Contractors and Subcontractors Drug-Free Workplace Act of 1988
1) Publish and give a policy statement to all covered employees informing them that the unlawful manufacture, distribution, dispensation, possession or use of a controlled substance is prohibited in the covered workplace and specifying the actions that will be taken against employees who violate the policy.
2) Establish a drug-free awareness program to make employees aware of a) the dangers of drug abuse in the workplace; b) the policy of maintaining a drug-free workplace; c) any available drug counseling, rehabilitation, and employee assistance programs; and d) the penalties that may be imposed upon employees for drug abuse violations.
3) Notify employees that as a condition of employment on a federal contract or grant, the employee must a) abide by the terms of the policy statement; and b) notify the employer, within five (5) calendar days, if he or she is convicted of a criminal drug violation in the workplace.
4) Notify the contracting or granting agency within ten (10) days after receiving notice that a covered employee has been convicted of a criminal drug violation in the workplace.
5) Impose a penalty on or require satisfactory participation in a drug abuse assistance or rehabilitation program by any employee who is convicted of a reportable workplace drug conviction.
6) Make an ongoing, good faith effort to maintain a drug-free workplace by meeting the requirements of the act.
Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.
SUBCONTRACTORS AND SUPPLIERS The Commissioner reserves the right to reject any proposed Subcontractor or supplier for bona fide business reasons, including, but not limited to: the company failed to solicit New York State certified minority- and women-owned business enterprises as required in prior OGS Contracts; the fact that such Subcontractor or supplier is on the New York State Department of Labor’s list of companies with which New York State cannot do business; the Commissioner’s determination that the company is not qualified or is not responsible; or the fact that the company has previously provided unsatisfactory work or services.
Contractor’s Employees and Subcontractors (a) Contractor shall only disclose PII to Contractor’s employees and subcontractors who need to know the PII in order to provide the Services and the disclosure of PII shall be limited to the extent necessary to provide such Services. Contractor shall ensure that all such employees and subcontractors comply with the terms of this DPA.
(b) Contractor must ensure that each subcontractor performing functions pursuant to the Service Agreement where the subcontractor will receive or have access to PII is contractually bound by a written agreement that includes confidentiality and data security obligations equivalent to, consistent with, and no less protective than, those found in this DPA.
(c) Contractor shall examine the data security and privacy measures of its subcontractors prior to utilizing the subcontractor. If at any point a subcontractor fails to materially comply with the requirements of this DPA, Contractor shall: notify the EA and remove such subcontractor’s access to PII; and, as applicable, retrieve all PII received or stored by such subcontractor and/or ensure that PII has been securely deleted and destroyed in accordance with this DPA. In the event there is an incident in which the subcontractor compromises PII, Contractor shall follow the Data Breach reporting requirements set forth herein.
(d) Contractor shall take full responsibility for the acts and omissions of its employees and subcontractors.
(e) Contractor must not disclose PII to any other party unless such disclosure is required by statute, court order or subpoena, and the Contractor makes a reasonable effort to notify the EA of the court order or subpoena in advance of compliance but in any case, provides notice to the EA no later than the time the PII is disclosed, unless such disclosure to the EA is expressly prohibited by the statute, court order or subpoena.
Contractor’s Project Manager 7.2.1 The Contractor’s Project Manager is designated in Exhibit F (Contractor’s Administration). The Contractor shall notify the County in writing of any change in the name or address of the Contractor’s Project Manager.
7.2.2 The Contractor’s Project Manager shall be responsible for the Contractor’s day-to-day activities as related to this Contract and shall meet and coordinate with County’s Project Manager and County’s Contract Project Monitor on a regular basis.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Payroll Records Contractors and Subcontractors must keep original payrolls or transcripts subscribed and affirmed as true under the penalties of perjury as required by law. For public works contracts over $25,000 where the Contractor maintains no regular place of business in New York State, such records must be kept at the work site. For building services contracts, such records must be kept at the work site while work is being performed.
CONTRACTOR's Agents and Subcontractors To impose the same restrictions and conditions set forth in this Personal Information and Security Contract on any subcontractors or other agents with whom CONTRACTOR subcontracts any activities under the Agreement that involve the disclosure of DHCS PI or PII to such subcontractors or other agents.
Employees and Subcontractors It is understood that, from time to time, it may become necessary for the Contractor to replace an individual working as an employee or subcontractor of the Contractor. All such removals or replacements shall be subject to Owner’s prior approval. Owner reserves the right to approve a replacement, which approval shall not be unreasonably withheld, or terminate the Work, either partially or in its entirety without further obligation to the Contractor thereunder other than to remit payment for the Work rendered up to the termination date. Contractor agrees that Owner may, at any time, with cause, require Contractor to remove an individual from the performance of the Work. An election by Owner of any of its rights under this Section 19 shall not affect the Contractor’s responsibilities, liabilities or warranties under this Agreement.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
