CHARACTERISTICS AND TERM Sample Clauses

CHARACTERISTICS AND TERM. ING Lease (España), E.F.C, S.A., hereinafter referred to as the “Lessor” and registered with the number 4709 in the Bank of Spain’s Register of Credit Institutions, shall grant the Lessee the enjoyment and use of the goods set forth in this Agreement’s Specific Terms and Conditions for the term agreed upon therein and through the payment of installments set forth in Annex 1 attached hereto. The Lessor is the legal owner of such goods and holds full ownership over them through title of purchase until such time as the ownership of the leased goods is conveyed to the Lessee through the exercise of its granted purchase option. The leased goods have been acquired by the Lessor in accordance with the specific instructions it has received from the Lessee, which has chosen both the supplier of such goods as well as the goods that are the purpose of this agreement, with the sole purpose of proceeding to lease them. The Lessee hereby states that it gives its full acceptance of the goods that have been delivered to it. Consequently, the Lessee shall hold the Lessor harmless from any liability that may arise as a result of the lack of objective or subjective fitness of purpose, malfunctioning, breakdown or any other circumstance or condition that may be stated about the goods acquired by the Lessor, which have hereby been ceded on a financial lease. Hence, the Lessee shall waive any such claims against the Lessor and shall, in any event, undertake to pay the Agreement’s installments. For its part, the Lessor, as the goods’ purchaser, subrogates to the Lessee all of its rights and actions corresponding to the supplier of the goods, including any actions to cancel and rescind the purchase and sale on the grounds of the goods being defective. It is hereby agreed that this Agreement shall have a term equivalent to the period between the date it is entered into and the date set forth to exercise the purchase option. Said term shall be construed as fixed and irrevocable, without prejudice to the stipulations set forth in Clause 8, paragraph (b) of these General Terms and Conditions.
Sample 1
AutoNDA by SimpleDocs

Related to CHARACTERISTICS AND TERM

  • Scope of Services and Term Subject to the provisions for early termination as set forth herein, the Contractor agrees that it will perform the Services enumerated in the scope of services attached hereto as Exhibit A and incorporated herein by reference (the “Scope of Services”) for a term of five years (5) beginning , 2023 through , 2028 (the “Term”). The Authority in its sole discretion may extend the Agreement for two (2) additional one-year periods, for a potential maximum term of *** (**) years. The Authority will provide any such renewal notice in writing at least thirty (30) days prior to expiration of the Agreement. The maximum payment for the Term is set forth in Section II(a). All work shall be diligently performed by the Contractor in an economical, expeditious and professional manner.

  • Purpose and Term The purpose to be conducted or promoted by the Company is to engage solely in the following activities: (a) (i) to engage in any lawful act or activity for which a limited liability company may be organized under the Act, including, but not limited to, owning and operating the Property; (ii) to engage in any other lawful act or activity and to exercise any powers permitted by the Act that are related or incidental to and necessary, convenient or advisable for the accomplishment of the above-mentioned purposes. (b) The term of the Company shall commence on the date the Certificate of Formation was filed with the Secretary of State of the State of Delaware and will continue to the earlier of the date on which the Company is dissolved in accordance with the Act or this Agreement.

