Limited Warranties State Street represents and warrants that it is the owner of and has the right to grant access to the System and to provide the Remote Access Services contemplated herein. Because of the nature of computer information technology including, but not limited to, the use of the Internet, and the necessity of relying upon third party sources, and data and pricing information obtained from third parties, the System and Remote Access Services are provided “AS IS”, and the Customer and its Authorized Designees shall be solely responsible for the investment decisions, results obtained, regulatory reports and statements produced using the Remote Access Services. State Street and its relevant licensors will not be liable to the Customer or its Authorized Designees for any direct or indirect, special, incidental, punitive or consequential damages arising out of or in any way connected with the System or the Remote Access Services, nor shall either party be responsible for delays or nonperformance under this Addendum arising out of any cause or event beyond such party’s control. State Street will take reasonable steps to ensure that its products (and those of its third-party suppliers) reflect the available state of the art technology to offer products that are Year 2000 compliant, including, but not limited to, century recognition of dates, calculations that correctly compute same century and multi century formulas and date values, and interface values that reflect the date issues arising between now and the next one-hundred years, and if any changes are required, State Street will make the changes to its products at no cost to you and in a commercially reasonable time frame and will require third-party suppliers to do likewise. The Customer will do likewise for its systems. EXCEPT AS EXPRESSLY SET FORTH IN THIS ADDENDUM, STATE STREET, FOR ITSELF AND ITS RELEVANT LICENSORS, EXPRESSLY DISCLAIMS ANY AND ALL WARRANTIES CONCERNING THE SYSTEM AND THE SERVICES TO BE RENDERED HEREUNDER, WHETHER EXPRESS OR IMPLIED INCLUDING, WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTIBILITY OR FITNESS FOR A PARTICULAR PURPOSE. State Street will defend or, at our option, settle any claim or action brought against the Customer to the extent that it is based upon an assertion that access to the System or use of the Remote Access Services by the Customer under this Addendum constitutes direct infringement of any patent or copyright or misappropriation of a trade secret, provided that the Customer notifies State Street promptly in writing of any such claim or proceeding and cooperates with State Street in the defense of such claim or proceeding. Should the System or the Remote Access Services or any part thereof become, or in State Street’s opinion be likely to become, the subject of a claim of infringement or the like under any applicable patent or copyright or trade secret laws, State Street shall have the right, at State Street’s sole option, to (i) procure for the Customer the right to continue using the System or the Remote Access Services, (ii) replace or modify the System or the Remote Access Services so that the System or the Remote Access Services becomes noninfringing, or (iii) terminate this Addendum without further obligation.
Manufacturer’s Warranties If a Lease Vehicle is covered by a Manufacturer’s warranty, the Lessee, during the Vehicle Term for such Lease Vehicle, shall have the right to make any claims under such warranty that the Lessor could make.
Supplier Warranties The warranties made by Supplier with respect to each Product are solely those that are contained in the product insert accompanying such Product. No other affirmation of fact or promise made by Distributor or its Suppliers, whether or not in this Agreement, by words or action shall constitute a warranty. The foregoing warranty does not extend to any Product that is modified or altered, or treated with abuse, negligence or other improper treatment. Standard Limited Warranty. Distributor shall pass on to Subdistributor so that it may pass on to the customers the Supplier’s standard limited warranty for Products, including limitations set for in subsection (b) Limitation of Liability and Warranty below. Except for the stated warranty set forth on, or included with, the Products as delivered to the Subdistributor and /or its customers, the warranty and remedy set forth in this 0 are exclusive and all other warranties, guarantees or representations, express or implied, by Distributor’s Suppliers with respect to the applicable Products, including, without limitation, warranties of merchantability and fitness for particular purpose, and any other obligation or liability of Distributor and its Suppliers to Subdistributor or to any third party with respect to the Products, are hereby excluded. This warranty is contingent upon proper use of a Product in the application for which such Product was intended and does not cover Products that were modified without Distributor or its Supplier’s prior written approval, that have expired or that were subjected to physical, chemical or electrical stress that the products were not originally designed for.
