Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.
Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.
Preservation, Maintenance, and Protection of the Property Inspections. Borrower will not destroy, damage, or impair the Property, allow the Property to deteriorate, or commit waste on the Property. Whether or not Borrower is residing in the Property, Borrower must maintain the Property in order to prevent the Property from deteriorating or decreasing in value due to its condition. Unless Lender determines pursuant to Section 5 that repair or restoration is not economically feasible, Borrower will promptly repair the Property if damaged to avoid further deterioration or damage. If insurance or condemnation proceeds are paid to Lender in connection with damage to, or the taking of, the Property, Borrower will be responsible for repairing or restoring the Property only if Xxxxxx has released proceeds for such purposes. Lender may disburse proceeds for the repairs and restoration in a single payment or in a series of progress payments as the work is completed, depending on the size of the repair or restoration, the terms of the repair agreement, and whether Borrower is in Default on the Loan. Lender may make such disbursements directly to Borrower, to the person repairing or restoring the Property, or payable jointly to both. If the insurance or condemnation proceeds are not sufficient to repair or restore the Property, Borrower remains obligated to complete such repair or restoration. Lender may make reasonable entries upon and inspections of the Property. If Lender has reasonable cause, Xxxxxx may inspect the interior of the improvements on the Property. Lender will give Borrower notice at the time of or prior to such an interior inspection specifying such reasonable cause.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.
Maintenance Repairs and Alterations A. Except to the extent such obligations are imposed upon Landlord hereunder, Tenant shall, at its sole cost and expense, maintain the interior of the Premises in good order, condition and repair throughout the entire Lease Term, ordinary wear and tear excepted. Tenant agrees to keep the areas visible from outside the Premises in a neat, clean and attractive condition at all times. Tenant shall, within thirty (30) days after Landlord’s written demand therefor, reimburse Landlord for the cost of all repairs, replacements and alterations (collectively, “Repairs”) in and to the Premises, Building and Property and the facilities and systems thereof, plus an administration charge often percent (10%) of such cost, the need for which Repairs arises out of (and provided Landlord has given prior written notice to Tenant of such need): (1) Tenant’s use of the Premises in contravention of the terms and conditions of this Lease, or Tenant’s failure to perform maintenance or repairs which are Tenant’s obligation hereunder, (2) the installation, removal, use or operation of Tenant’s Property, if undertaken by Landlord at Tenant’s request or by virtue of Tenant’s default in undertaking such obligations, (3) the moving of Tenant’s Property into or out of the Building, or (4) the act, omission, misuse or negligence of Tenant, its agents, contractors, employees or invitees. B. Tenant shall not make or allow to be made any alterations, additions or improvements to the Premises (collectively, “Alterations”), without first obtaining the written consent of Landlord, which consent shall not be unreasonably withheld or delayed; provided however, Tenant shall have the right to perform, without Landlord’s consent, certain Alterations that do not cost in excess of $25,000.00 in the aggregate (at any one time), and do not affect any mechanical or electrical or life safety systems or plumbing in the Building, provided that advance notice has been given to Landlord in each instance. Landlord reserves the right to require Tenant to remove at the end of the Lease Term any Alterations installed without the Landlord’s consent. Prior to commencing any such Alterations and as a condition to obtaining Landlord’s consent where necessary, Tenant shall deliver to Landlord plans and specifications acceptable to Landlord; names and addresses of contractors reasonably acceptable to Landlord; copies of contracts; necessary permits and approvals; evidence of contractor’s and subcontractor’s insurance in accordance with Section 13 hereof; and a payment bond or other security, all in form and amount satisfactory to Landlord. Tenant shall be responsible for insuring that all such persons procure and maintain insurance coverage against such risks, in such amounts and with such companies as Landlord may reasonably require. All Alterations shall be constructed in a good and workmanlike manner using Building standard materials or other new materials of equal or greater quality. Landlord, to the extent reasonably necessary to avoid any disruption to the tenants and occupants of the Building, shall have the right to designate