Conditions for quality of peer production18 Sample Clauses

Conditions for quality of peer production18. As a point of departure, eLearning 2.0 does not require a new mode of thinking or method of quality development, such as a new and completely altered philosophy of quality – no “educational quality 2.0” is needed. However, changed basic conditions and contexts need to be taken into account. Doing justice to these different contexts, different questions need to be posed when dealing with quality development, different objects evaluated, different criteria of quality applied and specific methods of quality assurance, enhancement and development used. In short: the role of quality development is changing. While in traditional learning scenarios it mostly means the checking and controlling of quality, in eLearning 2.0 it is becoming more the role of an enabler of learning progress. Learning methods and quality development are moving closer together. Methods such as feedback, reflection and recommendation mechanisms are becoming more important. Typical basic conditions, which need to be taken into account in quality development for eLearning 2.0 scenarios, are explained in the following: ♦ From reception to participation: the metaphor used for learning is changing. In eLearning
Sample 1
AutoNDA by SimpleDocs

Related to Conditions for quality of peer production18

  • EMHS Governance, Safety and Quality Requirements 4.1 Participates in the maintenance of a safe work environment.

  • SMHS Governance, Safety and Quality Requirements 4.1 Participates in the maintenance of a safe work environment.

  • NMHS Governance, Safety and Quality Requirements 3.1 Participates in the maintenance of a safe work environment.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Data Quality 4.1 Each party ensures that the shared Personal Data is accurate.

  • Xxxxxxx to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.

  • Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.

  • COUNTY’S QUALITY ASSURANCE PLAN The County or its agent will evaluate the Contractor’s performance under this Contract on not less than an annual basis. Such evaluation will include assessing the Contractor’s compliance with all Contract terms and conditions and performance standards. Contractor deficiencies which the County determines are severe or continuing and that may place performance of the Contract in jeopardy if not corrected will be reported to the Board of Supervisors. The report will include improvement/corrective action measures taken by the County and the Contractor. If improvement does not occur consistent with the corrective action measures, the County may terminate this Contract or impose other penalties as specified in this Contract.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. OGS CENTRALIZED CONTRACT MODIFICATIONS Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.

Time is Money Join Law Insider Premium to draft better contracts faster.