Service Warranties Contractor warrants that: (i) the Services will be rendered with promptness and diligence and will be executed in a workmanlike manner, in accordance with the practices and professional standards used in well-managed operations performing services similar to the Services; and (ii) Contractor will perform the Services in the most cost-effective manner consistent with the required level of quality and performance. Contractor warrants that each Deliverable will conform to and perform in accordance with the requirements of this Agreement and all applicable specifications and documentation. For each such Deliverable, the foregoing warranty shall commence for such Deliverable upon the JBE’s acceptance of such Deliverable, and shall continue for a period of one (1) year following acceptance. In the event any Deliverable does not to conform to the foregoing warranty, Contractor shall promptly correct all nonconformities to the satisfaction of the JBE.
Exclusion of Warranties CUSTOMER HEREIN ACKNOWLEDGES THAT ALL EQUIPMENT TO BE RENTED FROM XXXXXXXX CAMERA WILL BE AS A RESULT OF CUSTOMER’S SOLE SELECTION, DISCRETION AND OPINION AS TO EQUIPMENT WHICH IT REQUIRES. ALL EQUIPMENT IS ACCEPTED BY CUSTOMER “AS IS”. NO WARRANTIES OR REPRESENTATIONS ARE MADE BY XXXXXXXX CAMERA OF ANY TYPE OR NATURE WHATSOEVER, EXPRESSED OR IMPLIED, REGARDING THE PERFORMANCE OF CAMERAS, SERVICES, SUPPLIES, FILM OR OTHER EQUIPMENT RENTED. XXXXXXXX CAMERA HEREIN EXPRESSLY EXCLUDES ANY AND ALL WARRANTIES, GUARANTEES, EXPRESSED OR IMPLIED, STATUTORY, BY OPERATION OF LAW, OR OTHERWISE, INCLUDING ANY IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. IN NO EVENT, UNDER NO CIRCUMSTANCES, SHALL XXXXXXXX CAMERA BE RESPONSIBLE OR LIABLE TO CUSTOMER OR ANYONE ELSE FOR ANY DAMAGES, INCLUDING LOST PROFITS, LOST SAVINGS OR OTHER DIRECT OR INDIRECT INCIDENTAL OR CONSEQUENTIAL DAMAGES ARISING OUT OF THE USE OR INABILITY TO USE ANY EQUIPMENT RENTED OR THE ALLEGED BREACH OF ANY AGREEMENT DESCRIBED HEREIN, EVEN IN THE EVENT THAT XXXXXXXX CAMERA OR XXXXXXXX CAMERA’S AGENTS HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.
Manufacturer Warranties Prior to the transfer to the Interconnected Transmission Owner of title to the Transmission Owner Interconnection Facilities built by the Interconnection Customer, the Interconnection Customer shall produce documentation satisfactory to the Interconnected Transmission Owner evidencing the transfer to the Interconnected Transmission Owner of all manufacturer warranties for equipment and/or materials purchased by the Interconnection Customer for use and/or installation as part of the Transmission Owner Interconnection Facilities built by the Interconnection Customer.
DISCLAIMER OF ALL OTHER WARRANTIES EXCEPT AS EXPRESSLY PROVIDED IN THIS AGREEMENT, THE SOFTWARE IS PROVIDED ON AN “AS IS” BASIS AND TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW WE DISCLAIM ALL OTHER REPRESENTATIONS, WARRANTIES, CONDITIONS AND GUARANTEES, WHETHER EXPRESS, IMPLIED, STATUTORY OR OTHERWISE, INCLUDING ANY WARRANTIES, CONDITIONS OR GUARANTEES: (I) OF MERCHANTABILITY OR SATISFACTORY QUALITY; (II) OF FITNESS FOR A PARTICULAR PURPOSE; (III) OF NON- INFRINGEMENT; OR (IV) ARISING FROM CUSTOM OR TRADE USAGE OR BY ANY COURSE OF PRIOR DEALING OR COURSE OF PERFORMANCE. EXCEPT AS EXPRESSLY PROVIDED HEREIN, WE DO NOT WARRANT THAT YOUR USE OF THE SOFTWARE WILL BE UNINTERRUPTED OR ERROR-FREE, OR THAT THE SOFTWARE, DOCUMENTATION AND/OR THE INFORMATION OBTAINED BY YOU THROUGH THE SOFTWARE WILL MEET YOUR REQUIREMENTS OR PRODUCE PARTICULAR OUTCOMES OR RESULTS. WE ARE NOT RESPONSIBLE OR LIABLE FOR ANY ISSUES WITH THE SOFTWARE THAT ARISE FROM CUSTOMER DATA, THIRD-PARTY SERVICES OR THIRD- PARTY PROVIDERS. YOU ACKNOWLEDGE THAT WE DO NOT PROVIDE ANY ACCOUNTING, TAXATION, FINANCIAL, INVESTMENT, LEGAL OR OTHER ADVICE TO YOU, USERS, OR ANY THIRD PARTY. YOU ARE SOLELY RESPONSIBLE FOR THE TIMELY INSTALLATION OF MAINTENANCE AND WE SHALL HAVE NO LIABILTY FOR ANY ISSUES WITH THE SOFTWARE, OR FOR ANY CLAIMS, COSTS, DAMAGES, LOSSES, LIABILITIES AND EXPENSES WHICH YOU INCUR AS A RESULT OF YOUR FAILURE TO DO SO.