  • Premises and Term a. Landlord, in consideration of the Rent hereinafter reserved to be paid and of the covenants, conditions and agreements to be kept and performed by Tenant, hereby leases, lets and demises to Tenant, and Tenant hereby leases and hires from Landlord, the Project. Upon the Commencement Date for Phase 1, Tenant shall be entitled to the exclusive use and occupancy of Phase 1 and that portion of the Parking Area allocated for Phase 1 plus such spaces in addition to the spaces allocated for Phase 1, if any, that may be constructed by Landlord at the time, so long as Tenant’s use of such spaces in addition to the spaces allocated for Phase 1 does not interfere with the construction of the remainder of the Project by Landlord. Upon the Commencement Date for Phase 2, Tenant shall be entitled to the exclusive use and occupancy of Phase 2 and the entire Parking Area, and at which time Tenant will have the exclusive use and occupancy of the entire Project. b. Promptly after the actual Commencement Date for each Phase, the parties shall execute an instrument in which the Commencement Date and expiration date for such Phase will be specified, as well as any adjustments to the Rentable Area of the Premises as described above and any corresponding adjustments to the Base Rent. c. Notwithstanding anything to the contrary contained in this Lease, although Landlord has estimated a completion date for Phase 1 of October 1, 1999, the parties agree that if Landlord has not achieved Substantial Completion of Phase 1 on or before November 1, 1999 (the “Phase 1 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 1999, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 1, such credit to be equal to one (1) day’s Base Rent for Phase 1 for each day of Landlord’s delay beyond the Phase 1 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. d. If Landlord has not achieved Substantial Completion of Phase 1 on or before November 15, 1999 (the “Phase 1 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 1999, the Base Rent credit available to Tenant for Phase 1 shall be increased to two (2) days’ Base Rent for each day of Landlord’s delay beyond the Phase 1 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. e. If Landlord has not achieved Substantial Completion of Phase 1 on or before December 17, 1999 (the “Phase 1 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 1999, (x) the Base Rent credit available to Tenant for Phase 1 shall be decreased back to one (1) day’s Base Rent for each day of Landlord’s delay beyond the Phase 1 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below. f. If Landlord has not achieved Substantial Completion of Phase 1 on or before January 17, 2000 (the “Phase 1 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 1 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. g. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 1 on or before May 17, 2000 (the “Phase 1 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Extended Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2000 and May 1, 2000 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right. h. Although Landlord has estimated a completion date for Phase 2 of October 1, 2001, the parties agree that if Landlord has not achieved Substantial Completion of Phase 2 on or before November 1, 2001 (the “Phase 2 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 2001, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 2, such credit to be equal to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. i. If Landlord has not achieved Substantial Completion of Phase 2 on or before November 15, 2001 (the “Phase 2 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 2001, the Base Rent credit available to Tenant for Phase 2 shall be increased to two (2) days’ Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. j. If Landlord has not achieved Substantial Completion of Phase 2 on or before December 17, 2001 (the “Phase 2 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 2001, (x) the Base Rent credit available to Tenant shall be decreased back to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below. k. If Landlord has not achieved Substantial Completion of Phase 2 on or before January 17, 2002 (the “Phase 2 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 2 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. l. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 2 on or before May 17, 2002 (the “Phase 2 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Extended Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2002 and May 1, 2002 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right. m. The abatements, liquidated damages and termination rights in favor of Tenant as described above shall be Tenant’s sole and exclusive remedies in the event of any late delivery of the Buildings by Landlord, and notwithstanding anything to the contrary contained in this Lease, in no event shall the entire liability of Landlord in connection with the total aggregate amounts of the Base Rent credits, plus the $10,000.00 per day damages, plus the out-of-pocket costs incurred by Tenant exceed a total amount of Seven Hundred Fifty Thousand and No/100 ($750,000.00) Dollars in the aggregate, regardless of the length of time such rent credits, and/or liquidated damages and/or out-of-pocket costs actually accrue and regardless of whether Tenant terminates this Lease. n. Although the completion date for Phase 2 is intended to be October 1, 2001, Tenant may notify Landlord in writing of Tenant’s election to have the Commencement Date for Phase 2 be on October 1, 2000. Tenant must provide such notice no later than April 1, 1999. If Tenant timely provides such notice, then the anticipated Commencement Date for Phase 2 will be deemed to be October 1, 2000, and subparagraphs 2.h through 2.I above will be deemed to be modified as follows: All references to the year “2001” in such subparagraphs will be deemed to be “2000,” and all references to the year “2002” in such subparagraphs will be deemed to be “2001.”

  • PRICES AND TERMS Price Structure Standard Product: all Participating Consumers are enrolled in this option unless they opt out. This product includes the statutory mix plus voluntary RECs to bring total mix to % Green. Optional Greener Products: to enroll in this option participant must affirmatively opt in. This product includes the statutory mix plus voluntary RECs equal to % of the load plus RECs to bring total mix to % Green Optional Least Expensive Product: to enroll in this option participant must affirmatively opt in. This product includes the statutory mix, no additional voluntary RECs. Terms for System Supply Service Renewable Energy in System Supply:

