteed Maximum Costs. No funds shall be available under this Agreement until prior written authorization certified by the San Francisco Controller. In addition, as set forth in Section 21.10-1 of the San Francisco Administrative Code: (a) San Francisco's obligations hereunder shall not at any time exceed the amount approved by the Grant Budget and certified by the Controller for the purpose and period stated in such certification. (b) Except as may be provided by San Francisco ordinances governing emergency conditions, San Francisco and its employees and officers are not authorized to request San Mateo to perform services or to provide materials, equipment and supplies that would result in San Mateo performing services or providing materials, equipment and supplies that are beyond the scope of the services, materials, equipment and supplies specified in this Agreement unless this Agreement is amended in writing and approved as required by law to authorize the additional services, materials, equipment or supplies. San Francisco is not required to pay San Mateo for services, materials, equipment or supplies that are provided by San Mateo that are beyond the scope of the services, materials, equipment and supplies agreed upon herein and which were not approved by a written amendment to this Agreement having been lawfully executed by San Francisco. (c) San Francisco and its employees and officers are not authorized to offer or promise to San Mateo additional funding for this Agreement that would exceed the maximum amount of funding provided for herein. Additional funding for this Agreement in excess of the maximum provided herein shall require lawful approval and certification by the Controller. San Francisco is not required to honor any offered or promised additional funding that exceeds the maximum provided in this Agreement that requires lawful approval and certification of the Controller when the lawful approval and certification by the Controller has not been obtained. (d) The Controller is not authorized to make payments on any agreement for which funds have not been certified as available in the budget or by supplemental appropriation.
Sample 1
Certification of Controller; Guaranteed Maximum Costs. No funds shall be available under this Agreement until prior written authorization certified by the Controller. In addition, as set forth in
Sample 1
Certification of Controller; Guaranteed Maximum Costs. No funds shall be available under this Agreement until prior written authorization certified by the Controller. In addition, as set forth in Section 21.10-1 of the San Francisco Administrative Code: City's obligations hereunder shall not at any time exceed the amount certified by the Controller for the purpose and period stated in such certification. Except as may be provided by City ordinances governing emergency conditions, City and its employees and officers are not authorized to request Grantee to perform services or to provide materials, equipment and supplies that would result in Grantee performing services or providing materials, equipment and supplies that are beyond the scope of the services, materials, equipment and supplies specified in this Agreement unless this Agreement is amended in writing and approved as required by law to authorize the additional services, materials, equipment or supplies. City is not required to pay Grantee for services, materials, equipment or supplies that are provided by Grantee which are beyond the scope of the services, materials, equipment and supplies agreed upon herein and which were not approved by a written amendment to this Agreement having been lawfully executed by City. City and its employees and
Sample 1
Certification of Controller; Guaranteed Maximum Costs. No funds shall be available under this Agreement until prior written authorization certified by the Controller. In addition, as set forth in Section 21.19 of the San Francisco Administrative Code: City's obligations hereunder shall not at any time exceed the amount certified by the Controller for the purpose and period stated in such certification. Except as may be provided by City ordinances governing emergency conditions, City and its employees and officers are not authorized to request Grantee to perform services or to provide materials, equipment
Sample 1

Related to Certification of Controller; Guaranteed Maximum Costs

  • Guaranteed Maximum Costs The City’s payment obligation to Contractor cannot at any time exceed the amount certified by City’s Controller for the purpose and period stated in such certification. Absent an authorized Emergency per the City Charter or applicable Code, no City representative is authorized to offer or promise, nor is the City required to honor, any offered or promised payments to Contractor under this Agreement in excess of the certified maximum amount without the Controller having first certified the additional promised amount and the Parties having modified this Agreement as provided in Section 11.5, “Modification of this Agreement.”

  • Application of this Revenue Sharing Agreement to Notes The terms of this Revenue Sharing Agreement shall apply to each Note as if the terms of this Revenue Sharing Agreement were fully set forth in each Note.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Subordinate Certificate Loss Coverage; Limited Guaranty Subject to subsection (c) below, prior to the later of the third Business Day prior to each Distribution Date or the related Determination Date, the Master Servicer shall determine whether it or any Sub-Servicer will be entitled to any reimbursement pursuant to Section 4.02(a) on such Distribution Date for Advances or Sub-Servicer Advances previously made, (which will not be Advances or Sub-Servicer Advances that were made with respect to delinquencies which were subsequently determined to be Excess Special Hazard Losses, Excess Fraud Losses, Excess Bankruptcy Losses or Extraordinary Losses) and, if so, the Master Servicer shall demand payment from Residential Funding of an amount equal to the amount of any Advances or Sub-Servicer Advances reimbursed pursuant to Section 4.02(a), to the extent such Advances or Sub-Servicer Advances have not been included in the amount of the Realized Loss in the related Mortgage Loan, and shall distribute the same to the Class B Certificateholders in the same manner as if such amount were to be distributed pursuant to Section 4.02(a).

  • QUANTITY BASIS OF CONTRACT – NO GUARANTEED QUANTITIES The contract established has no guarantee of any specific quantity and the State is obligated only to buy that quantity which is needed by its agencies.

  • Treatment of Unallowable Costs Previously Submitted for Payment Mallinckrodt further agrees that within 120 days of the Effective Date of this Agreement it shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Mallinckrodt or any of its subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Mallinckrodt agrees that the United States, at a minimum, shall be entitled to recoup from Mallinckrodt any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Mallinckrodt or any of its subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Mallinckrodt or any of its subsidiaries or affiliates’ cost reports, cost statements, or information reports.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Conditions to Obligations of Each Party Under This Agreement The respective obligations of each party to effect the Merger and the other transactions contemplated herein shall be subject to the satisfaction at or prior to the Effective Time of the following conditions, any or all of which may be waived, in whole or in part, to the extent permitted by applicable Law:

  • GUARANTEED DISPLAY REFERRAL FEE WAIVERS XXXX.xxx offers a paid featured agent program referred to as “Guaranteed Display.” This paid product provides the following Referral Fee benefits to the Recipient Broker/Agent: • If a closing results from a lead originated during the time, and in the zip code, that the Recipient Broker/Agent was an active Guaranteed Display sponsor, the referral fee will be discounted from the standard 35% to 30%. • If a closing results from a lead originated during the time, and in the zip code, that the Recipient Broker/Agent was an active Guaranteed Display sponsor, and if XXXX.xxx was not responsible for brokering an appointment between the Referred Client and the Recipient Broker/ Agent, the referral fee will be waived entirely to 0%. To qualify for this Referral Fee waiver, Recipient Broker/Agent must update the Referral Status in the XXXX.xxx Agent Portal (xxxxx://xxxxxx.xxxx.xxx) to reflect the property has been listed prior to XXXX.xxx indicating that an appointment has been set.

  • Definition of Guaranteed Obligations As used herein, the term “Guaranteed Obligations” means:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!