Limited Warranty Seller warrants to Customer for a period of twelve (12) months following delivery only that (a) the Products shall conform to the description and specifications, subject to industry standard tolerances and variations; and (b) Seller has good title to the Products free and clear of liens, security interests or encumbrances by any party claiming by, through or under Seller. SELLER HEREBY DISCLAIMS AND CUSTOMER HEREBY WAIVES ANY AND ALL OTHER ORAL OR WRITTEN WARRANTIES IN RESPECT OF THE PRODUCTS, EXPRESS OR IMPLIED, INCLUDING, WITHOUT LIMITATION, THE WARRANTIES OF DESIGN, MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. SELLER EXPRESSLY DISCLAIMS ANY AND ALL OTHER WARRANTIES UNLESS EXPRESSLY MADE IN WRITING AND SIGNED BY AN OFFICER OF SELLER. Seller’s liability shall be limited, at Seller’s option, to repair or replacement of non-conforming Products or refund of the purchase price. The foregoing sets forth Seller’s entire obligation and liability to Customer in respect of the Products, and Customer accepts the same as its entire right and sole remedy in relation to any breach by Seller of these Terms and Conditions. IN NO EVENT OR CIRCUMSTANCE WHATSOEVER SHALL SELLER BE LIABLE FOR ANY CONSEQUENTIAL, INCIDENTAL, INDIRECT, EXEMPLARY, PUNITIVE OR SPECIAL DAMAGES OF ANY TYPE OR NATURE EVEN IF SELLER HAS REASON TO KNOW OF THE POSSIBILITY OF SUCH DAMAGES. SELLER’S TOTAL LIABILITY ARISING OUT OF OR IN ANY WAY RELATED TO THE PRODUCTS, WHETHER BASED IN CONTRACT, WARRANTY, TORT (INCLUDING NEGLIGENCE AND/OR GROSS NEGLIGENCE), STRICT LIABILITY, OR ANY OTHER CAUSE OF ACTION, SHALL IN NO EVENT EXCEED THE PURCHASE PRICE ACTUALLY PAID BY CUSTOMER FOR THE PRODUCTS TO WHICH SUCH LIABILITY RELATES.
SUPPLIER’S WARRANTIES 16.1 The Supplier represents, warrants and undertakes to the Authority that: 16.1.1 the Supplier has the full right, power and authority to enter into and perform this Agreement and to grant all of the Authority Rights to the Authority and for the Authority to use and exploit the same as contemplated in this Agreement; 16.1.2 all information, representations, warranties and other matters of fact contained in the Supplier’s tender submission as part of the competitive tender process referred to in the recitals to this Agreement are true, complete and accurate in all respects and the Supplier agrees to be bound by the obligations and statements made in such tender submission as if the same were set out in this Agreement, save where there is any inconsistency between the terms of this Agreement and such tender submission the terms of this Agreement shall prevail; 16.1.3 save in respect of any Third Party Content, no Deliverable has and no Deliverable will have been broadcast, released or otherwise exploited in any Broadcast Media anywhere in the world prior to the relevant Delivery Date; 16.1.4 there is no contract or arrangement to which the Supplier is a party and the Supplier will not enter into any contract or arrangement and there is and will be no other encumbrance or restriction which could in any way interfere with or inhibit the full exercise or exploitation of any and all of the Authority Rights by the Authority; 16.1.5 the Supplier has paid and shall promptly pay all sums due to any person who is or may be entitled to any payment in respect of services or facilities rendered or goods supplied or rights granted in connection with the Deliverables or on the exercise by the Authority of any of the Authority Rights or in respect of any tax, duty, levy, national insurance or any similar payment in connection with the Deliverables required to be made by the Supplier; 16.1.6 the Supplier will have, by and as at the relevant Delivery Date, obtained all necessary consents, grants, clearances and rights (including any rights in musical compositions contained within the Deliverables (if any) which are controlled by the Performing Right Society or its affiliated bodies) to enable it to produce and deliver the Deliverables and to grant to and enable the Authority to exercise the Authority Rights free from any liens, claims and encumbrances; 16.1.7 to the extent any musical compositions are contained in the Deliverables: 16.1.7.1 all recording synchronisation and dubbing licences have been obtained and licence fees have been paid; and 16.1.7.2 the performing rights in such compositions shall throughout the