Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.
Condition of the Business (a) Notwithstanding anything contained in this Agreement to the contrary, Purchaser acknowledges and agrees that Seller is not making any representations or warranties whatsoever, express or implied, beyond those expressly given by Seller in Article V hereof (as modified by the Seller Schedules as supplemented or amended), and Purchaser acknowledges and agrees that, except for the representations and warranties contained therein, the Purchased Assets and the Business are being transferred on a “where is” and, as to condition, “as is” basis. Any claims Purchaser may have for breach of representation or warranty shall be based solely on the representations and warranties of Seller set forth in Article V hereof (as modified by the Seller Schedules as supplemented or amended). Purchaser further represents that neither Seller nor any of its Affiliates nor any other Person has made any representation or warranty, express or implied, regarding Seller, the Purchased Assets, the Business or the transactions contemplated by this Agreement or as to the accuracy or completeness of any information not expressly set forth in this Agreement and neither Purchaser nor any of its Affiliates has relied on any such express or implied representation or warranty. Purchaser further agrees that none of Seller, any of its Affiliates or any other Person will have or be subject to any liability to Purchaser or any other Person resulting from the distribution to Purchaser or its representatives or Purchaser’s use of, any such information, including any confidential memoranda distributed on behalf of Seller relating to the Business or other publications or data room information provided to Purchaser or its representatives, or any other document or information in any form provided to Purchaser or its representatives in connection with the sale of the Business and the transactions contemplated hereby. Purchaser acknowledges that it has conducted to its satisfaction, its own independent investigation of the Business and, in making the determination to proceed with the transactions contemplated by this Agreement, Purchaser has relied on the results of its own independent investigation.
Condition of Facilities (i) Use of the Real Property of Purchaser for the various purposes for which it is presently being used is permitted as of right under all Applicable Laws related to zoning and is not subject to “permitted nonconforming” use or structure classifications. All Improvements are in compliance with all Applicable Laws, including those pertaining to zoning, building and the disabled, are in good repair and in good condition, ordinary wear and tear excepted, and are free from latent and patent defects. To the Knowledge of Purchaser, no part of any Improvement encroaches on any real property not included in the Real Property of Purchaser, and there are no buildings, structures, fixtures or other Improvements primarily situated on adjoining property which encroach on any part of the Land.
(ii) Each item of Tangible Personal Property is in good repair and good operating condition, ordinary wear and tear excepted, is suitable for immediate use in the Ordinary Course of Business and is free from latent and patent defects. No item of Tangible Personal Property is in need of repair or replacement other than as part of routine maintenance in the Ordinary Course of Business. Except as disclosed in Schedule 5.1(l)(ii), all Tangible Personal Property used in the Purchaser Business is in the possession of Purchaser.
Condition of the Premises Tenant has examined the Premises, including the appliances and fixtures ( and furnishings), and acknowledges that they are in good condition and repair, normal wear and tear excepted, and accepts them in its current condition, except for:
Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Conditions to Obligation of the Buyer The obligation of the Buyer to consummate the transactions to be performed by it in connection with the Closing is subject to satisfaction of the following conditions:
(i) the representations and warranties set forth in Section 3(a) above shall be true and correct in all material respects at and as of the Closing Date;
(ii) the Seller shall have performed and complied with all of their covenants hereunder in all material respects through the Closing;
(iii) there shall not be any injunction, judgment, order, decree, ruling, or charge in effect preventing consummation of any of the transactions contemplated by this Agreement;
(iv) all necessary governmental, shareholder and third party consents and approvals in connection with the transactions contemplated by the Agreement shall have been obtained;
(v) the Seller shall have delivered to the Buyer certificates executed by the responsible officer or the secretary of the Seller, as applicable, certifying (A) that each of the conditions specified in Section 9(a)(i)-(iv) are satisfied in all respects, (B) the resolution(s) of the Seller's board of directors authorizing the Seller's execution, delivery and performance of the Agreement and all matters in connection with the Agreement and transactions contemplated thereby, and (C) the incumbency of the officer of the Seller executing the Agreement and all other documents executed and delivered in connection therewith;
(vi) the relevant parties shall have entered into the agreements in the forms set forth in (A) Exhibit G (Agreement Amending the Warrants), (B) Exhibit H (Assumption Agreement regarding the Warrants) and (C) Exhibit I (Agreement Amending Securities Purchase Agreement) and attached hereto and the same shall be in full force and effect;
(vii) the Buyer shall have received: (A) from Hungarian Counsel of the Seller, a legal opinion in the form set forth in Exhibit L attached hereto, and dated as of the Closing Date, to the effect that (u) the Seller need not give any notice to, make any filing with, or obtain any authorization, consent, or approval of any government or governmental agency in order to consummate the transactions contemplated by this Agreement, or if such notice filing, authorization, consent or approval is needed, it has been gained or obtained, (v) any arbitration award in favor of the Buyer obtained pursuant to this Agreement would be valid and enforceable before a court of competent jurisdiction in Hungary and (x) the matters set forth in Section 3(a)(i) and the first and third sentences of Section 3(a)(ii) of the Agreement; and (B) from US Counsel to the Seller, an opinion in the form as may be attached hereto as Exhibit K, and dated as of the Closing Date (y) covering the matters set forth in the second sentence of Section 3(a)(ii) of the Agreement and (z) stating that no registration is required under the Securities Act to transfer the Shares, Unsecured Notes or the Warrants to Buyer in accordance with the Agreement;
(viii) the Closing Arrangements set forth in Exhibit J attached hereto shall have been implemented in full to the Buyer's satisfaction; for the avoidance of doubt Seller acknowledges and agrees that unless and until the Closing Arrangements set forth in Exhibit J have been implemented as contemplated by this Section 9(a)(viii), Buyer shall have no obligation whatsoever to pay the Purchase Price;
(ix) Since the date of the this Agreement, no event or events shall have occurred which have had or reasonably may be expected to have a Material Adverse Effect;
(x) All actions to be taken by the Seller in connection with consummation of the transactions contemplated hereby and all certificates, opinions, instruments, and other documents required to effect the transactions contemplated hereby will be reasonably satisfactory in form and substance to the Buyer; and
(xi) The Buyer shall have had the opportunity to conduct a reasonable investigation of the matters set forth in Schedule 3(a)(viii) of this Agreement and satisfy itself that no material commercial risk will be transferred with respect to the Shares, Unsecured Notes and Warrants as a result of the dispute described therein in the event that the Closing shall occur. The Buyer may waive any condition specified in this Section 9(a) if it executes a writing so stating at or prior to the Closing.
Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