the time when any Alterations may be performed and to otherwise designate reasonable rules, regulations and procedures for the performance of work in the Building. Upon completion of the Alterations, Tenant shall deliver to Landlord “as-built” plans, contractor’s affidavits and full and final waivers of lien and receipted bills covering all labor and materials. All Alterations shall comply with the insurance requirements and with applicable codes, ordinances, laws and regulations. Tenant shall reimburse Landlord upon demand for all reasonable sums, if any, expended by Landlord for third party examination of the architectural, mechanical, electrical and plumbing plans for any Alterations. In addition, if Landlord so requests, Landlord shall be entitled to oversee the construction of any Alterations, and in such event, Tenant shall reimburse Landlord for Landlord’s actual out of pocket costs incurred in connection therewith, which may include the cost of management personnel working outside of Normal Business Hours. Landlord’s approval of Tenant’s plans and specifications for any Alterations performed for or on behalf of Tenant shall not be deemed to be representation by Landlord that such plans and specifications comply with applicable insurance requirements, building codes, ordinances, laws or, regulations or that the Alterations constructed in accordance with such plans and specifications will be adequate for Tenant’s use.
Installation and Maintenance Except for the bi‐directional and production metering equipment owned by the City, all equipment on Customer’s side of the delivery point, including the required disconnect device, shall be provided and maintained in satisfactory operating condition by Customer and shall remain the property and responsibility of the Customer. The City will bear no responsibility for the installation or maintenance of Customer’s equipment or for any damage to property as a result of any failure or malfunction thereof. The City shall not be liable, directly or indirectly for permitting or continuing to allow the interconnection of the Facility or for the acts or omissions of Customer or the failure or malfunction of any equipment of Customer that causes loss or injury, including death, to any party.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Installation and Use Rights You may install and use any number of copies of the software on your devices.
Maintenance, Alteration and Repair (a) Resident is responsible for and agrees to take good care of the premises, fixtures and all common areas. Resident may not remove any of Owner’s property and will not perform any repairs, upgrades, painting, wallpapering, electric changes or other alterations of the premises without prior written consent from Owner. Resident will be responsible for damage from waste stoppages caused by foreign or improper objects or improper use in lines serving bathrooms, damage to fixtures, appliances, doors, windows, screens, damage from water faucets left on or from doors left open, and repairs or replacements to alarm devices necessitated by misuse or damage by Resident and/or guests. Extraordinary appliances or furnishings such as satellite dishes, hot tubs, pool tables, water beds or high utility- consuming devices may not be installed or placed on the premises or anywhere at the Property without Owner’s prior written consent, in its sole discretion. (b) In the case of a malfunction of any utilities or damage by fire, water or similar cause, or any water leak, suspected mold or microbial growth, electrical problem, broken glass, broken lock or any other condition that Resident reasonably believes poses a hazard to health and safety, Resident must promptly notify Owner in writing. Owner will act with reasonable time and diligence in making repairs and reconnections; Resident may not withhold or reduce payment of rent or other charges during such time. Maintenance and repair requested by Resident will generally be performed between 8am and 8pm, unless the work is considered an emergency, in which case work may take place at any time. Owner may temporarily disconnect equipment or utilities to avoid property damage and/or to perform repairs requiring such interruption, in Owner’s sole discretion. Owner will not be liable for any inconvenience, discomfort, disruption or interference with Resident use of the premises because of ongoing repairs, alterations or improvements to the Property or any apartment. (c) Following move-in, Resident is responsible for providing and changing all light bulbs and batteries (for smoke detectors and remote controls) in the assigned apartment. A written maintenance report requesting assistance in changing these items may be submitted for maintenance staff assistance, with extra charges payable by Resident as applicable per Owner’s published rates. From time to time, maintenance staff may enter the assigned apartment with or without notice to inspect and change furnace filters and to provide pest control.