  • Title and Terms The aggregate principal amount of Securities that may be authenticated and delivered under this Indenture is unlimited. The Securities may be issued in one or more series. There shall be established in or pursuant to a Board Resolution and, subject to Section 3.3, set forth or determined in the manner provided, in an Officers' Certificate, or established in one or more indentures supplemental hereto, prior to the issuance of Securities as a series: (a) the title of the securities of such series, which shall distinguish the Securities of the series from all other Securities; (b) the limit, if any, upon the aggregate principal amount of the Securities of such series that may be authenticated and delivered under this Indenture (except for Securities authenticated and delivered upon registration of transfer of, or in exchange for, or in lieu of, other Securities of the series pursuant to Section 3.4, 3.5, 3.6, 9.6 or 11.6 and except for any Securities that, pursuant to Section 3.3, are deemed never to have been authenticated and delivered hereunder); provided, however, that the authorized aggregate principal amount of such series may be increased above such amount by a Board Resolution to such effect; (c) the Person to whom any interest on a Security of the series shall be payable, if other than the Person in whose name that security (or one or more Predecessor Securities) is registered at the close of business on the Regular Record Date for such interest; (d) the Stated Maturity or Maturities on which the principal of the Securities of such series is payable or the method of determination thereof, and any dates on which or circumstances under which, the Company shall have the right to extend or shorten such Stated Maturity or Maturities; (e) the rate or rates, if any, at which the Securities of such series shall bear interest, if any, the rate or rates and extent to which Additional Interest, if any, shall be payable with respect to any Securities of such series, the date or dates from which any such interest or Additional Interest shall accrue, the Interest Payment Dates on which such interest shall be payable, the right, pursuant to Section 3.12 or as otherwise set forth therein, of the Company to defer or extend an Interest Payment Date, and the Regular Record Date for the interest payable on any Interest Payment Date or the method by which any of the foregoing shall be determined; (f) the place or places where the principal of (and premium, if any) and interest or Additional Interest on the Securities of such series shall be payable, the place or places where the Securities of such series may be presented for registration of transfer or exchange, any restrictions that may be applicable to any such transfer or exchange in addition to or in lieu of those set forth herein and the place or places where notices and demands to or upon the Company in respect of the Securities of such series may be made; (g) the period or periods within or the date or dates on which, if any, the price or prices at which and the terms and conditions upon which the Securities of such series may be redeemed, in whole or in part, at the option of the Company, and if other than by a Board of Resolution, the manner in which any election by the Company to redeem such Securities shall be evidenced; (h) the obligation or the right, if any, of the Company to redeem, repay or purchase the Securities of such series pursuant to any sinking fund, amortization or analogous provisions, or at the option of a Holder thereof, and the period or periods within which, the price or prices at which, the currency or currencies (including currency unit or units) in which and the other terms and conditions upon which Securities of the series shall be redeemed, repaid or purchased, in whole or in part, pursuant to such obligation; (i) the denominations in which any Securities of such series shall be issuable; (j) if other than Dollars, the currency or currencies (including any currency unit or units) in which the principal of (and premium, if any) and interest and Additional Interest, if any, on the Securities of the series shall be payable, or in which the Securities of the series shall be denominated and the manner of determining the equivalent thereof in Dollars for purposes of the definition of Outstanding; (k) the additions, modifications or deletions, if any, in the Events of Default or covenants of the Company set forth herein with respect to the Securities of such series; (l) if, other than the principal amount thereof, the portion of the principal amount of Securities of such series that shall be payable upon declaration of acceleration of the Maturity thereof; (m) if the principal amount payable at the Stated Maturity of any Securities of the series will not be determinable as of any one or more dates prior to the Stated Maturity, the amount which shall be deemed to be the principal amount of such Securities as of any such date for any purpose thereunder or hereunder, including the principal amount thereof which shall be due and payable upon any Maturity other than the Stated Maturity or which shall be deemed to be Outstanding as of any date prior to the Stated Maturity (or, in any such case, the manner in which such amount deemed to be the principal amount shall be determined); (n) if applicable, that the Securities of the series, in whole or in any specified part, shall be defeasible and, if other than by a Board Resolution, the manner in which any election by the Company to defease such Securities shall be evidenced; (o) the additions or changes, if any, to this Indenture with respect to the Securities of such series as shall be necessary to permit or facilitate the issuance of the Securities of such series in bearer form, registrable or not registrable as to principal, and with or without interest coupons; (p) any index or indices used to determine the amount of payments of principal of and premium, if any, on the Securities of such series or the manner in which such amounts will be determined; (q) if applicable, that any Securities of the series shall be issuable in whole or in part in the form of one or more Global Securities and, in such case, the respective Depositaries for such Global Securities, the form of any legend or legends that shall be borne by any such Global Security in addition to or in lieu of that set forth in Section 2.4 and any circumstances in addition to or in lieu of those set forth in Section 3.5 in which any such Global Security may be exchanged in whole or in part for Securities registered, and any transfer of such Global Security in whole or in part may be registered, in the name or names of Persons other than the Depositary for such Global Security or a nominee thereof; (r) the appointment of any Paying Agent or agents for the Securities of such series; (s) the terms of any right to convert or exchange Securities of such series into any other securities or property of the Company, and the additions or changes, if any, to this Indenture with respect to the Securities of such series to permit or facilitate such conversion or exchange; (t) if such Securities are to be issued to an Issuer Trust, the form or forms of the Trust Agreement and Guarantee relating thereto; (u) if, other than as set forth herein, the relative degree, if any, to which the Securities or the series shall be senior to or be subordinated to other series of Securities in right of payment, whether such other series of Securities are Outstanding or not; (v) any addition to or change in the Events of Default which applies to any Securities of the series and any change in the right of the Trustee or the requisite Holders of such Securities to declare the principal amount thereof due and payable pursuant to Section 5.2; (w) any addition to or change in the covenants set forth in Article X which applies to Securities of the series; and (x) any other terms of the Securities of such series (which terms shall not be inconsistent with the provisions of this Indenture, except as permitted by Section 9.1(6)). All Securities of any one series shall be substantially identical except as to denomination and except as may otherwise be provided herein or in or pursuant to such Board Resolution and set forth, or determined in the manner provided, in such Officers' Certificate or in any indenture supplemental hereto. If any of the terms of the series are established by action taken pursuant to a Board Resolution, a copy of an appropriate record of such action shall be certified by the Secretary or an Assistant Secretary of the Company and delivered to the Trustee at or prior to the delivery of the Officers' Certificate setting forth the terms of the series. The securities shall be subordinated in right of payment to Senior Indebtedness as provided in Article XIII.

