City’s Right to Reject The City reserves the right to reject a certificate of insurance if Contractor’s insurance company is widely regarded in the insurance industry as financially unstable. This would include but is not limited to insurance companies with no less than AVIII rating in the A.M. Best insurance rating guide.
Right to Review After receiving written notice of the denial of a claim, a claimant or his representative shall be entitled to:
Right to Reject Notwithstanding Buyer’s rights pursuant to Sec. 8.5 and save other rights pursuant to this Order, Buyer may reject any goods within 2 months from the delivery if they are materially defective and in Buyer’s reasonable assessment do not allow a commercially reasonable use. In that case, no payments for these goods are due.
Right to Refuse Unsafe Work Employees have the right to refuse to perform unsafe work pursuant to the Occupational Health and Safety Regulations of the Workers Compensation Act.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.
Right to Receive Documentation a. Periodic Statements. Transfers and withdrawals made through any ATM or POS terminal, debit card transactions, audio response transactions, preauthorized EFTs, online/PC transactions, mobile access device transactions or xxxx payments you make will be recorded on your periodic statement. You will receive a statement monthly unless there is no transaction in a particular month. In any case, you will receive a statement at least quarterly.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Agency’s Right to Audit A. Performing Agency shall make available at reasonable times and upon reasonable notice, and for reasonable periods, work papers, reports, books, records, supporting documents kept current by Performing Agency pertaining to the Contract for purposes of inspecting, monitoring, auditing, or evaluating by System Agency and the State of Texas.
Right to Refuse Dangerous Work An employee shall have the right to refuse to work in situations, which can reasonably be considered dangerous.
