Completion of Transformation/Transition Sample Clauses

Completion of Transformation/Transition. (a) Client reserves the right to monitor, test and otherwise observe and participate in the Transformation/Transition. Provider will notify Client without delay if any Client monitoring, testing or participation has caused (or Provider expects it to cause) a problem or delay in the Transformation/Transition and work with Client to mitigate the impact of the problem or delay, including the adjustment of Transformation/Transition Milestones and the Transformation/Transition Completion Date. (b) Client may elect, at its reasonable discretion, to suspend or delay a Transformation/Transition activity at any time, including in the event such Transformation/Transition activity is not proceeding in accordance with the requirements of the approved Transformation/Transition project and other Transformation/Transition Documents or is causing unplanned disruptions or other adverse effects to Client (or other Eligible Recipient). During any suspension or delay period, Provider, to the extent possible, will perform the Services as required under this Agreement in the manner the Services were performed prior to the commencement of the applicable Transformation/Transition activity. If Client elects to suspend or delay a Transformation /Transition activity and Client’s decision is not based, at least in material part, on reasonable concerns about Provider’s ability to perform the Transformation/Transition Services or Provider’s failure to perform its obligations under the applicable Transformation/Transition Documents, Client shall reimburse Provider for any additional expenses reasonably incurred by Provider as a result of such decision (provided that Provider notifies Client in advance of such expenses, obtains Client’s approval prior to incurring such expenses, and uses Commercially Reasonable Efforts to minimize such expenses).
Sample 1
AutoNDA by SimpleDocs

Related to Completion of Transformation/Transition

  • Order of Completion of Transactions The transactions provided for in Article II and Article III of this Agreement shall be completed immediately following the Effective Time in the following order: first, the transactions provided for in Article II shall be completed in the order set forth therein; and second, following the completion of the transactions provided for in Article II, the transactions provided for in Article III, if they occur, shall be completed.

  • Execution of Transactions (a) In executing transactions for the Assets, selecting brokers or dealers and negotiating any brokerage commission rates, the Sub-Adviser will use its best efforts to seek best execution. In assessing best execution available for any portfolio transaction, the Sub-Adviser will consider all factors it deems relevant including, but not limited to, the breadth of the market in the security, the price of the security, the financial condition and execution capability of the broker or dealer and the reasonableness of any commission for the specific transaction and for transactions executed through the broker or dealer in the aggregate. In selecting brokers or dealers to execute a particular transaction and in evaluating the best overall terms available, to the extent that the execution and price offered by more than one broker or dealer are comparable the Sub-Adviser may consider any brokerage and research services (as those terms are defined in Section 28(e) of the Securities Exchange Act of 1934) provided to the Sub-Adviser or to CSAM for use on behalf of the Fund or other clients of the Sub-Adviser or CSAM. (b) It is understood that the services of the Sub-Adviser are not exclusive, and nothing in this Agreement shall prevent the Sub-Adviser from providing similar services to other investment companies or from engaging in other activities, provided that those activities do not adversely affect the ability of the Sub-Adviser to perform its services under this Agreement. The Fund and CSAM further understand and acknowledge that the persons employed by the Sub-Adviser to assist in the performance of its duties under this Agreement will not devote their full time to that service. Nothing contained in this Agreement will be deemed to limit or restrict the right of the Sub-Adviser or any affiliate of the Sub-Adviser to engage in and devote time and attention to other businesses or to render services of whatever kind or nature, provided that doing so does not adversely affect the ability of the Sub-Adviser to perform its services under this Agreement. (c) On occasions when the Sub-Adviser deems the purchase or sale of a security to be in the best interest of the Fund as well as of other investment advisory clients of the Sub-Adviser, the Sub-Adviser may, to the extent permitted by applicable laws and regulations, but shall not be obligated to, aggregate the securities to be so sold or purchased with those of its other clients. In such event, allocation of the securities so purchased or sold, as well as the expenses incurred in the transaction, will be made by the Sub-Adviser in a manner that is fair and equitable, in the judgment of the Sub-Adviser, in the exercise of its fiduciary obligations to the Fund and to such other clients. The Fund recognizes that the effect of the aggregation may operate on some occasions to the Fund's advantage or disadvantage. The Sub-Adviser shall provide to CSAM and the Fund all information reasonably requested by CSAM and the Fund relating to the decisions made by the Sub-Adviser regarding allocation of securities purchased or sold, as well as the expenses incurred in a transaction, among the Fund and the Sub-Adviser's other investment advisory clients. (d) In connection with the purchase and sale of securities for the Fund, the Sub-Adviser will provide such information as may be reasonably necessary to enable the custodian and co-administrators to perform their administrative and recordkeeping responsibilities with respect to the Fund.

  • COMPLETION OF AGREEMENT This document comprises the entire agreement between the District and the Association in the matters lawfully within the scope of negotiation. Neither party shall have any obligation to meet and negotiate during the term of this agreement.

  • Completion of Services (a) The Customer must: (i) notify Deswik in writing as soon as the Customer becomes aware of any defects in the Services; or (ii) provide Deswik with an email confirming successful completion of any Services Deswik advises the Customer have been completed. (b) If the Customer does not notify Deswik of any defects under clause 5.4(a)(i) or provide Deswik with an email confirming successful completion of the Services within 14 days of Deswik notifying the Customer that the relevant Services are complete, the Customer is deemed to have accepted the Services. (c) If the Customer notifies Deswik of any defects under clause 5.4(a)(i), Deswik will, as soon as possible investigate and (where applicable) undertake rectification of the defects. Upon completion of any defect rectification the Customer must promptly provide an email notification of the successful completion of the services, unless further defects exist. In this case, the Customer is further required to notify Deswik of such defects.

  • Effectuation of Transactions Each of the representations and warranties contained in this Agreement (and all corresponding definitions) is made after giving effect to the Transactions, unless the context otherwise requires.

  • Description of Transaction 1.1 Merger of Merger Sub into the Company. Upon the terms and subject to the conditions set forth in this Agreement, at the Effective Time (as defined in Section 1.3), Merger Sub shall be merged with and into the Company, and the separate existence of Merger Sub shall cease. The Company will continue as the surviving corporation in the Merger (the “Surviving Corporation”).

  • Effective Date of Transfer Any assignment of a Limited Partner's Interest or Special Limited Partner's Interest pursuant to Section 12.1 shall become effective as of the first day of the calendar month in which the last of the conditions to such assignment are satisfied.

  • Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain. (b) Employees shall not be required to start a concrete pour in Inclement Weather. (c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear. (d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay. (e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.

  • Completion of Work The Contractor agrees to complete the work on, or before October 29, 2021.

  • Completion of the Work The Contractor must obtain Material Completion as defined in Section 6.1.2 below prior to any occupancy of the Project.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!