Term be controlled (i) by the Performing Right Society or its affiliated bodies; or (ii) by the Supplier; or (iii) are in the public domain, in all cases to the extent required for the purposes of the Authority's full exercise of its rights as contemplated by this Agreement; 16.1.8 no claim or litigation is pending or threatened in respect of the Deliverables or any the Authority Rights; 16.1.9 the Deliverables will be produced in accordance with all Laws (including with respect to health and safety); 16.1.10 the Deliverables will be free from all Viruses; 16.1.11 the Deliverables will not contain anything which is in contravention of the Codes and Guidelines or any Laws or which is obscene, blasphemous, seditious, racially inflammatory, defamatory or which infringes the rights of any person, including rights of copyright or trade marks or service marks, privacy, publicity or confidentiality or any other civil or common law or statutory right whatsoever or breaches any contract or is in contempt of court; 16.1.12 the Supplier has not entered and will not enter into any co-production, co-financing, pre-sale or other arrangement or agreement which involves the surrender by the Supplier of any control of the Deliverables; 16.1.13 all information, records and data provided to the Authority and with respect to the Deliverables and the production process will be accurate in all respects, full and up to date; 16.1.14 the Supplier is not insolvent nor unable to pay its debts as they fall due and no steps have been taken with a view to the winding-up or administration of the Supplier or the making of any composition or arrangement with any creditors of the Supplier; and 16.1.15 the Supplier will not at any time do or say anything which is or may be considered by the Authority (acting reasonably) to be detrimental or prejudicial to or to affect adversely the name, image, reputation or business of the Authority or otherwise to bring the Authority or any member of the Authority Group into disrepute. 16.2 The Supplier's warranties shall be deemed repeated on each Delivery Date (or, if any Deliverables are delivered to the Authority after the scheduled Delivery Date and the Authority has not exercised any right under this Agreement to treat such delay as an Event of Default under clause 27.1, within ten Working Days of the date of actual delivery) and on every occasion when the Authority exercises its Authority Rights.
Representations, Warranties and Covenants of the Distributor A. The Distributor hereby represents and warrants to the Client, which representations and warranties shall be deemed to be continuing throughout the term of this Agreement, that: (i) it is duly organized and existing under the laws of the jurisdiction of its organization, with full power to carry on its business as now conducted, to enter into this Agreement and to perform its obligations hereunder; (ii) this Agreement has been duly authorized, executed and delivered by the Distributor and, when executed and delivered, will constitute a valid and legally binding obligation of the Distributor, enforceable in accordance with its terms, subject to bankruptcy, insolvency, reorganization, moratorium and other laws of general application affecting the rights and remedies of creditors and secured parties; (iii) it is conducting its business in compliance in all material respects with all applicable laws and regulations, both state and federal, and has obtained all regulatory approvals necessary to carry on its business as now conducted; there is no statute, rule, regulation, order or judgment binding on it and no provision of its charter, operating agreement or any contract binding it or affecting its property which would prohibit its execution or performance of this Agreement; and (iv) it is registered as a broker-dealer under the 1934 Act and is a member in good standing of FINRA. B. In connection with all matters relating to this Agreement, the Distributor will comply with the applicable requirements of the 1933 Act, the 1934 Act, the 1940 Act, the regulations of FINRA and all other applicable federal or state laws and regulations. C. The Distributor shall promptly notify the Client of the commencement of any litigation or proceedings against the Distributor or any of its managers, officers or directors in connection with the issue and sale of any of the Shares.
