Commencement date 3 Sample Clauses

Commencement date 3. (6) Subject to the approval by the Minister or determination by arbitration as herein provided of each and every of the detailed proposals and matters referred to in clause 6(1) the date upon which the last of those proposals of the Joint Venturers shall have been so approved or determined shall be the commencement date for the purposes of this agreement.
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Commencement date 3. If the Commencement Date is not the first day of a calendar month, then the Term shall be extended by the time between the Commencement Date and the first day of the next month. In the event Tenant occupies the Premises prior to the scheduled Commencement Date, the Commencement Date shall be defined as the date such occupancy commences. If this Lease is executed before the Premises become vacant or otherwise available and ready for occupancy by Tenant, or if any present occupant of the Premises holds over and Landlord cannot acquire possession of the Premises before the Commencement Date, then (a) Tenant's obligation to pay Rent hereunder shall be waived until Landlord tenders possession of the Premises to Tenant, (b) the Term shall be extended by the time between the scheduled Commencement Date and the date on which Landlord tenders possession of the Premises to Tenant (which date will then be defined as the Commencement Date), (c) Landlord shall not be in default hereunder or be liable for damages therefor, and (d) Tenant shall accept possession of the Premises when Landlord tenders possession thereof to the Tenant. With the exception of the Temporary Space, by occupying the Premises, Tenant shall be deemed to have accepted the Premises in their condition as of the date of such occupancy, subject to the performance of punch-list items that remain to be performed by Landlord, if any, Landlord shall have the right, but not the Initial ______________
Sample 1

Related to Commencement date 3

  • Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):

  • Commencement Date Memorandum When the actual Commencement Date is determined, the parties shall execute a Commencement Date Memorandum, in the form attached hereto as EXHIBIT D, setting forth the Commencement Date and Expiration Date.

  • Commencement Date and Term 1.1 This Agreement shall come into force on [insert date] (the “Commencement Date”) and, subject to paragraph 1.2 below, shall continue in full force and effect until [insert date] OR [until all Services have been completed and all Deliverables have been delivered to the British Council’s satisfaction as set out in Schedule 2 (Terms of Reference)] (the “Term”).

  • Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans: the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.

  • Commencement Date The Subcontractor shall be permitted to begin the Services on , 20 (“Commencement Date”).

  • Term Commencement Date The term of this Agreement shall commence on , 2020 (the “Commencement Date”) and, unless earlier terminated in accordance with the terms of this Agreement, shall end on June 30, 2055 (the “Term”).

  • Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).

  • Adjustment of Commencement Date; Possession 3.01 If Landlord is required to perform Landlord Work prior to the Commencement Date: (a) the date set forth in Section 1.06 as the Commencement Date shall instead be defined as the “Target Commencement Date”; (b) the actual Commencement Date shall be the date on which the Landlord Work is Substantially Complete (defined below); and (c) the Termination Date will the last day of the Term as determined based upon the actual Commencement Date. Landlord’s failure to Substantially Complete the Landlord Work by the Target Commencement Date shall not be a default by Landlord or otherwise render Landlord liable for damages. Promptly after the determination of the Commencement Date, Landlord and Tenant shall enter into a commencement letter agreement in the form attached as Exhibit D. If the Termination Date does not fall on the last day of a calendar month, Landlord and Tenant may elect to adjust the Termination Date to the last day of the calendar month in which Termination Date occurs by the mutual execution of a commencement letter agreement setting forth such adjusted date. The Landlord Work shall be deemed to be “Substantially Complete” on the date that all Landlord Work has been performed, other than any details of construction, mechanical adjustment or any other similar matter, the non-completion of which does not materially interfere with Tenant’s use of the Premises. If Landlord is delayed in the performance of the Landlord Work as a result of the acts or omissions of Tenant, the Tenant Related Parties (defined in Section 13) or their respective contractors or vendors, including, without limitation, changes requested by Tenant to approved plans, Tenant’s failure to comply with any of its obligations under this Lease, or the specification of any materials or equipment with long lead times (a “Tenant Delay”), the Landlord Work shall be deemed to be Substantially Complete on the date that Landlord could reasonably have been expected to Substantially Complete the Landlord Work absent any Tenant Delay.

  • Effective Date; Term This Agreement shall become effective on the date of its execution and shall remain in force for a period of two (2) years from such date, and from year to year thereafter but only so long as such continuance is specifically approved at least annually by the vote of a majority of the Trustees who are not interested persons of the Trust or the Adviser, cast in person at a meeting called for the purpose of voting on such approval, and by a vote of the Board of Trustees or of a majority of the outstanding voting securities of the Fund. The aforesaid requirement that this Agreement may be continued "annually" shall be construed in a manner consistent with the Act and the rules and regulations thereunder.

  • ANNUITY COMMENCEMENT DATE The Valuation Date on which the Contract Value is withdrawn for payment of annuity benefits under the Annuity Payment Option selected.

Time is Money Join Law Insider Premium to draft better contracts faster.