Termination Compensation Termination Compensation equal to two (2) times the Executive's Base Period Income shall be paid to the Executive in a single sum payment in cash on the thirtieth (30th) business day after the later of (a) the Control Change Date and (b) the date of the Executive's employment termination; provided that if at the time of the Executive's termination of employment the Executive is a Specified Employee, then payment of the Termination Compensation to the Executive shall be made on the first day of the seventh (7th) month following the Executive's employment termination.
Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.
Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.
Compensation for Convenience Termination If City shall terminate for its convenience as herein provided, City shall compensate Consulting Engineer/Architect for all Engineering/Architectural Services satisfactorily completed to date of its receipt of the termination notice and any additional Engineering/Architectural Services requested by City to bring the Project to reasonable termination. Compensation shall not include anticipatory profit or consequential damages, neither of which will be allowed.
Compensation for Reimbursable Expenses 11.8.1 Reimbursable Expenses are in addition to compensation for Basic, Supplemental, and Additional Services and include expenses incurred by the Architect and the Architect’s consultants directly related to the Project, as follows:
Compensation Schedule Except as otherwise provided herein, employees shall be compensated within the pay range assigned to the classification of the position in which they are employed and in accordance with the pertinent conditions of employment enumerated in this Agreement. Sec. 503 REGULAR PAY DAY: Employees shall be paid on or about the Friday following the end of the biweekly payroll period.
Compensation for Unused Sick Leave 1. Employees who enter County service after July 1, 1979, shall not be eligible for compensation for any of their unused sick leave credits.
Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -
