Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Contractor’s Performance Warranties Contractor represents and warrants to the State that:
(i) Each and all of the services shall be performed in a timely, diligent, professional and skillful manner, in accordance with the highest professional or technical standards applicable to such services, by qualified persons with the technical skills, training and experience to perform such services in the planned environment.
(ii) Any time software is delivered to the State, whether delivered via electronic media or the internet, no portion of such software or the media upon which it is stored or delivered will have any type of software routine or other element which is designed to facilitate unauthorized access to or intrusion upon; or unrequested disabling or erasure of; or unauthorized interference with the operation of any hardware, software, data or peripheral equipment of or utilized by the State. Without limiting the generality of the foregoing, if the State believes that harmful code may be present in any software delivered hereunder, Contractor will, upon State’s request, provide a new or clean install of the software. Notwithstanding the foregoing, Contractor assumes no responsibility for the State’s negligence or failure to protect data from viruses, or any unintended modification, destruction or disclosure.
(iii) To the extent Contractor resells commercial hardware or software it purchased from a third party, Contractor will, to the extent it is legally able to do so, pass through any such third party warranties to the State and will reasonably cooperate in enforcing them. Such warranty pass-through will not relieve the Contractor from Contractor’s warranty obligations set forth herein.
CONTRACTOR’S PERFORMANCE 2.21.1 Contractor shall make citizen satisfaction a priority in providing services under this Agreement. Contractor shall train its employees to be customer service-oriented and to positively and politely interact with citizens when performing contract services. Contractor’s employees shall be clean, courteous, efficient, and neat in appearance and committed to offering the highest quality of service to the public. If, in the Director’s opinion, Contractor is not interacting in a positive and polite manner with citizens, he or she shall direct Contractor to take all remedial steps to conform to these standards
Right to Compel Performance Notwithstanding the foregoing, upon the occurrence of an event of Default, a non-Defaulting Interconnection Party shall be entitled to (a) commence an action to require the Defaulting Interconnection Party to remedy such Default and specifically perform its duties and obligations hereunder in accordance with the terms and conditions hereof, (b) withhold payments, (c) suspend performance hereunder, and (d) exercise such other rights and remedies as it may have in equity or at law; provided, however, that the Transmission Provider shall not terminate the Interconnection Service Agreement due to the failure of Interconnection Customer to make a payment hereunder unless such failure could reasonably be expected to have a material adverse effect on the Interconnected Transmission Owner.
Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing.
2.1.2 The Train Operator may serve a Suspension Notice where a Network Rail Event of Default has occurred and is continuing.
Right to Specific Performance THE COMPANY HEREBY ACKNOWLEDGES AND AGREES THAT THE DAMAGES TO BE INCURRED BY PARTICIPANT AS A RESULT OF THE COMPANY’S BREACH OF THIS AGREEMENT WILL BE DIFFICULT, IF NOT IMPOSSIBLE, TO ASCERTAIN, THAT DAMAGES WILL NOT BE AN ADEQUATE REMEDY AND THAT ANY BREACH OR THREATENED BREACH OF ANY OF THE PROVISIONS OF THIS AGREEMENT BY THE COMPANY MAY CAUSE IMMEDIATE IRREPARABLE HARM FOR WHICH THERE MAY BE NO ADEQUATE REMEDY AT LAW. ACCORDINGLY, THE PARTIES AGREE THAT, IN THE EVENT OF ANY SUCH BREACH OR THREATENED BREACH, PARTICIPANT SHALL BE ENTITLED TO IMMEDIATE AND PERMANENT EQUITABLE RELIEF (INCLUDING INJUNCTIVE RELIEF AND SPECIFIC PERFORMANCE OF THE PROVISIONS OF THIS AGREEMENT) FROM A COURT OF COMPETENT JURISDICTION (IN ADDITION TO ANY OTHER REMEDY TO WHICH IT MAY BE ENTITLED AT LAW OR IN EQUITY). THE PARTIES AGREE AND STIPULATE THAT PARTICIPANT SHALL BE ENTITLED TO SUCH EQUITABLE (INCLUDING INJUNCTIVE) RELIEF WITHOUT POSTING A BOND OR OTHER SECURITY AND THE COMPANY FURTHER WAIVES ANY DEFENSE IN ANY SUCH ACTION FOR SPECIFIC PERFORMANCE OR INJUNCTIVE RELIEF THAT A REMEDY AT LAW WOULD BE ADEQUATE AND ANY REQUIREMENT UNDER LAW TO POST SECURITY AS A PREREQUISITE TO OBTAINING EQUITABLE RELIEF. NOTHING CONTAINED IN THIS SECTION SHALL LIMIT THE PARTIES’ RIGHT TO ANY REMEDIES AT LAW, INCLUDING THE RECOVERY OF DAMAGES FOR BREACH OF THIS AGREEMENT.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
No Right to Subcontracting Subcontractor may not subcontract, either part or in whole, the Services authorized under this Agreement.
Lessor's Right to Perform for Lessee If Lessee fails to make any payment of Rent required to be made by it hereunder or fails to perform or comply with any of its agreements contained herein, then (but in each case, except in the case of failure to pay Rent or in the case of failure to maintain insurance as required hereunder, no earlier than the fifteenth day after the occurrence of such failure, whether or not it shall yet constitute an Event of Default hereunder) Lessor may itself make such payment or perform or comply with such agreement but shall not be obligated hereunder to do so, and the amount of such payment and the amount of the reasonable expenses of Lessor incurred in connection with such payment or the performance of or compliance with such agreement, as the case may be, together with interest thereon at the Past Due Rate, shall be deemed Supplemental Rent, payable by Lessee upon demand.
Landlord’s Right to Perform Tenant’s Covenants Tenant covenants and agrees that, if it shall at any time fail to make any payment or perform any other act on its part to be made or performed as in this Lease provided, then Landlord, in its sole discretion may after due notice to, or demand upon, Tenant and subject to the limitations set forth below, make any payment or perform any other act on the part of Tenant to be made and performed as in this Lease provided, in such manner and to such extent as Landlord may reasonably deem desirable, and in exercising any such rights, Landlord may pay necessary and incidental costs and expenses, employ counsel, and incur and pay reasonable attorneys’ fees. The making of any such payment or the performing of any other act by Landlord pursuant to this Article shall not waive, or release Tenant from, any obligations of Tenant in this Lease contained. All sums so paid by Landlord and all reasonably necessary and incidental costs and expenses in connection with the performance of any such act by Landlord shall, except as otherwise in this Lease expressly provided, be payable to Landlord on demand, and Tenant covenants to pay any such sum or sums promptly, and Landlord shall have (in addition to any other right or remedy of Landlord) the same rights and remedies in the event of the non-payment thereof by Tenant as in the case of default by Tenant in the payment of the Base Rent. Whenever practicable, Landlord, before proceeding as provided in this Section 12.4, shall give Tenant notice in writing of the failure of Tenant which Landlord proposes to remedy, and shall allow Tenant such length of time as may be reasonable in the circumstances, consistent with any grace periods contained herein, but not exceeding 30 days from the giving of notice, to remedy the failure itself and, if Tenant shall not remedy the failure in the time so allowed, Landlord shall be deemed to have given “due notice” and may proceed as provided in this Section 12.4; provided that nothing in this Section shall prevent Landlord from acting without notice to Tenant in case of any emergency wherein there is danger to property or person or where there may exist any violation of legal requirements including but not limited to the presence of Hazardous Materials, in which event no notice shall be required.
