Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Unsafe Work Conditions No Employee shall be disciplined for refusal to work on a job which in the opinion of: (a) A member of a safety committee; or (b) A person designated by a safety committee; or (c) A safety officer after an on-site inspection and following discussion with a representative of the Employer, does not meet the standards established pursuant to the Workers' Compensation Act.
– OTHER SPECIAL CONDITIONS I. 12.1 Exchange rate applicable for the conversion of currencies into euro Payments shall be made by the Commission in euro. The co-ordinator shall submit the payment requests in accordance with article I.5.3, including the underlying financial statements, in euro. By way of derogation from article II.16.1, any conversion of actual costs into euro shall be made by the beneficiary at the monthly accounting rate established by the Commission and published on its website applicable on the day when the cost was incurred.
Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
Permission to Leave Work The Employer agrees that stewards shall not be hindered, coerced, restrained or interfered with in any way in the performance of their duties, while investigating disputes and presenting adjustments as provided in this Article. The Union recognizes that each xxxxxxx is employed by the Employer and that they will not leave their work during working hours except to perform their duties under this Agreement. Therefore, no xxxxxxx shall leave their work without permission of their supervisor, which will not be unreasonably withheld.
Warranty of Services Contractor warrants that the services provided conform to the contract requirements, including all descriptions, specifications and attachments made a part of this contract. The Department’s acceptance of services provided by Contractor shall not relieve Contractor from its obligations under this warranty. In addition to its other remedies under this contract, at law, or in equity, the Department may, at Contractor's expense, require prompt correction of any services failing to meet Contractor's warranty herein. Services corrected by Contractor shall be subject to all the provisions of this contract in the manner and to the same extent as services originally furnished.
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants: a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals: (1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency; (2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and (4) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
