Company’s General Indemnity Sample Clauses

Company’s General Indemnity. Company shall release, defend, indemnify and hold harmless Owner and its subsidiaries and Affiliates, directors, officers, agents, employees, successors and assigns, and the owners of the real property comprising the Project Site (each of the foregoing, an “Owner Indemnified Party”) from and against any and all losses, costs, damages, injuries, liabilities, claims, demands, fines, penalties, assessments, interest, causes of action, and expenses, including reasonable attorney’s fees (collectively, “Losses”), asserted against any Owner Indemnified Party to the extent and as a result of any and all of the following:
AutoNDA by SimpleDocs
Company’s General Indemnity. Company shall release Contractor Group from any liability for, and shall protect, Defend and indemnify Contractor Group from and against all Losses, without limit and REGARDLESS OF 4 3510625v1 FAULT, arising in connection herewith in favor of Company Group and Company Group's employees on account of bodily injury, death or damage to property.
Company’s General Indemnity. The Company shall indemnify and keep indemnified the Contractor from and against all claims in connection with the Agreement arising from:

Related to Company’s General Indemnity

  • General Indemnity Without limiting any other provision of this Agreement or of any other Loan Document, Borrowers hereby jointly and severally indemnify each Lender, the Agent and their respective directors, officers, employees, Affiliates and agents (collectively, "Indemnified Persons") against, and agree to hold each such Indemnified Person harmless from, any and all claims, damages and liabilities, including claims brought by any shareholder or former shareholder of any Borrower, and related expenses, including reasonable counsel fees and expenses, incurred by such Indemnified Person arising out of any claim, litigation, investigation or proceeding (whether or not such Indemnified Person is a party thereto) relating to any transactions, services or matters that are the subject or arise in connection with or as a result of this Agreement or the transactions contemplated hereby (including, without limitation, relating to the properties or business of any Borrower, or any default by a Borrower in the performance or observance of any representation, warranty, covenant or condition in this Agreement or any other Loan Document); provided, however, that such indemnity shall not apply to any such losses, claims, damages, or liabilities or related expenses determined by a court of competent jurisdiction to have arisen from the gross negligence, willful misconduct or subjective bad faith of such Indemnified Person, and if such Indemnified Person is a director, officer, employee, Affiliate or agent of a Lender or the Agent, then, to the extent of such gross negligence, willful misconduct or subjective bad faith, such indemnity shall not apply to such Lender or the Agent, as applicable. If any litigation or proceeding is brought against any Indemnified Person in respect of which indemnity may be sought against Borrowers pursuant to this Section 2.22, such Indemnified Person shall promptly notify Borrowers in writing of the commencement of such litigation or proceeding, but the omission so to notify Borrowers shall not relieve Borrowers from any other obligation or liability which it may have to any Indemnified Person, except that no Borrower waives any rights for damages incurred by it on account of such delay. Failure of the Indemnified Person to timely notify Borrowers of the commencement of such litigation or proceeding shall not relieve Borrowers of their obligations under this Section 2.22, except where such failure irrevocably prejudices Borrowers' ability to defend such litigation or proceeding. In case any such litigation or proceeding shall be brought against any Indemnified Person and such Indemnified Person shall notify Borrowers of the commencement of such litigation or proceeding, Borrowers shall be entitled to participate in such litigation or proceeding and, after written notice from Borrowers to such Indemnified Person, to assume the defense of such litigation or proceeding with counsel of its choice at its expense, provided that such counsel is satisfactory to the Indemnified Person in the exercise of its reasonable judgment. Notwithstanding the election of Borrowers to assume the defense of such litigation or proceeding, such Indemnified Person shall have the right to employ separate counsel and to participate in the defense of such litigation or proceeding, and Borrowers shall bear the reasonable fees, costs and expenses of such separate counsel if (i) the use of counsel chosen by Borrowers to represent such Indemnified Person would present such counsel with a conflict of interest; (ii) the defendants in, or targets of, any such litigation or proceeding include both an Indemnified Person and any Borrower, and such Indemnified Person shall have reasonably concluded that there may be legal defenses available to it which are different from or additional to those available to any Borrower (in which case Borrowers shall not have the right to direct the defense of such action on behalf of the Indemnified Person); (iii) Borrowers shall not have employed counsel satisfactory to such Indemnified Person in the exercise of the Indemnified Person's reasonable judgment to represent such Indemnified Person within a reasonable time after notice of the institution of such litigation or proceeding; or (iv) Borrowers shall authorize such Indemnified Person to employ separate counsel at the expense of Borrowers, provided that Borrowers shall not be liable for the fees, costs and expenses of more than one separate counsel at the same time for all such Indemnified Persons in connection with the same action and any separate but substantially similar or related action in the same jurisdiction. Borrowers shall not consent to the entry of any judgment or enter into any settlement in any such litigation or proceeding unless such judgment or settlement includes as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Person of a release from all liability in respect to such claim or litigation. The agreements of Borrowers in this Section 2.22 shall be in addition to any liability that Borrowers may otherwise have. All amounts due under this Section 2.22 shall be payable within ten (10) days of written demand therefor.

  • General Indemnification Supplier agrees to protect, defend, indemnify and save DXC harmless from all sums, costs and expenses as a result of any and all loss, expense, damage, liability, claims, demands, either at law or in equity, resulting from any personal injury or death, or damages to property resulting directly or indirectly from the performance of Supplier hereunder.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!