  • Amounts and Terms of the Purchases SECTION 2.01.

  • Title and Terms; Denominations The aggregate number of Units evidenced by Certificates authenticated, executed on behalf of the Holders and delivered hereunder is limited to 40,000,000 Units except for Certificates authenticated, executed and delivered upon registration of transfer of, in exchange for, or in lieu of, other Certificates pursuant to Section 3.4, Section 3.5, Section 3.10, Section 3.12, Section 3.13, Section 5.9 or Section 8.5. The Certificates shall be issuable only in registered form and only in denominations of a single Corporate Unit or Treasury Unit and any integral multiple thereof.

  • Agreement and Term This Agreement records the Parties' agreement that:

  • Amounts and Terms of the Loans 33 2.1. The Revolving Credit Loans............................................................................ 33 2.2. Making the Loans...................................................................................... 33 2.3. Fees ................................................................................................ 35 2.4. Reduction and Termination of the Commitments.......................................................... 36 2.5. Repayment............................................................................................. 36 2.6. Prepayments........................................................................................... 37 2.7. Conversion/Continuation Option........................................................................ 38 2.8. Interest.............................................................................................. 39 2.9. Interest Rate Determination and Protection............................................................ 40 2.10.

  • Terms and Termination (a) Either party may terminate this Agreement without cause on or after July 31, 2002 by giving 180 days written notice to the other party; (b) Either party may terminate this Agreement if the other party has materially breached the Agreement by giving the defaulting party 30 days written notice and the defaulting party has failed to cure the breach within 60 days thereafter; and (c) Any written notice of termination shall specify the date of termination. The Fund shall provide notice of the successor transfer agent within 30 days of the termination date. Upon termination, FDISG will deliver to such successor a certified list of shareholders of the Fund (with names, addresses and taxpayer identification of Social Security numbers and such other federal tax information as FDISG may be required to maintain), an historical record of the account of each shareholder and the status thereof, and all other relevant books, records, correspondence, and other data established or maintained by the books, records, correspondence, and other data established or maintained by FDISG under this Agreement in the form reasonably acceptable to the Fund, and will cooperate in the transfer of such duties and responsibilities, including provisions for assistance from FDISG's personnel in the establishment of books, records and other data by such successor or successors. FDISG shall be entitled to its out-of-pocket expenses set forth in Schedule C incurred in the delivery of such records net of the fees owed to FDISG for the last month of service if this Agreement is terminated pursuant to paragraph (b) immediately above. (d) If a majority of the non-interested trustees of any of the Funds determines, in the exercise of their fiduciary duties and pursuant to their reasonable business judgement after consultation with Eaton Vance Management, that the perxxxxxxxx xf FDISG has been unsatisfactory or adverse to the interests of shareholders of any Fund or Funds or that the terms of the Agreement are no longer consistent with publicly available industry standards, then the Fund or Funds shall give written notice to FDISG of such determination and FDISG shall have 60 days (or such longer period if the non-interested Trustees so determine) to (1) correct such performance to the satisfaction of the non-interested trustees or (2) renegotiate terms which are satisfactory to the non-interested trustees of the Funds. If the conditions of the preceding sentence are not met then the Fund or Funds may terminate this Agreement on sixty (60) days written notice provided, however, that the provisions of Paragraph 11(c) shall remain outstanding for an additional 30 days if necessary to transfer records to a successor transfer agent. (e) If the Board of Trustees hereafter establishes and designates a new Fund, FDISG agrees that it will act as transfer agent and shareholder servicing agent for such new Fund in accordance with the terms set forth herein. The Trustees shall cause a written notice to be sent to FDISG to the effect that it has established a new Fund and that it appoints FDISG as transfer agent and shareholder servicing agent for the new Fund. Such written notice must be received by FDISG in a reasonable period of time prior to the commencement of operations of the new Fund to allow FDISG, in the ordinary course of its business, to prepare to perform its duties.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!