Time Period The bounded Party’s(ies’) duty to hold the Confidential Information in confidence shall remain in effect until such information no longer qualifies as a trade secret or written notice is given releasing such Party from this Agreement.
Calculation of Time Periods Unless otherwise specified, in computing any period of time described in this Agreement, the day of the act or event after which the designated period of time begins to run is not to be included and the last day of the period so computed is to be included, unless such last day is a Saturday, Sunday or legal holiday under the laws of the State in which the Property is located, in which event the period shall run until the end of the next day which is neither a Saturday, Sunday or legal holiday. The final day of any such period shall be deemed to end at 5 p.m., local time.
Changes in Contract Time All Change Orders must state that the Contract Time and the Material Completion and Occupancy Date either are not changed or are increased or decreased by a specific number of Days. The CONTRACTOR must provide written justification for the extension to the Design Professional and to the Owner. The written justification must demonstrate an anticipated actual increase in the time required to complete the Work beyond that allowed by the Contract as adjusted by prior Change Orders to the Contract. No extension to the Contract Time shall be allowed unless the additional or changed Work increases the length of the critical path beyond the Material Completion and Occupancy Date. If approved, the increase in time required to complete the Work shall be added to the Contract Time. The Owner may decrease, by Change Order, the Contract Time when an Owner-requested deletion from the Work results in a decrease in the actual time required to complete the Work as demonstrable on the critical path of the Construction Progress Schedule. Eligibility and processing requirements for Time Dependent Overhead Costs for compensable delay is addressed in Article 3.3.8 and 3.3.10.
Computation of Time Periods In this Agreement in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each mean “to but excluding”.
Changes in Terms The terms of this housing agreement may be amended by the UNIVERSITY for any reason, provided that written notice of such amendment is given to the STUDENT forty-five (45) days in advance.
Time Periods The nondisclosure provisions of this Agreement shall survive the termination of this Agreement and Receiving Party's duty to hold Confidential Information in confidence shall remain in effect until the Confidential Information no longer qualifies as a trade secret or until Disclosing Party sends Receiving Party written notice releasing Receiving Party from this Agreement, whichever occurs first.
Changes in Work A. Work Previously Submitted as Satisfactory. If the Engineer has submitted work in accordance with the terms of this contract but the State requests changes to the completed work or parts thereof which involve changes to the original scope of services or character of work under the contract, the Engineer shall make such revisions as requested and as directed by the State. This will be considered as additional work and paid for as specified under Article 4, Additional Work.
Change of Time Periods The time periods and/or dates described in this Agreement with respect to the giving of notices and hearings are subject to approval and change by the Court or by written agreement of Class Counsel and Counsel for Defendant, without notice to Settlement Class Members. The Parties reserve the right, by agreement and subject to Court approval, to grant any reasonable extension of time that might be needed to carry out any of the provisions of this Agreement.
Changes in Service This Agreement is made in good faith based upon the present and projected conditions and the quality of the equipment and/or Property, as well as its present ownership and management. Should changes in any of these elements occur which the Judicial Council believes may adversely affect the Program, the Judicial Council reserves the right to renegotiate this Agreement or terminate pursuant to the termination for cause provision, as set forth herein, without penalty or prejudice.
Changes in Work Schedules (a) In situations other than emergencies, the scheduled employees are entitled to forty-eight (48) hours notice of any change in their respective work schedules.
