Utility Services Company agrees to pay the full cost and expense associated with its use of all utilities, including but not limited to water, sanitary sewer, electric, storm drainage, and telecommunication services.
Post-Closing Access Following the Closing, subject to applicable Law and subject to Section 5.6, Buyer shall (i) retain the Books and Records and any other material documents pertaining to the Transferred Assets and Assumed Liabilities conveyed and assumed at the Closing to the extent that such materials were delivered to Buyer or are otherwise in existence in Buyer’s possession at the Closing that are required to be retained under current retention policies for a period of five (5) years from the Closing Date, and (ii) provide Seller or its representatives at Seller’s expense with reasonable access without hindering the normal operations of the Business, during normal business hours, and upon reasonable advance notice and under the supervision of Xxxxx’s personnel, to the Books and Records with respect to periods or occurrences prior to the Closing Date for purposes of Seller’s preparation of financial statements, taxes, reporting obligations, litigation, compliance or as otherwise reasonably requested by Seller. Notwithstanding the foregoing provisions of this Section 5.2(b), Buyer may withhold access, documents or information, the disclosure of which in the reasonable judgment of Buyer would (A) result in the disclosure of any trade secrets of third parties or (B) violate any Law applicable to Buyer that requires Buyer to restrict or prohibit access to such information or (C) violate any of Buyer’s obligations with respect to confidentiality (provided Buyer uses its reasonable efforts to obtain a waiver or consent for such disclosure) or (D) result in the disclosure of any privileged information of Buyer. Following the Closing, subject to applicable Law and subject to Section 5.6, Seller shall (1) retain the Excluded Books and Records relating to the Business and any other material documents pertaining to the Transferred Assets and Assumed Liabilities not conveyed and assumed at the Closing for a period of five (5) years from the Closing Date, and (2) provide Buyer or its representatives at Buyer’s expense with reasonable access without hindering the normal operations of the Seller’s business, during normal business hours, and upon reasonable advance notice and under the supervision of Seller’s personnel, to the Excluded Books and Records relating to the Business and any other material documents pertaining to the Transferred Assets and Assumed Liabilities not conveyed and assumed at the Closing with respect to periods or occurrences prior to the Closing Date solely for Buyer’s preparation of financial statements, taxes, reporting obligations, litigation, compliance or as otherwise reasonably requested by Buyer. Notwithstanding the foregoing provisions of this Section 5.2(b), Seller may withhold access, documents or information, the disclosure of which in the reasonable judgment of Seller would (I) result in the disclosure of any trade secrets of third parties or (II) violate any Law applicable to Seller that requires Seller to restrict or prohibit access to such information, (III) violate any of Seller’s obligations with respect to confidentiality (provided Seller uses its reasonable efforts to obtain a waiver or consent for such disclosure) or (IV) result in the disclosure of any privileged information of Seller. Notwithstanding anything to the contrary set forth herein, neither Seller nor Buyer shall be required by this Agreement to provide the other Party with access, documents or information in connection with a dispute, claim or litigation between Buyer or any Affiliates of Buyer, on the one hand, and Seller or any Affiliates of Seller, on the other hand, except as may be required in accordance with applicable Laws, including rules of discovery.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Shared Loss Arrangement 1 2.1 Accounting for and Management of Shared-Loss Assets 1
Shared Services 5.1.1 ETFO agrees to adopt a shared services model that will allow other Trusts to join the shared services model. The shared services office of the Trust is responsible for the services to support the administration of benefits for the members, and to assist in the delivery of benefits on a sustainable, efficient and cost effective basis.
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Information Systems Acquisition Development and Maintenance Security of System Files. To protect City Information Processing Systems and system files containing information, Service Provider will ensure that access to source code is restricted to authorized users whose specific job function necessitates such access.
Working Facilities During the Term of Employment, the Company shall furnish the Executive with an office, secretarial help and such other facilities and services suitable to his position and adequate for the performance of his duties hereunder.
Transportation Management Tenant shall fully comply with all present or future programs intended to manage parking, transportation or traffic in and around the Building, and in connection therewith, Tenant shall take responsible action for the transportation planning and management of all employees located at the Premises by working directly with Landlord, any governmental transportation management organization or any other transportation-related committees or entities.
