Change in project period Sample Clauses

Change in project period. The recipient shall include in the request the cause of the needed extension, a description of remaining work to be completed, the proposed date of completion, the amount of funds remaining, and a revised budget for the remaining funds. If all funds have been disbursed to the recipient, this must be indicated in the request. No-cost extensions are discouraged. Applicants should consider their time commitments at the time of application for a cooperative agreement. Requests for no-cost extensions will be considered on a case-by-case basis. The USGS reserves the right to limit the length of time and number of no-cost extensions. A request for an extension that is received by the Administrative Contracting Officer after the expiration date shall not be honored. Only one no-cost extension may be granted.
Sample 1
AutoNDA by SimpleDocs

Related to Change in project period

  • Project Period The Project Period ("Project Period") is the time during which the Applicant will be conducting the Project. Unless this Investment Agreement is terminated earlier under Article 7 Termination, the Project Period commences on the Project Start Date and ends on the Project Completion Date.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Construction Preparation Period 2.1.3 Construction Management Plan

  • Change from Prior Year FY2023 County Executive Request

  • Construction Period During the construction period, Redeveloper agrees to keep the construction area, including completed operations insured against loss or damage by fire, and such other risks, casualties, and hazards as are customarily covered by builders’ risk or extended coverage policies in an amount not less than the replacement value but allowing for reasonable coinsurance clauses and deductibles. In the event of any insured damage or destruction, Redeveloper agrees to use its good faith efforts to commence restoration of the Private Improvements to its prior condition within nine (9) months from the date of the damage or destruction, and shall diligently pursue the same to completion.

  • Operation Delays STATE shall have the authority to delay or suspend the operations of PURCHASER and contractors of PURCHASER, wholly or in part, under this contract for such period or periods necessary due to fire hazard conditions, severe weather occurrence, surveying for threatened or endangered species listed under the state or federal Endangered Species Act, or any other activity STATE determines to be necessary for identification, management, or protection of a threatened or endangered species. PURCHASER agrees to cooperate with surveying efforts of STATE or its contractors. In no event shall STATE be liable for any costs incurred by PURCHASER by reason of delay or suspension under this section, including but not limited to costs of additional move-in/move-out of equipment and personnel, extra fire and equipment security, and insurance or bonding expenses.

  • RENTAL DURATION 3.1 Rental days are calculated on a calendar day basis. When calculating the number of days the Vehicle is rented, the day of pick-up is counted as day one of the rental, regardless of pick-up time. The day of the Vehicle’s return is counted as the final day of the rental regardless of drop-off time.

  • Correction Period (1) End of correction period. The last day of the correction period for an Operational Failure is the last day of the second plan year following the plan year for which the failure occurred. However, in the case of a failure to satisfy the requirements of § 401(k)(3), 401(m)(2), or 401(m)(9), the correction period does not end until the last day of the second plan year following the plan year that includes the last day of the additional period for correction permitted under § 401(k)(8) or 401(m)(6). If a 403(b) Plan does not have a plan year, the plan year is deemed to be the calendar year for purposes of this subsection.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Development Period The Contractor may commence pre-construction activities like utility shifting, boundary wall construction or any other activity assigned to the Contractor by the Authority to enable construction of the Project Highway immediately after signing of the Agreement, to the extent that such work is ready for execution. The Parties agree that these works may be taken up and completed to the extent feasible by the Contractor, before declaration of the Appointed Date, but no claim against the Authority for delay shall survive during this period and that the undertaking of these works by the Contractor shall not count towards the Scheduled Construction Period of the project which starts counting only from the Appointed Date. No construction activity of the Project Highway shall be undertaken during the development period.

Time is Money Join Law Insider Premium to draft better contracts faster.