Completion Management of the Company
Completion Management of the Company Sample Clauses
Related to Completion Management of the Company
Management of the Company The Company's business and affairs shall be conducted and managed by the Member(s) in accordance with this Agreement and the laws of the State of the Formation. Single-Member (Applies ONLY if Single-Member): The Member(s) of the Company has sole authority and power to act for or on behalf of the Company, to do any act that would be binding on the Company or incur any expenditures on behalf of the Company. The Member(s) shall not be liable for the debts, obligations, or liabilities of the Company, including under a judgment, decree, or order of a court. The Company is organized as a “member-managed” limited liability company. The Member(s) is designated as the initial managing Member(s). Multi-Member (Applies ONLY if Multi-Member): Except as expressly provided elsewhere in this Agreement, all decisions respecting the management, operation, and control of the business and affairs of the Company and all determinations made in accordance with this Agreement shall be made by the affirmative vote or consent of Member(s) holding a majority of the Members’ Percentage Interests. Notwithstanding any other provision of this Agreement, the Member shall not, without the prior written consent of the unanimous vote or consent of the Member(s), sell, exchange, lease, assign or otherwise transfer all or substantially all of the assets of the Company; sell, exchange, lease (other than space leases in the ordinary course of business), assign or transfer the Company’s assets; mortgage, pledge or encumber the Company’s assets other than is expressly authorized by this Agreement; prepay, refinance, modify, extend or consolidate any existing mortgages or encumbrances; borrow money on behalf of the Company; lend any Company funds or other assets to any person or entity; establish any reserves for working capital repairs, replacements, improvements or any other purpose; confess a judgment against the Company; settle, compromise or release, discharge or pay any claim, demand or debt, including claims for insurance; approve a merger or consolidation of the Company with or into any other limited liability company, corporation, partnership or other entity; or change the nature or character of the business of the Company. The Member(s) shall receive such sums for compensation as Member(s) of the Company as may be determined from time to time by the affirmative vote or consent of Member(s) holding a majority of the Member(s)’ Percentage Interests.
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Union Management Relations Any changes deemed necessary in this Agreement may be made by mutual agreement of the parties at any time during the life of this Agreement.
Management and Control of the Company The Manager shall direct, manage and control the business of the Company to the best of such Manager’s ability and shall have full and complete authority, power and discretion to make any and all decisions and to do any and all things which the Manager shall deem to be reasonably required in light of the Company’s business and objectives. (1) No Member except one who shall also be a Manager may participate in or have any control over the Company business or have any authority or right to act for or bind the Company. The Member hereby consents to the exercise by the Manager of the powers respectively conferred on it by this Agreement. (2) The Manager may, if appropriate, establish, if Company funds are available, reserves for working capital and for payment of taxes, insurance, debt service, repairs, replacements or renewals, or other costs and expenses incident to the operation of the Company and the property of the Company and for such other purposes as the Manager may determine and thereafter shall maintain such reserves in such amounts as the Manager deems appropriate under the circumstances to the extent that any such reserves are not in conflict with any other provisions of this Agreement regarding any required disbursements.
Utilization Management Contractor shall maintain a utilization management program that complies with applicable laws, rules and regulations, including Health and Safety Code § 1367.01 and other requirements established by the applicable State Regulators responsible for oversight of Contractor.
Construction Manager The individual, partnership, corporation, joint venture, or any combination thereof, or its authorized representative, named as such by the District. If no Construction Manager is used on the Project that is the subject of this Contract, then all references to Construction Manager herein shall be read to refer to District.
Management of Company 5.1.1 The Members, within the authority granted by the Act and the terms of this Agreement shall have the complete power and authority to manage and operate the Company and make all decisions affecting its business and affairs. 5.1.2 Except as otherwise provided in this Agreement, all decisions and documents relating to the management and operation of the Company shall be made and executed by a Majority in Interest of the Members. 5.1.3 Third parties dealing with the Company shall be entitled to rely conclusively upon the power and authority of a Majority in Interest of the Members to manage and operate the business and affairs of the Company.
Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:
