Measurements and arithmetic conventions All measurements and calculations shall be in the metric system and calculations done to 2 (two) decimal places, with the third digit of 5 (five) or above being rounded up and below 5 (five) being rounded down.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Payment for Working Overtime on a Holiday Where an employee is required to work authorized overtime in excess of his regularly scheduled hours on a paid holiday, such employee shall receive twice (2x) his regular straight time hourly rate for such authorized overtime.
Night Shift Differential Unit 12 employees who regularly work shifts shall receive a night shift differential as set forth below: A. Employees shall qualify for the first night shift pay differential of forty (40) cents per hour where four (4) or more hours of the regularly scheduled work shift falls between 6 p.m. and 12 midnight. B. Employees shall qualify for the second night shift pay differential of fifty (50) cents per hour where four (4) or more hours of the regularly scheduled work shift fall between 12 midnight and 6 a.m. C. A "regularly scheduled work shift" are those regularly assigned work hours established by the department director or designee.
Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
Purchases of Portfolio Shares for Sale to Customers (a) In offering and selling Portfolio shares to your customers, you agree to act as dealer for your own account; you are not authorized to act as agent for us or for any Portfolio.
Packaging Materials and Containers for Retail Sale 1. When packaging materials and containers in which a good is packaged for retail sales are classified in the Harmonized System with the good, they shall not be taken into account in determining whether all non-originating materials used in the production of the good undergo the applicable change in tariff classification set out in Annex 4.03. 2. When the good is subject to a requirement of regional value content, the value of these packaging materials and containers shall be taken into account as originating or non-originating materials, as the case may be, in calculating the regional value content of the good.
Night Shift Premium All hours worked by an employee between ten (10:00) p.m. and seven (7:00) a.m. shall be considered as shift work and paid for at the applicable straight time/overtime rate plus two ($2.00) dollars per hour shift premium for each full hour worked during this period. Night-shift premium shall not be added to the employee’s hourly rate of pay for the purpose of computing overtime pay.
