Changes to the Work 7.1 Changes to the Work may be accomplished by preparation of and execution of a change order or construction change directive. Change orders or construction change directives will be preceded by a change proposal request initiated by the Architect. The Construction Manager shall provide prices and details within 30 days of receipt of a change proposal request, and the Architect shall forward the completed change proposal request to the Owner within 15 days after receipt of the information provided by the Construction Manager.
Changes to Scope of Work The City of Nashua may, at any time, by written order, make changes to the general scope, character, or cost of this contract and in the services or work to be performed, either increasing or decreasing the scope, character, or cost of Independent Contractor's performance under the contract. Independent Contractor shall provide to the City of Nashua within 10 calendar days, a written proposal for accomplishing the change. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. If the change causes an increase or a decrease in Independent Contractor's cost or time required for performance of the contract as a whole, an equitable adjustment shall be made and the contract accordingly modified in writing. Any claim of Independent Contractor for adjustment under this clause shall be asserted in writing within 30 days of the date the City of Nashua notified Independent Contractor of the change. When Independent Contractor seeks changes, Independent Contractor shall, before any work commences, estimate their effect on the cost of the contract and on its schedule and notify the City of Nashua in writing of the estimate. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. Except as provided in this paragraph, Independent Contractor shall implement no change unless the City of Nashua in writing approves the change. Unless otherwise agreed to in writing, the provisions of this contract shall apply to all changes. The City of Nashua may provide verbal approval of a change when the City of Nashua, in its sole discretion, determines that time is critical or public health and safety are of concern. Any verbal approval shall be confirmed in writing as soon as practicable. Any change undertaken without prior City of Nashua approval shall not be compensated and is, at the City of Nashua's election, sufficient reason for contract termination.
Changes to Service We may, from time to time, modify the Service to reflect improvements and other changes and modifications to our network. In addition, we reserve the right to discontinue or limit Service as required to comply with or satisfy our obligations under applicable laws or regulations, including when changes to or interpretations of such laws and regulations have a material, adverse effect on the business, technical or economic feasibility of providing Service, as determined by us in our reasonable judgment.
Changes to Fees Modernizing Medicine may change the fees and discounts set forth in this Agreement by providing at least thirty (30) days prior written notice (the “Notice Period”) of such change to Medical Practice. Any such change shall take effect at the beginning of the next Renewal Term after the expiration of the Notice Period.
Changes to Services The Parties acknowledge and agree that there will be changes to the scope of the Services during the Contract Period. The Customer may amend the Stories that are comprised within the Minimum Marketable Features of a Release at any time during the Release at no additional charge and without adopting the Change Control Procedure set out in Clause 28 above provided that: the Customer shall not be entitled to make any changes to the Stories that form the subject of a Sprint following the mutual agreement by the Parties of the Sprint Plan for that Sprint; new Stories and/or changes to existing Stories may only be introduced if: existing Stories with an equivalent number of Story Points are removed; or existing Stories are reduced in size by the equivalent number of Story Points, such that the total number of Story Points for the Release remains constant throughout the Release. The Supplier shall consider any request by the Customer to increase the number of Story Points for a Release, and may, subject to the Change Control Procedure set out at Clause 28, agree to such request.
Changes to the Service We reserve the right to terminate, modify, add and remove features from the Service at any time in our sole discretion. You may reject changes by discontinuing use of the Service. Your continued use of the Service will constitute your acceptance of and agreement to such changes. Maintenance to the Service may be performed from time-to-time resulting in interrupted service, delays or errors in the Service and we shall have no liability for any such interruptions, delays or errors.
Changes to the Project 9.1 All Changes must be approved by the Secretary of State prior to the relevant Change being deemed to be effective. The Grant Recipient shall request the Change on a Project Change Request Form. The Secretary of State shall either agree to the change request or reject the change request within 60 days of the date of the Project Change Request Form.
Changes to Project Should the Subgrantee wish to make changes to the outcomes, Scope of Work, equipment to be purchased, key personnel, expenditures or deliverables, the Subgrantee must request permission to revise the project. This is done by submitting a Change Request. Changes within a budget category that are more than ten percent (10%) of the award or that move funds from one budget category to another require submission of a Change Request. Approval must be obtained from the Division before the changes are implemented in the project. Approval will be granted for changes that are consistent with the intent of the approved application or prior Change Requests. Changes to the project must be requested using the Change Request in the DOS Grants System at xxxxxxxxx.xxx.
CHANGE IN CLASSIFICATION SPECIFICATIONS Section 1. The Employer shall notify the Union of intended classification studies.
Changes to the Notice Information Either Party may change this information by giving five Business Days written notice prior to the effective date of the change.
